CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Owner’s Obligation Giving Notice to Cure to Contractor and Analyzing Repair Protocol

November 23, 2016 — David Adelstein – Florida Construction Legal Updates
Recently, I read an informative article from another attorney addressing considerations of an owner when it receives a repair protocol in response to a Florida Statutes Chapter 558 notice of defect letter. This is a well-written article and raises two important issues applicable to construction defect disputes: 1) how is an owner supposed to respond to a repair protocol submitted by a contractor in accordance with Florida’s 558 notice of construction defects procedure and 2) irrespective of Florida’s 558 procedure, how is an owner supposed to treat a contractual notice to cure / notice of defect requirement that requires the owner to give the contractor a notice to cure a defect. This article raises such pertinent points that I wanted to address the issues and topics raised in this article. 558 Procedure–Owner’s Receipt of Contractor’s Repair Protocol When a contractor submits a repair protocol to an owner in response to a notice of construction defects letter per Florida Statutes Chapter 558, the owner should seriously consider that protocol. The owner does this by discussing with counsel and any retained expert. The owner needs to know whether the protocol is a reasonable, cost-effective protocol to repair the asserted defects or, alternatively, whether the protocol is merely a band-aid approach and/or otherwise insufficiently addresses the claimed defects. Every scenario is different. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

---

Virginia Decision Emphasizes Importance of Naming All Necessary Parties

June 17, 2015 — Beverley BevenFlorez-CDJ STAFF
Nate Budde on the Construction Payment Blog, discussed the potential of mechanics liens, and the pitfalls that occur when not all necessary parties are named. Budde analyzed the case Johnson Controls Inc. v. Norair Eng’g Corp. that involved a “claimant’s failure to name all the necessary parties in his claim against a bond,” resulting “in the claimant losing his claim against the bond, and with it, an opportunity to get paid.” Budde concluded, “Unfortunately, as was the case here, when the bond claim is not handled correctly procedurally, a party can be left with no recourse for payment. It’s important to understand which of the parties involved should be named in both mechanics lien claims and bond claims.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Want a Fair Chance at a Government Contract? Think Again

July 13, 2017 — Duane Craig - Construction Informer
If you’ve ever missed out on a government contract, part of the reason might have been because entrenched government contractors gained competitive advantages by under-paying their workers. The Fair Pay & Safe Workplaces executive order was nullified by Congress this year and much of the reporting by the business press presented just one side of the story. Here’s another perspective. When awarding federal contracts the government is supposed to consider each contractor’s compliance with labor laws related to pay, health and safety. But, there is a huge problem with enforcement on a government contract, according to Senator Elizabeth Warren and other observers.

• Some federal contractors frequently underpay their workers violating wage and hour laws. More than 300,000 workers were cheated out of pay while working under federal contracts in the last decade. There were 12,000 companies working on federal contracts that were doing the cheating.
• 692 federal contractors significantly violated federal labor laws, and then repeated the behavior, over and over. The repeat offenders receive millions in taxpayer dollars as they violated safety and health standards. Those violations caused a wide range of physical harm to workers. Dozens of workers died, and countless numbers were exposed to chemicals that cause long term health problems.

Read the court decision
Read the full story...
Reprinted courtesy of Duane Craig, Construction Informer
Mr. Craig may be contacted at dtcraig@constructioninformer.com

---

A Court-Side Seat: A Poultry Defense, a Houston Highway and a CERCLA Consent Decree that Won’t Budge

March 22, 2021 — Anthony B. Cavender - Gravel2Gavel
February saw the usual array of significant environmental decisions and federal regulatory notices. THE FEDERAL COURTS U.S. Court of Appeals for the District of Columbia Luminant Generation v. EPA The court will be grappling with a difficult venue case governed by the Clean Air Act (42 USC Section 7607(b)). In 2013, the U.S. Court of Appeals for the Fifth Circuit decided the case of Luminant Generation v. EPA (714 F. 3d 841), in which the court upheld the affirmative defenses that were made part of the Texas State Implementation Plan (SIP) and which applied to certain unpermitted emissions from regulated sources during periods of startup, shutdown or malfunction. These defenses were challenged in the Fifth Circuit and were rejected. On the national stage, EPA has been involved in litigation over these affirmative defenses and recently excluded from a “SIP Call” the Texas program, which was carved out. This EPA decision is being challenged in the DC Circuit (see Case number 20-1115),with the State of Texas arguing as an intervenor that any issues involving Texas belong in the Fifth Circuit, and not in the DC Circuit because the Act allows regional issues to be decided in the regional federal courts. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---

Weed Property Owner Gets Smoked Under Insurance Policy

May 10, 2022 — Garret Murai - California Construction Law Blog
When’s the last time you read your homeowner’s insurance policy? Didn’t think so. But you might consider doing so, particularly in light of all of the discussions surrounding climate change – a nearly 2 degree Fahrenheit increase in summer temperatures over the past 20 years – and studies finding that wildfires in California could increase by 20% or more by the 2040s, and that the total burned area could increase by 25% or more. In the next case, Vulk v. State Farm (2021) 69 Cal.App.5th 243, one homeowner found out too late (after his house burned to the ground) that his homeowner’s insurance policy didn’t provide the coverage that he thought it did. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Combating Climate Change by Reducing Embodied Energy in the Built Environment

December 02, 2019 — Brent Trenga - Construction Executive
The building and construction industry is a significant consumer of non-renewable energy resources and is contributing to changing the earth’s environment in damaging and irreversible ways. These impacts are being felt in climate-related shifts that include increases in the earth’s average temperature and rising sea levels. A new report by NASA and the National Oceanic and Atmospheric Administration shows that 2018 was the fourth-hottest year since 1880, the earliest year for which reliable global temperature data is available. The three hottest years on record were 2015, 2016 and 2017. Additionally, the rise in sea levels is causing “nuisance floods” to become more common. From the 1950s to the early 2000s, the days of flooding in the 27 most vulnerable cities across the United States grew from two per year to nearly 12. These and other environmental impacts underscore the urgency of battling climate change and how critical it is for all industries—including construction—to stem the tide on this issue. Reducing embodied energy in the built environment is one way the building and construction sector can do its part to address one of the major challenges of this century. Reprinted courtesy of Brent Trenga, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Trenga may be contacted at brent.trenga@kingspan.com

---

More Hensel Phelps Ripples in the Statute of Limitations Pond?

February 03, 2020 — Christopher G. Hill - Construction Law Musings
As is always the case when I attend the Virginia State Bar’s annual construction law seminar, I come away from it with a few posts on recent cases and their implications. The first of these is not a construction case, but has implications relating to the state project related statute of limitations and indemnification issues for construction contracts brought out in stark relief in the now infamous Hensel Phelps case. In Radiance Capital Receivables Fourteen, LLC v. Foster the Court considered a waiver of the statute of limitations found in a loan contract. The operative facts are that the waiver was found in a Continuing Guaranty contract and that the default happened more than 5 years prior to the date that Radiance filed suit to enforce its rights. When the defendants filed a plea in bar stating that the statute of limitations had run and therefore the claim was barred, Radiance of course argued that the defendants had waived their right to bring such a defense. The defendants responded that the waiver was invalid in that it violated the terms of Va. Code 8.01-232 that states among other things:

an unwritten promise not to plead the statute shall be void, and a written promise not to plead such statute shall be valid when (i) it is made to avoid or defer litigation pending settlement of any case, (ii) it is not made contemporaneously with any other contract, and (iii) it is made for an additional term not longer than the applicable limitations period.

The Circuit Court and ultimately the Supreme Court agreed with the defendants. In doing so, the Virginia Supreme Court rejected arguments of estoppel and an argument that a “waiver” is not a “promise not to plead.” Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---