FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

County Sovereign Immunity Invokes Change-Order Ordinance

December 20, 2017 — Lizbeth Dison - AHC Contruction Law Blog
The recent case of Fulton County v. Soco Contracting Company, Inc. addresses two very interesting questions for local government attorneys. First, can a county ordinance bolster a defense of sovereign immunity against a contractor’s claims? Second, can a county waive sovereign immunity by failing to respond to Requests for Admission? Facts: County hired Contractor to construct a facility near the airport. The contract provided that change orders must satisfy a county ordinance, which required approval by the Board of Commissioners. But in emergency situations, the County Manager could approve change orders, as long as the contractor executes a proposed modification and the purchasing agent approves it. The project suffered substantial delays, which Contractor attributed to weather, design delays, delays by the County in providing decisions on changes, and delays in obtaining permits during the federal government’s shutdown. As a result of these issues, Contractor comes County changed the scope of the contract. Contractor asserted claims against County for the delays and the changes to the work. The appellate opinion addresses the change order claims. Read the court decision
Read the full story...
Reprinted courtesy of Lizbeth Dison, Autry Hall & Cook, LLP

---

UK Construction Defect Suit Lost over One Word

October 16, 2013 — CDJ STAFF
In the UK, be careful what you tell your insurer; the Court of Appeal has upheld the legality of basis clauses. As Paul Lewis and Janetta Gibbs of Herbert Smith Freehills LLP explain, “a basis clause is a provision set out in the proposal form or in the insurance contract itself, to the effect that all or any of the answers to the questions in the proposal shall form the basis of the contract of insurance.” The catch, as they point out, is that “should any of those answers — whether material to the risk or not — prove to be untrue, the insurer may repudiate the policy and treat itself as never having been on risk.” There is a move in the UK to abolish the use of basis clauses in business insurance, but currently they are still legal. This came up in a construction defect case covering latent defects in a public housing project. The contract between the owner, Genesis Housing Association Limited, and the contractor, Time and Tide (Bedford) Ltd, required TT Bedford to indemnify Genesis if it became insolvent. In the contract with the insurer, representatives of Bedford and Genesis referred to the contractor as “TT Construction.” While the courts concluded that Bedford and Genesis were not guilty of misrepresentation or intent to defraud, they did note that neither party thought the firm’s name was “TT Construction.” Therefore, over the failure to name the builder correctly, the court found that the insurance contract was invalid. Read the court decision
Read the full story...
Reprinted courtesy of

---

Southern California Lost $8 Billion in Construction Wages

August 17, 2011 — CDJ STAFF

Los Angeles and Orange Counties are first on a list no area wants to be on. According to the Sacramento Bee, reporting on data from the U.S. Bureau of Economic Analysis, LA and Orange Counties saw an $8 billion drop in construction wages in 2010, as compared to 2006. In 2006, the region saw payrolls of $26.8 billion, but in 2010, that was reduced to $18.5 billion.



This was not the largest percentage change. Of the metropolitan areas with the largest declines in construction earnings, Las Vegas saw a $3.6 billion drop, however that represented half of their 2006 totals of $7.2 billion. Conversely, a $3.3 billion drop in the New York area represented only 10% of what had been $33.8 billion in payroll in 2006.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

ADA Lawsuits Spur Renovation Work in Fresno Area

November 06, 2013 — CDJ STAFF
The El Gallo restaurant in Clovis, California has completed more than $45,000 worth of accessibility upgrades, ranging from installing signs for handicap parking to an $8,000 wheelchair-accessible ramp. The restaurant closed in 2010 when they were sued over alleged Americans with Disabilities Act (ADA) violations. But the El Gallo was only the first Fresno-area business hit with an accessibility lawsuit. And others wanted to avoid getting sued at all. Donald Bremseth, an architect working in Clovis, said that designing modifications to older buildings to bring them into compliance with the ADA has kept him busy, designing dozens of projects in the area. Daniel Zoldak, vice president of Lars Anderson & Associates, noted at on one inspection, he saw about 50 ADA violations, and with the fines at least $2,000 per violation, $10,000 or $20,000 of renovations doesn’t look so bad. That’s under the new law, which also allows a business 30 days to get into compliance. Under the old law, the minimum fine was $4,000. Read the court decision
Read the full story...
Reprinted courtesy of

---

Deck Police - The New Mandate for HOA's Takes Safety to the Next Level

November 18, 2019 — Joseph Ferrentino – Newmeyer Dillion
A recent California law will hold homeowners’ associations accountable for the safety of their decks. SB326 now mandates all homeowners' associations to have decks inspected at least once every nine years by an architect or structural engineer to determine whether the decks are safe and waterproof. This law (Civil Code section 5551) follows SB721 which was passed in 2018 and requires a similar inspection every six years for other multifamily dwelling units. Failure to comply can result in paying the enforcement costs of local building agencies. DETAILS ON THE MANDATE: More specifically, the 2019 law requires inspections of wood “decks, balconies, stairways, and their railings” more than six feet off of the ground and designed for human use. Additionally, the engineer or architect must (1) certify that he or she has inspected for safety and waterproofing, and (2) certify the remaining useful life of the system. Further, the inspector must inspect a random sample of enough units to provide 95% confidence that “the results are reflective of the whole.” In other words, in addition to the inspector, the association will have to hire a statistician. The nine-year timetable for inspection is no coincidence. After all, the statute of limitations for construction defects is ten years. In fact, associations are required to give notice to their members before filing a suit against a builder. However, under the new law, the association can delay giving notice to its members “if the association has reason to believe that the statute of limitations will expire.” Also, recent case law held that builders could add requirements to CC&R’s to limit a board’s authority to file lawsuits – i.e. adding a supermajority vote by members. Under SB326, any such provisions are now void. Hence, “supermajority” voting provisions are now invalid. IMPACT ON CONSTRUCTION LITIGATION These recent laws are clearly a reaction to the tragic collapse of an apartment balcony in Berkley in 2015 that resulted in the death of six college students. While it is imperative that decks be structurally safe, the requirements of SB326 will fuel more construction defect litigation. Joseph Ferrentino is a Partner in Newmeyer Dillion's Newport Beach office. With 25 years of experience, Joe guides clients through construction law issues, among other areas. For more information on how Joe can help, contact him at joe.ferrentino@ndlf.com ABOUT NEWMEYER DILLION For 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results that align with the business objectives of clients in diverse industries. With over 70 attorneys working as an integrated team to represent clients in all aspects of business, employment, real estate, privacy & data security and insurance law, Newmeyer Dillion delivers tailored legal services to propel clients’ business growth. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California and Nevada, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com Read the court decision
Read the full story...
Reprinted courtesy of

---

The Trend in the Economic Loss Rule in Construction Defect Litigation

January 14, 2015 — Beverley BevenFlorez-CDJ STAFF
Heather Howell Wright of Bradley Arant Boult Cummings LLP, analyzed the Massachusetts Supreme Court decision in Wyman v. Ayer Properties, LLC, which ruled that the “economic loss rule is not applicable to the damage caused to the common areas of a condominium building as a result of the builder’s negligence.” Wright compared Wyman to last year’s Florida Supreme Court case, Tiara Condominium Association v. Marsh & McLennan Companies that decided “that the economic loss rule did not preclude a condominium association from asserting a negligence claim against a contractor for defective work.” Wright concluded that “[t]he Wyman decision is another ruling in a growing line of cases where courts have limited application of the economic loss rule and have held that a contractor can be liable in tort for defective work.” Read the court decision
Read the full story...
Reprinted courtesy of

---

The Right to Repair Act Means What it Says and Says What it Means

December 18, 2022 — Garret Murai - California Construction Law Blog
A rather short case for a short week. In Gerlach v. K. Hovnanian’s Four Seasons at Beaumont, LLC, 82 Cal.App.5th 303 (2022), the 4th District Court of appeals examined provisions of the Right to Repair Act (Civ. Code §§895 et. seq), also known as “SB 800” after its original bill number, as it applies to roofs. The Gerlach Case Lynn Gerlach and Lola Seals are homeowners who purchased their homes in the Four Seasons at Beaumont adult community, for those 55 year old and older, located in Beaumont, California. Gerlach purchased her home when it was built in 2006. Seals purchased her home from the original owners in 2015. In 2015 and 2016, Gerlach and Seals served the developer, K. Hovnanian’s Four Seasons at Beaumont, LLC, with claim notices under the Right to Repair Act. The Right to Repair Act, as its name implies, provides notice requirements and repair rights by developers of new single-family homes. The Right to Repair Act also includes construction standards, the violation of which, provides homeowners with a statutory basis for bringing construction defect claims. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Ensuring Efficient Arbitration of Construction Disputes Involving Mechanic’s Liens

February 18, 2020 — Robert G. Campbell & Trevor B. Potter - Construction Executive
There may be tension between the enforcement of statutory mechanic’s lien claims when a contractual dispute resolution provision calls for arbitration. Once the parties are in arbitration, it may not be clear whether the arbitrator has authority to make factual determinations regarding amount and validity of mechanic’s liens, and whether courts are bound by these determinations. This uncertainty stems from the fact that in most states a mechanic’s lien can only be enforced by a court of competent jurisdiction. Indeed, many mechanic’s liens statutes define foreclosure as a “judicial process,” and courts generally have exclusive jurisdiction to issue orders foreclosing on real property1. The risk for contractors and owners is that they will spend time and money re-litigating factual issues related to proving elements of a mechanic’s lien claim, including the proper lien amount, timeliness and other prerequisites. Without a clear understanding of what issues and elements are arbitrable, the parties run the risk that an arbitrator will rule on certain elements only to find out during post-arbitration lien foreclosure proceedings that the arbitrator lacked authority to make determinations on those elements. Questions therefore arise whether a court will enforce the arbitrator’s determinations and whether the parties must relitigate mechanic’s lien issues creating a further risk of inconsistent rulings. These risks can be minimized through arbitration provisions which address these issues, express requests in arbitration demands and by ensuring that arbitration awards contain explicit determinations of mechanic’s liens issues. Reprinted courtesy of Robert G. Campbell & Trevor B. Potter, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Mr. Potter may be contacted at tpotter@coxcastle.com Mr. Campbell may be contacted at rcampbell@coxcastle.com Read the court decision
Read the full story...
Reprinted courtesy of

---