Seattle Washington Building Expert Directory

Burlingame Construction Defect Case Heading to Trial

December 30, 2013 — CDJ STAFF
A condominium association in the Aspen, Colorado area will likely go to trial over its claims of construction defects, reports Aspen Daily News Online. According to the suit, siding and trim were improperly manufactured and installed. The homeowners engaged experts to determine the appropriate remedy, and then sought bids from contractors. Shaw Construction, which built the condos, responded with a counteroffer. Chris Rhody, the lawyer for the homeowners, said there was “a big difference” between the association’s request and the builder’s counteroffer. According to Mr. Rhody, settlement is still possible, but seems unlikely. A date for the trial is yet to be set. Read the court decision
Read the full story...
Reprinted courtesy of

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Thanks for My 6th Year Running as a Construction Litigation Super Lawyer

May 16, 2022 — Christopher G. Hill - Construction Law Musings
It is with humility and a sense of accomplishment that I announce that I have been selected for the sixth straight year to the Virginia Super Lawyers in the Construction Litigation category for 2022. Add this to my recent election to the Virginia Legal Elite in Construction and I’ve had a pretty good year. As always, I am thrilled to be included on these peer-elected lists. So without further ado, thank you to my peers and those on the panel at Virginia Super Lawyers for the great honor. I feel quite proud to be part of the 5% of Virginia attorneys that made this list for 2020. The full lists of Virginia Super Lawyers will appear in the May edition of Richmond Magazine. Please check it out. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Home Prices Up in Metro Regions

October 30, 2013 — CDJ STAFF
Housing prices in the largest metro regions beat expectations, rising 12.8% in August as compared to a year before. Analysts were expecting weaker increases; instead these have been the fastest increases in seven years. The metropolitan area with the largest increase was Las Vegas, where houses increased in price by 29.2%. Three California regions — San Francisco, Los Angeles, and San Diego — also saw increases of greater than 20%. Read the court decision
Read the full story...
Reprinted courtesy of

Sales of New U.S. Homes Fell in February to Five-Month Low

March 26, 2014 — Shobhana Chandra – Bloomberg
Purchases of new homes in the U.S. fell in February to the lowest level in five months, a sign the industry may take time to pick up after inclement weather damped demand earlier in the year. Sales declined 3.3 percent to a 440,000 annualized pace, following a 455,000 rate in the prior month that was the strongest in a year, figures from the Commerce Department showed today in Washington. The median forecast of 77 economists surveyed by Bloomberg called for 445,000. Unusually frigid temperatures added to restraints including rising mortgage rates, higher property values, and a lack of supply that kept prospective buyers away from the market for new and existing properties. Bigger gains in employment and consumer sentiment would help spur the recovery in homebuilding, sustaining its contribution to economic growth and boosting earnings at companies such as Lennar Corp. and KB Home. Read the court decision
Read the full story...
Reprinted courtesy of Shobhana Chandra, Bloomberg
Ms. Chandra may be contacted at schandra1@bloomberg.net

Chinese Telecommunications Ban to Expand to Federally Funded Contracts Effective November 12, 2020

September 21, 2020 — Lori Ann Lange & Sabah Petrov - Peckar & Abramson
In our previous alert, we discussed the Federal Government’s Ban (the “Ban”) on certain Chinese covered telecommunications and video surveillance equipment and services in federal government contracts. The ban prohibits government contractors and subcontractors from supplying to the Federal Government or using in their own internal operations certain telecommunications or video surveillance equipment or services produced by Huawei Technologies Company, ZTE Corporation, Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, and Dahua Technology Company, as well as their subsidiaries and affiliates. The Ban currently applies to companies contracting directly with the Federal Government. Soon, however, the Ban – at least in part – will expand to contractors and subcontractors who are awarded certain federally assisted contracts and subcontracts. On August 13, 2020, the Office of Management and Budget (“OMB”) published Final Guidance revising its grants and agreements regulations (2 CFR Part 200) to prohibit recipients and subrecipients from using loan or grant funds to purchase or obtain covered telecommunications and video surveillance equipment or services. Effective November 12, 2020, recipients and subrecipients are prohibited from obligating or expending loan or grant funds to:

Procure or obtain;
Extend or renew a contract to procure or obtain; or
Enter into a contract (or extend or renew a contract) to procure or obtain equipment, services, or systems that use covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

Reprinted courtesy of Lori Ann Lange, Peckar & Abramson and Sabah Petrov, Peckar & Abramson Ms. Lange may be contacted at llange@pecklaw.com Ms. Petrov may be contacted at spetrov@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Additional Insured Coverage Confirmed

February 23, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Texas Court of Appeals found that Exxon Mobil Corporation was an additional insured under the CGL policy for Exxon's service provider. Liberty Surplus Ins. Corp. v. Exxon Mobil Corporation, 2015 Tex. App. LEXIS 12757 (Tex. Ct. App. Dec. 17, 2015). Exxon contracted with Wyatt Field Service Company to perform "services" as set forth in various work orders from Exxon's affiliates. The contract also required Wyatt to maintain $5 million of commercial general liability insurance. The contract provided that the policies must cover Exxon and its affiliates "as additional insureds in connection with the performance of Services." In 2008, Wyatt was assigned to work on a flexicoker unit at Exxon's refinery. Wyatt was to reinstall dummy nozzles and chains. It completed this service in October 2008. Three years later, one of the dummy nozzles pulled free, and the escaping steam and coke burned three individuals who were working on the unit. After the accident, it was discovered that the safety chain had been installed in the wrong location so that it did not properly secure the dummy nozzle. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Insurance Company Must Show that Lead Came from Building Materials

August 17, 2011 — CDJ STAFF

The Fourth Circuit Court of Appeals for Louisiana has reversed the summary judgment of a lower court in the case of Widder v. Louisiana Citizens Property Insurance Company. Judge Roland L. Belsome wrote the opinion for the panel of three judges. Ms. Widder discovered that her home and its content were contaminated by lead. She applied to her insurer, Louisiana Citizens Property Insurance, which denied her claim.

In response to Ms. Widder’s suit, LCPIC applied for a summary judgment on the grounds that there was no physical loss and that the policy did not cover defective material, latents defects, and pollution damage.

The appeals court found that the lead contamination of Widder’s home did meet the standards of a direct physical loss, citing a recent Chinese Drywall case. There, it was found, “when a home has been rendered unusable or uninhabitable, physical damage is not necessary.”

The lower court addressed only one of LCPIC’s exclusions, addressing only the exclusion on basis of “faulty, inadequate or defective material.” The appeals court noted that the evidence offered at trial does not show that the building materials were the source of the lead. This provided the appeals court with a matter of fact to remand to the lower court.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES