Seattle Washington Building Expert Directory

Ready, Fire, Aim: The Importance of Targeting Your Delay Notices

November 08, 2021 — Bradley Sands, Jones Walker LLP - ConsensusDocs
Providing written notice of delay to subcontractors when a project is behind schedule is a regular part of good project documentation practices. A properly targeted delay notice is an important, project correspondence that is an appropriate response to a subcontractor’s specific delay or ongoing delays. However, when a project falls behind schedule and the project management team is in the fog of war, it could seem like a good idea to start firing off project delay notices to any and every subcontractor. While these delay notices may provide a short term burst of productivity, you could find that those same notices are aimed back at you in a future litigation. This article identifies two potential unintended consequences of sending delay notices that a contractor should keep in its sights and then provides recommendations for properly calibrating future delay notices in light of these potential consequences. Acceleration: You Might Get What You Ask For A delay notice to a subcontractor could be interpreted as—or expressly state—direction to the subcontractor to accelerate its work. When a subcontractor is directed to accelerate its work, it may incur additional costs for premium, extended, or overtime labor, additional crews, increased supervision costs, increased overhead costs, and losses due to productivity impacts from the acceleration (e.g., stacking of trades and fatigue). A subcontractor may be entitled to recover these increased costs that are caused by a direction to accelerate. Read the court decision
Read the full story...
Reprinted courtesy of Bradley Sands, Jones Walker LLP
Mr. Sands may be contacted at bsands@joneswalker.com

Massachusetts Federal Court Rejects Adria Towers, Finds Construction Defects Not an “Occurrence”

July 03, 2022 — Eric B. Hermanson & Austin D. Moody - White and Williams
In an important ruling for insurers, U.S. District Court Judge Patti Saris found that Massachusetts does not follow the position taken in Cypress Point Condo Association v. Adria Towers, LLC, 226 N.J. 403, 418 (2016), i.e., it does not hold that "faulty workmanship claims [should be recognized] as ... an 'occurrence,' thus triggering coverage, 'so long as the allegedly defective work [was] performed by a subcontractor rather than the policyholder itself."[1] Instead, Judge Saris reaffirmed earlier Massachusetts authority holding faulty work is not an "occurrence" for coverage purposes,[2] and found this authority applied whether or not the work in question was subcontracted. In the alternative, Judge Saris found, even if a contractor's faulty work could be deemed an an "occurrence," such work did not constitute covered "property damage," because none of the alleged damage was "outside the scope of the work that Tocci was contractually required to fulfill as general contractor."[3] Reprinted courtesy of Eric B. Hermanson, White and Williams and Austin D. Moody, White and Williams Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Moody may be contacted at moodya@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

California Makes Big Changes to the Discovery Act

March 04, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Beginning January of 2024, California amended the Civil Discovery Act to mirror the Federal Rules and require that any party appearing in a civil action to provide initial disclosures to any other party demanding the same. In January of 2024, California amended the Civil Discovery Act, specifically C.C.P. section 2016.090, to affirmatively require that any party appearing in a civil action to provide initial disclosures to any other party demanding the same. In an effort to reflect the Federal Rule 26 disclosure requirements, as many other States have adopted, California will now also mandate (upon demand) that a party produce evidence without an arduous and possibly duplicative effort. In other words, this initial disclosure will require a party making initial disclosures of persons or records to additionally disclose persons or records that are relevant to the subject matter of the action and to disclose information and records regarding insurance policies or contracts that would make a person or insurance company liable to satisfy a judgment. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Traub Lieberman Attorneys Lisa M. Rolle and Vito John Marzano Secure Dismissal of Indemnification and Breach of Contract Claims Asserted against Subcontractor

November 24, 2019 — Lisa M. Rolle & Vito John Marzano - Traub Lieberman Perspectives
On August 7, 2019, TLSS Partner Lisa M. Rolle and associate Vito John Marzano obtained a dismissal of all claims on behalf of their client, the subfloor subcontractor at the worksite, in a severed action filed in the Supreme Court of the State of New York, County of Kings. In April 2014, plaintiff commenced suit against several defendants, including the general contractor, after he sustained an injury when he fell through temporary plywood while installing a staircase at a worksite in Brooklyn. In May 2018, plaintiff filed a note of issue and certified the matter as ready for trial. Immediately thereafter, the general contractor initiated a second third-party action against the subcontractor seeking common-law and contractual indemnification and breach of contract. The Court subsequently granted Traub Lieberman’s motion to sever the second third-party action and instructed the general contractor to file a new action. After the general contractor recommenced suit, Traub Lieberman, on behalf of its client, the subcontractor, immediately moved to dismiss for failure to state a cause of action. In relevant part, Traub Lieberman pointed to the deposition testimony of the general contractor’s principal to establish that the subcontractor had finished its work on the permanent subfloor no less ten months to over a year prior to plaintiff’s accident, and that the subfloor required no alteration, repair or maintenance prior to or as a result of plaintiff’s accident. Further, the general contractor’s testimony pointed to work performed by another subcontractor that directly resulted in plaintiff’s injuries. It was also brought to the Court’s attention that plaintiff had testified that he fell through a temporary plywood floor, and that the subcontractor had only installed a permanent subfloor. Reprinted courtesy of Lisa Rolle, Traub Lieberman and Vito John Marzano, Traub Lieberman Ms. Rolle may be contacted at lrolle@tlsslaw.com Mr. Marzano may be contacted at vmarzano@tlsslaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Discussion of the Discovery Rule and Tolling Statute of Limitations

February 26, 2015 — Beverley BevenFlorez-CDJ STAFF
Attorney Clay Olson analyzed a recent South Carolina appeals case that “discussed the threshold for ‘notice’ as it pertains to statute(s) of limitations in construction defect cases. At the root of this action was a 2003 forensic report obtained by the HOA which was not acted upon until 2009.” Olson presented the background of the case as well as the case progression. Olson concluded, “It is well settled that an expert’s findings, when presented to a claimant, trigger the statute of limitations as to the specific defective conditions and locale where defects are present. This case is interesting in its treatment of the initial report as a trigger of all defects in not only the main building which was subject of the 2003 report, but additional structures.” Read the court decision
Read the full story...
Reprinted courtesy of

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

Product Defect Allegations Trigger Duty To Defend in Pennsylvania

August 31, 2020 — Stacy M. Manobianca - Saxe Doernberger & Vita
The Third Circuit Court of Appeals recently concluded, in Nautilus Insurance Co. v. 200 Christian Street Partners, LLC., that a duty to defend is triggered when product-related allegations are pled in connection with a claim for defective construction. In Nautilus, the coverage dispute arose out of two independent underlying lawsuits in which homeowners alleged that the homes built by 200 Christian Street Partners (“Christian Street”) were defectively constructed. Christian Street tendered the claim to its insurer, Nautilus Insurance Co. (“Nautilus”), for defense and indemnity.1 Nautilus filed a lawsuit in the United States District Court for the Eastern District of Pennsylvania, seeking a declaration that it was not obligated to defend Christian Street in the underlying actions.2 Specifically, Nautilus asserted that it was not required to provide a defense in the underlying actions because Pennsylvania law does not consider faulty workmanship to constitute an “occurrence” and, therefore, to trigger the policy’s insuring agreement and the insurer’s duty to defend.3 Read the court decision
Read the full story...
Reprinted courtesy of Stacy M. Manobianca, Saxe Doernberger & Vita
Ms. Manobianca may be contacted at smm@sdvlaw.com

The Independent Tort Doctrine (And Its Importance)

October 24, 2022 — David Adelstein - Florida Construction Legal Updates
A non-construction raises an important legal principle. Here it is because it applies to construction disputes. It actually applies to many business-type disputes. It is based on what is widely referred to as the independent tort doctrine: Florida law does not allow a party damaged by a breach of contract to recover exactly the same contract damages via a tort claim. “It is a fundamental, long-standing common law principle that a plaintiff may not recover in tort for a contract dispute unless the tort is independent of any breach of contract. A plaintiff bringing both a breach of contract and a tort claim must allege, in addition to the breach of contract, “some other conduct amounting to an independent tort.” Bedoyan v. Samra, 47 Fla.L.Weekly D1955a (Fla. 3d 2022) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES