Cambridge Massachusetts Building Expert Directory

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

When an Intentional Act Results in Injury or Damage, it is not an Accident within the Meaning of an Insurance Policy Even When the Insured did not Intend to Cause the Injury or Damage

June 06, 2022 — Gary L. LaHendro - Haight Brown & Bonesteel LLP
In Maryam Ghukasian v. Aegis Security Insurance Company (No. B311310, filed April 14, 2022, and certified for publication on May 5, 2022), the Court of Appeal of the State of California, Second Appellate District held that Maryam Ghukasian’s insurer, Aegis Security Insurance Company (“Aegis”), had no duty to defend her in an underlying lawsuit alleging she cleared land and cut trees on her neighbors’ property without their consent. The appellate court explained Ms. Ghukasian’s acts of intentionally cutting the trees and clearing the land were not accidental for purposes of insurance coverage, even if she acted on the good faith but mistaken belief the trees were on her property. Ms. Ghukasian owns a home in Glendale, California. She purchased a homeowner’s insurance policy from Aegis for the policy period of June 13, 2018 to June 13, 2019 (the “Aegis Policy”). In August 2018, Ms. Ghukasian hired a contractor to clear and cut trees she believed were on her property. However, the trees were on the property of her neighbors, Vrej and George Aintablian. Read the court decision
Read the full story...
Reprinted courtesy of Gary L. LaHendro, Haight Brown & Bonesteel LLP
Mr. LaHendro may be contacted at glahendro@hbblaw.com

Badly Constructed Masonry Walls Not an Occurrence in Arkansas Law

May 10, 2012 — CDJ STAFF

The US District Court for Maryland has granted a summary judgment in the case Konover Construction Corp. v. ATC Associates to Massachusetts Bay Insurance Company and denied a request for dismissal from ACT. Konover (KBE) was contracted by Wal-Mart to build a Wal-Mart store and a Sam’s Club in Port Covington, Maryland. Superus, Inc. was hired by KBE to build the masonry walls. Superus purchased a policy from Massachusetts Bay Insurance which named KBE as an additional insured. Wal-Mart hired ATC Associates to independently test and inspect the concrete structural steel, and masonry.

After the building was in use, a large crack appeared which was attributed a latent construction defect. Other cracks were discovered. Upon investigation, it was discovered that there were “voids or foam in the concrete block surrounding the reinforcing steel that should have been filled with grout,” and in some cases, “reinforcing steel was missing or not installed in accordance with the specifications.” KBE paid for the repair and remediation and Wal-Mart assigned all rights and interests against ATC to KBE.

KBE filed suit against ATC. ATC called for dismissal on the grounds that Wal-Mart had no claims as the problems had been remediated. Wal-Mart then provided KBE with additional agreements to give them enforceable rights against ATC and Superus. KBE filed a fourteen claims against ATC, Superus, and Massachusetts Bay. In the current case, Massachusetts Bay sought summary judgment and ATC sought dismissal of all claims against it.

Massachusetts Bay claims that they need not indemnify Superus, as “there is no evidence adequate to establish that Superus’ defective work caused any collateral and/or resulting damage that was not subject to an Impaired Property exclusion, and that, in any event, no damage occurred during the policy period.”

As Wal-Mart is headquarted in Arkansas, certain contracts were under Arkansas law. Under the Arkansas courts, “defective workmanship, standing alone and resulting in damages only to the work product itself, is not an ‘occurrence.’” The court determined that collateral or resultant damage would be covered. The court found that “it is clear under Arkansas law, and the parties appear to agree, that Massachusetts Bay is not obligated to indemnify KBE for any repairs to the masonry walls themselves, including any cracks or gaps in the walls.” The court also found that “there is no evidence adequate to prove that any allegedly resultant property damage was caused by Superus’ faulty construction of the walls.” The court also noted that “if the building code violation and structural integrity problem were ‘property damage,’ insurance coverage would be barred by the Impaired Property Exclusion.” Based on these findings, the court concluded that Massachusetts Bay is entitled to summary judgment.

While the court dismissed the case against Massachusetts Bay, the court declined ATC’s motion to dismiss. The court noted that ACT’s alleged negligence in conducting inspections “created only a risk of economic loss for KBE.” Although hired by Wal-Mart, ATC “transmitted its daily testing and inspection reports of the Wal-Mart and Sam’s Club projects directly to KBE.” The court found that “KBE has made a plausible claim.”

ATC also claimed that KBE contributed to the negligence due to the negligence of its subcontractor. The court concluded that it was plausible that “ATC will not be able to carry its burden of proving KBE was contributorily negligent.” The court was less sanguine about KBE’s fraud claim, but though it “may not now appear likely to have merit, it is above the ‘plausibility’ line.”

In conclusion, KBE may not continue its case against Massachusetts Bay. However, the judge allowed the other proceedings to continue.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

Owners and Contractors are Liable for Injuries Caused by their Independent Contractors under the “Peculiar Risk Doctrine”

October 15, 2024 — William L. Porter - Porter Law Group
Many contractors and owners believe that if they hire an independent contractor to perform work and that independent contractor causes injury to others during the performance of that work, then it is the independent contractor alone who will be liable for those injuries. In most circumstances, this is correct. The owner or the contractor will not be held liable for injuries caused by his or her independent contractor. However, this is not always the case. Under the “Peculiar Risk Doctrine” and California cases interpreting the doctrine, a contractor or owner who hires an independent contractor to do work which is considered to be “inherently dangerous work” can be still be held directly liable for damages when that independent contractor causes injury to others by negligently performing the work. Such liability can generally be imposed on the one hiring the independent contractor under either of two branches of the peculiar risk doctrine. First, where a person hires an independent contractor to do inherently dangerous work, but fails to provide in the contract or in some other manner that special precautions must be taken to avert the peculiar risk of injury related to that work, then the one hiring the independent contractor can be held liable for injuries to others caused by the independent contractor’s negligence. (Restatement Second of Torts Section 413). For example, in Mackey v. Campbell Construction Co. 101 Cal. App. 3d 774, 162 Cal. Rptr. 64 (1980), Western Electric Company, the owner of the project, was found liable for the personal injuries of a subcontractor’s employee because Western’s representatives were on the job at all times, had doubts about the safety of scaffolding being used on the project, yet failed to require use of precautions that could have been taken to avoid injury. Read the court decision
Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

Commercial Construction Heating Up

November 20, 2013 — CDJ STAFF
The Motley Fool suggests that commercial construction is the next hot sector. Their analysis is that lag time between a rise in residential construction and commercial construction is just about over. “Industry surveys and construction data are suggestion that commercial construction could be about to turn.” Among the indicators are increased billing by architects for commercial projects. With the exception of December 2012, with a strong slump in residential work, commercial projects lagged below residential projects from June 2012 until June 2013. Read the court decision
Read the full story...
Reprinted courtesy of

2019 Promotions - New Partners at Haight

January 15, 2019 — Haight Brown & Bonesteel LLP
Haight proudly announces the promotion of Renata Hoddinott, Sarah Marsey and Annette Mijianovic to Partner in January 2019. Renata and Sarah joined Haight’s San Francisco office in 2016. Renata relocated from a litigation firm in the Los Angeles area. She focuses her practice on professional liability, general liability, risk management & insurance law and transportation law. Before coming to Haight, Sarah was with a respected trial firm in Anchorage, Alaska. She handles a variety of complex matters in appellate law, food safety, construction law and general liability. Annette has been with Haight’s Los Angeles office for almost 12 years. Annette joined the firm as a summer clerk in 2007 and has continued to build her practice handling cases related to commercial litigation, products liability and transportation law. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys Renata L. Hoddinott, Sarah A. Marsey and Annette F. Mijanovic Ms. Hoddinott may be contacted at rhoddinott@hbblaw.com Ms. Marsey may be contacted at smarsey@hbblaw.com Ms. Mijanovic may be contacted at amijanovic@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Under the Hood of U.S. Construction Spending Is Revised Data

January 06, 2016 — Vince Golle – Bloomberg
Here’s one key takeaway from the Commerce Department’s report Monday on U.S. construction spending. The 0.4 percent decrease in November, which itself was weaker than the most pessimistic Bloomberg survey forecast, was accompanied by downward revisions to prior months. The combination suggests some economists may revise down their fourth-quarter GDP tracking forecasts. * October construction spending rose 0.3 percent, compared with a prior estimate of 1 percent, while September outlays advanced 0.2 percent versus a previous estimate of a 0.6 percent gain Read the court decision
Read the full story...
Reprinted courtesy of Vince Golle, Bloomberg

New Becker & Poliakoff Attorney to Expand Morristown Construction Litigation Practice

September 10, 2014 — Beverley BevenFlorez-CDJ STAFF
According to New Jersey On-Line, Matthew Meyers has joined the Becker & Poliakoff firm at its Morristown office. Meyers “specializes in commercial litigation, with an emphasis on complex construction defects and real estate disputes.” “This is an exciting move for me,” Meyers stated, as quoted by New Jersey On-Line. “I was attracted to Becker by the firm’s depth of construction litigation talent and the additional resources available for these claims. My new firm will not only enhance my practice but will elevate the level of services I provide to clients, which has always been my top priority.“ Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES