FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

---

New England Construction Defect Law Groups to Combine

November 13, 2013 — CDJ STAFF
The lawyers of Little Bulman Medeiros & Whitney PC will be joining Pierce Atwood on December 9, 2013. The combined firm will have a larger construction litigation practice. Little Bulman is already recognized for its handling of construction disputes. Pierce Atwood is one of the largest firms in New England. Their combined forces intended to create a strong presence in construction litigation throughout New England. Gloria Pinza, a managing partner at Pierce Atwood said of Little Bulman that “their exceptional credentials in the construction law area will combine with our strong construction practice to create a regional practice that will provide highly competitive expertise, depth and value throughout New England and beyond. Read the court decision
Read the full story...
Reprinted courtesy of

---

Oregon agreement to procure insurance, anti-indemnity statute, and self-insured retention

March 05, 2011 — CDCoverage.com

In Continental Casualty Ins. Co. v. Zurich American Ins. Co., No. 09-35484 (9th Cir. Oct. 28, 2010), general contractor TCR was sued by an employee of subcontractor Safeway for bodily injuries suffered while working on the project. In the subcontract, Safeway agreed to procure primary insurance providing coverage for TCR for liability arising out of Safeway’s negligence. Safeway’s CGL policy included a self-insured retention that had to be satisfied before the insurer had a duty to defend. TCR filed suit against Safeway alleging that

Read the full story...

Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Like Water For Chocolate: Insurer Prevails Over Chocolatier In Hurricane Sandy Claim

November 08, 2017 — Afua S. Akoto - Saxe Doernberger & Vita, P.C.
Recently, a New Jersey Magistrate ruled that an insurer did not have to provide coverage for a chocolatier’s property damage and business interruption losses due to Hurricane Sandy. Madeline Chocolate Novelties Inc. (Madeline), a family-owned chocolatier in Queens Rockaway Beach, held a one-year all-risk policy with Great Northern Insurance (Great Northern). The policy contained a flood exclusion and a windstorm endorsement. When Hurricane Sandy hit in October 2012, Madeline suffered extensive damage and ceased operations during the ensuing holiday season. The chocolatier claimed $40 million in property damage and $13.5 million in business interruption losses and sought coverage under its policy. Great Northern paid just under $4 million and denied the remainder of the claim, citing the policy’s flood exclusion. Read the court decision
Read the full story...
Reprinted courtesy of Afua S. Akoto, Saxe Doernberger & Vita, P.C.
Ms. Akoto may be contacted at asa@sdvlaw.com

---

The Miller Act Explained

May 21, 2014 — Beverley BevenFlorez-CDJ STAFF
Garret Murai, on his California Construction Law Blog, goes over the nuances of the Federal Miller Act. Murai explained, “Named after John E. Miller, former Arkansas Congressman, later U.S. Senator and still later federal judge, the Miller Act was enacted in 1935 in the middle of the Great Depression, to help ensure that subcontractors and material suppliers working on federal projects get paid, by requiring contractors who contract directly with the federal government on federal construction projects furnish payment and performance bonds.” Murai answered questions such as what is required under the act, who is protected, how a general contractor could protect itself from a Miller Act claim, as well as others. Read the court decision
Read the full story...
Reprinted courtesy of

---

Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can’t Look Back Again)

October 05, 2020 — Christopher G. Hill - Construction Law Musings
I’ve discussed the continuing litigation between White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc. previously here at Construction Law Musings because the case was another reminder that your construction contract terms matter and will be interpreted strictly here in the Commonwealth of Virginia. The prior opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision. In the latest opinion from the Court (PDF) the Court looked at when and how any liquidated damages would be calculated. In its June 22, 2020 opinion, the Court put the issue as follows:

White Oak’s motion for partial summary judgment presents a narrow issue: whether courts may consider the damages actually sustained by a party as a result of a contract breach when deciding if liquidated damages required by a contract “grossly exceed” a party’s actual damages.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Can a Home Builder Disclaim Implied Warranties of Workmanship and Habitability?

August 30, 2021 — Kevin J. Parker - Snell & Wilmer Real Estate Litigation Blog
In a recent Arizona Court of Appeals case, Zambrano v. M & RC II LLC, 2021 WL 3204491 (7/29/2021), the Court of Appeals addressed the question whether a home builder’s attempt to disclaim implied warranties of workmanship and habitability was effective. In that case, the buyer initialed the builder’s prominent disclaimer of all implied warranties, including implied warranties of habitability and workmanship. After the purchase, the buyer sued the builder, claiming construction defects. The builder moved for summary judgment, seeking enforcement of the disclaimer of warranties. The trial court granted the builder’s motion for summary judgment, thereby enforcing the disclaimers. The buyer appealed. The Court of Appeals addressed the question whether – as a matter of public policy – the implied warranties of workmanship and habitability were waivable. The Court of Appeals started the analysis by noting that the Arizona Supreme Court had, in a 1979 case, judicially eliminated the caveat emptor rule for newly built homes. The court further noted the long history of cases detailing the public policy favoring the implied warranties. But the court also noted the competing public policy of allowing parties to freely contract; explaining that the usual and most important function of the courts is to maintain and enforce contracts rather than allowing parties to escape their contractual obligations on the pretext of public policy. Read the court decision
Read the full story...
Reprinted courtesy of Kevin J. Parker, Snell & Wilmer
Mr. Parker may be contacted at kparker@swlaw.com

---

2017 Colorado Construction Defect Recap: Colorado Legislature and Judiciary Make Favorable Advances for Development Community

January 24, 2018 — Kaitlin Marsh-Blake – Gordon & Rees Construction Law Blog
Last March, the Colorado General Assembly introduced House Bill 17-1279 concerning the requirement that a unit owners’ association obtain approval through a vote of unit owners before filing a construction defect action. The bill, passed in May, requires a home owners’ association to first notify all unit owners and the developer or builder of a potential construction defect action, call a meeting where both the HOA and developer or builder have an opportunity to present arguments and potentially remedy the defect, and obtain a majority vote of approval from the unit owners to pursue a lawsuit before bringing a construction defect action against a developer or builder. The bill amends C.R.S. § 38-33.3-303.5, which previously only required substantial compliance with the above-mentioned actions. Moreover, the previous version of C.R.S. § 38-33.3-303.5 did not require the HOA to perform these actions prior to a suit being filed. HB 17-1279 also removed the provision of C.R.S. § 38-33.3-303.5 that made it only applicable to buildings of five or more units. Read the court decision
Read the full story...
Reprinted courtesy of Kaitlin Marsh-Blake, Gordon & Rees
Ms. Marsh-Blake may be contacted at kmarsh-blake@grsm.com

---