SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

“Time Is Money!” In Construction and This Is Why There Is a Liquidated Damages Provision

February 01, 2022 — David Adelstein - Florida Construction Legal Updates
In construction, the adage “Time is Money!” rings true for all parties involved on a project. This includes an owner of a project that wants a project completed on time, i.e., by a substantial completion date. While substantial completion is often defined as when an owner can use a project for its intended purpose, this intended purpose typically equates to beneficial occupancy (in new construction) and other factors as identified in the contract. The best mechanism for an owner to reinforce time and the substantial completion date is through a liquidated damages provision (also known as an LD provision) that includes a daily monetary rate for each day of delay to the substantial completion date. A liquidated damages provision is not designed, and should NEVER be designed, to serve as a penalty because then it would be unenforceable. Instead, it should be designed to reasonably compensate an owner for delay to the substantial completion date that cannot be ascertained with any reasonable degree of certainty at the time the contract is being negotiated and executed. (Liquidated damages are MUCH easier to prove than actual damages an owner may incur down the road.) As an owner, you don’t really want to assess liquidated damages because that means the project is not substantially completed on time. And, in reality, a timely completed and performing project should always be better and more profitable than a late and underperforming project. However, without the liquidated damages provision, there isn’t a great way to hold a contractor’s feet to the fire with respect to the substantial completion date. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Real Estate & Construction News Roundup (5/29/24) – Megaprojects on the Rise, Agency Guidance for CRE, and an Upbeat Forecast for Commercial Real Estate Investment

June 21, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, summer travelers seek alternative lodging options, purpose-built wellness real estate investments grow, bonds backed by CRE debt hit are hit with losses, and more!

• Across all property types, purpose-built wellness real estate investment has grown dramatically in recent years, including properties with wellness features as a focus. (Mary Salmonsen, Multifamily Dive)
• The travelers on the road this summer will have different demographics, budgets and reasons for travel and different preferences on accommodations, with more travelers opting for alternative housing options. (Noelle Mateer, Hotel Dive)
• Megaprojects are on the rise, with massive projects, from rail tunnels to computer chip factories, having myriad stakeholders and lengthy timelines that span political administrations. (Julie Strupp, Construction Dive)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Trump Administration Waives Border Wall Procurement Rules

March 23, 2020 — Mary B. Powers & Debra K. Rubin - Engineering News-Record
Acting Homeland Security Secretary Chad Wolf on Feb. 20 waived federal contracting rules to expedite construction of the U.S-Mexico border wall in California, Arizona, New Mexico and Texas, citing legal authority under several U.S. laws, some dating back to the 1990s, to deal with what he claimed is "an acute and immediate need to construct physical barriers and roads ... to prevent unlawful entries." Reprinted courtesy of Mary B. Powers, Engineering News-Record and Debra K. Rubin, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Port Authority Approves Subsidies for 2 World Trade Project

December 10, 2015 — David M. Levitt – Bloomberg
The Port Authority of New York and New Jersey approved subsidies to help expedite the construction of lower Manhattan’s 2 World Trade Center, where Rupert Murdoch’s 21st Century Fox Inc. and News Corp. companies have a tentative deal to move their headquarters from midtown. Developer Silverstein Properties Inc., which leases the sites for 2 World Trade Center and two other towers from the Port Authority, would receive a rent break that amounts to $9 million over the life of the lease, Authority Director Patrick Foye said, just before the agency board unanimously approved the proposal. Read the court decision
Read the full story...
Reprinted courtesy of David M. Levitt, Bloomberg

---

DE Confirms Robust D&O Protection Despite Company Demise

February 18, 2015 — James Yoder, Michael Onufrak and Siobhan Cole – White and Williams LLP
On Feb. 5, 2015, the United States Bankruptcy Court for the District of Delaware, per Judge Brendan L. Shannon, entered proposed findings of fact and conclusions of law in favor of the former president and CEO of Ultimate Escapes Inc., James M. Tousignant, and its chairman, Richard Keith, after determining that Tousignant’s actions in negotiating and executing a controversial asset purchase agreement were protected by the business judgment rule, despite the demise of the company a short time later. The failure of a business strategy, in and of itself, does not create liability on the part of the former directors and officers of a bankrupt company. Background Ultimate Escapes was a luxury destination club that provided its members with access to high-end vacation residences around the world. Unfortunately, Ultimate Escapes’ business suffered greatly from the economic downturn that began in 2008, and on Sept. 20, 2010, Ultimate Escapes filed voluntary petitions for relief pursuant to Chapter 11 of the Bankruptcy Code. Reprinted courtesy of White and Williams LLP attorneys James Yoder, Michael Onufrak and Siobhan Cole Mr. Yoder may be contacted at yoderj@whiteandwilliams.com Mr. Onufrak may be contacted at onufrakm@whiteandwilliams.com Ms. Cole may be contacted at coles@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Flushing Away Liability: What the Aqua Engineering Case Means for Contractors and Subcontractors

October 21, 2024 — Heather Zipperer - Colorado Construction Litigation Blog
The recent Town of Mancos v. Aqua Engineering case is an insightful example of how well written contracts and timely legal action can make all the difference in resolving disputes between municipalities, general contractors, and subcontractors. The ruling favored Aqua Engineering; a subcontractor that played a role in a wastewater treatment facility project gone wrong. The court’s decision highlighted key legal principles, including the economic loss rule and the importance of well-structured contracts in construction disputes. Whether you are a subcontractor looking to avoid undue liability or a general contractor seeking to ensure subcontractors shoulder their fair portion of responsibility, this case offers valuable lessons for all parties involved in construction projects. The Background: A Wastewater Project with Issues In 2008, the Town of Mancos, Colorado, hired Souder, Miller & Associates (“SMA”) to design a new wastewater treatment facility. SMA subcontracted Aqua Engineering to help implement a specific wastewater treatment system known as the Multi-Stage Activated Biological Process (“MSABP”). However, after construction, the facility never worked as expected. For years, the Town faced ongoing issues, and despite Aqua’s involvement in attempts to fix the problems, the facility remained dysfunctional. Read the court decision
Read the full story...
Reprinted courtesy of Higgins, Hopkins, McLain & Roswell, LLC

---

House of the Week: Spanish Dream Home on California's Riviera

July 30, 2014 — Emily Heffter – Bloomberg
Famous clients of renowned Los Angeles architect Richard Landry are not known for their restraint. The Brentwood estate he designed for Tom Brady and Gisele Bundchen has a moat and just sold to Dr. Dre for $40 million. Michael Jackson died in a home Landry designed (a rental), and he has designed luxurious mansions for Wayne Gretzky, Michael Bolton, Mark Wahlberg and Kenny G. Still, homeowner Lorna Auerbach did something unique when Landry started designing her dream home in Pacific Palisades: She flew him to Spain, with her, for 10 days. Read the court decision
Read the full story...
Reprinted courtesy of Emily Heffter, Bloomberg

---

Gaps in Insurance Created by Complex Risks

January 22, 2024 — The Hartford Staff - The Hartford Insights
From slips, trips and falls to extreme weather and cyberattacks, businesses are regularly confronted with risks to operations and profitability. In 2023, elevated building costs, increased flooding, and growing ransomware attacks made it compelling for business owners to make sure they had adequate insurance to stay ahead of property and liability exposures. However, if left unchecked, these trends can lead to gaps in coverage. As 2024 approaches, now is the time to assess your risk and collaborate with the right resources to fill any potential voids in insurance. Economic inflation for example has changed property valuations, which can result in coverage gaps if policyholders have not examined their replacement costs recently. Read the court decision
Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

---