SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

New Case Alert: California Federal Court Allows Policy Stacking to Cover Continuous Injury

November 23, 2016 — William S. Bennett - Saxe Doernberger & Vita, P.C.
“Stacking” is a practice that is very favorable for policyholders, especially in environmental coverage cases involving extended pollution events. It allows a policyholder to combine the limits of multiple consecutive policies to cover continuous injury claims occurring over multiple policy periods. Without stacking, insurers can limit a policyholder’s recovery to a single policy limit. The Eastern District of California recently decided that a policyholder could stack the limits of six consecutive policies, where the occurrence was a continuous injury spanning all six policy years. Among other rulings, the court determined that the plain language of the policy under dispute did not prevent stacking. Read the court decision
Read the full story...
Reprinted courtesy of William S. Bennett, Saxe Doernberger & Vita, P.C.
Mr. Bennett may be contacted at wsb@sdvlaw.com

---

Eminent Domain Bomb Threats Made on $775M Alabama Highway Project

July 03, 2022 — Derek Lacey - Engineering News-Record
Multiple bomb threats have been made against Alabama transportation officials, law enforcement and others in reaction to eminent domain plans for a major highway expansion project. Reprinted courtesy of Derek Lacey, Engineering News-Record Mr. Lacey may be contacted at laceyd@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

How the Cumulative Impact Theory has been Defined

November 30, 2020 — David Adelstein - Florida Construction Legal Updates
Largely in the federal contract arena, there is a theory referred to as “cumulative impacts” used by a contractor to recover unforeseeable costs associated with a multitude of changes that have an overwhelming ripple effect on its efficiency, particularly efficiency dealing with its original, base contract work. In other words, by dealing with extensive changes, there is an unforeseeable impact imposed on the contractor relative to its unchanged or base contract work. Under this theory, the contractor oftentimes prices its cumulative impact under a total cost approach with an examination on its cost overrun. However, this is not an easy theory to prevail on because there needs to be a focus on the sheer number of changes, causation supporting the impact, and whether there were concurrent impacts or delays that played a role in the ripple effect. See, e.g., Appeals of J.A. Jones Const. Co., ENGBCA No. 6348, 00-2 BCA P 31000 (July 7, 2000) (“However, in the vast majority of cases such claims are routinely denied because there were an insufficient number of changes, contractor-caused concurrent delays, disruptions and inefficiencies and/or a general absence of evidence of causation and impact.”). To best articulate how the cumulative impact theory has been defined, I want to include language directly from courts and board of contract appeals that have dealt with this theory. This way the contractor knows how to best work with their experts with this definition in mind–and, yes, experts will be needed–to persuasively package and establish causation and damages stemming from the multitude of changes. While many of these definitions are worded differently, you will see they have the same focus dealing with the unforeseeable ripple effect of the extensive changes. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Traub Lieberman Attorneys Named 2019 Super Lawyers

November 04, 2019 — Traub Lieberman
Related Attorneys: Jonathan R. Harwood, Michael K. Kiernan, Michael S. Knippen, Meryl R. Lieberman, Christopher Russo, Scot E. Samis, Lisa L. Shrewsberry, Stephen D. Straus, Richard K. Traub, Cheryl P. Vollweiler, Brian C. Bassett, Jessica N. Kull, Jeremy S. Macklin, Dana A. Rice, Burks A. Smith, III, Jason Taylor Ten Traub Lieberman attorneys have been named 2019 Super Lawyers and seven named 2019 Rising Stars. The honored attorneys represent five of the firm's seven offices and nearly all of its service areas. Super Lawyers, a Thomson Reuters business, is a rating service of outstanding lawyers from more than 70 practice areas, who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a patented multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates and peer reviews by practice area. Read the court decision
Read the full story...
Reprinted courtesy of

---

SCOTUS to Weigh Landowners' Damage Claim Against Texas DOT

November 13, 2023 — Mary B. Powers - Engineering News-Record
The U.S. Supreme Court has agreed to hear a case this term that could affect whether states must pay compensation to landowners whose property was damaged by public project execution. Payments also could extend to state owned utilities and others. Reprinted courtesy of Mary B. Powers, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Personal Thoughts on Construction Mediation

September 20, 2021 — Christopher G. Hill - Construction Law Musings
Construction Mediation WorksAs I left a mediation last week at 8:30 at night, I realized something that I knew all along. Mediation works. Why does mediation work? For several reasons that I can think of. The first, and likely most important is that lawyers are expensive. In most construction cases, we charge by the hour and those hours build up, especially close to a trial date. A mediated settlement can avoid this sharp uptick in attorney fees that always occurs in the last month before trial. Therefore the earlier the better. The second is the flexibility to make a business decision. Commercial contractors and subcontractors are in a business, and they should be making business decisions. While one such decision can be to go to litigation; litigation is not always the best solution from a financial, or stress perspective. Construction professionals, with the assistance of construction attorneys, can come up with a creative way to deal with a problem and solve it. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

What Buyers Want in a Green Home—and What They Don’t

March 19, 2014 — Beverley BevenFlorez-CDJ STAFF
Jennifer Goodman interviewed researcher Suzanne Shelton to find out what buyers want in a green home and what they do not. The questions and answers were published in Big Builder. Shelton has studied “Americans’ thoughts on environmental and energy issues” for the last ten years. Goodman wrote that while the term “high-performance” is often used by “builders and their advisors,” the term doesn’t resonate with buyers. In fact, in last fall’s Energy Pulse study, eighty-four percent of Americans said no when asked “if they could confidently and correctly explain the term ‘high-performance home’ to a friend.” Goodman and Shelton also discussed the best way to market green features. Shelton pointed out that in surveys “energy-efficient home… clobbered ‘green home’ year over year.” Furthermore, she found that “80 percent of prospective home buyers tell us…all other things being equal, energy efficiency would impact their home selection.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Badly Constructed Masonry Walls Not an Occurrence in Arkansas Law

May 10, 2012 — CDJ STAFF

The US District Court for Maryland has granted a summary judgment in the case Konover Construction Corp. v. ATC Associates to Massachusetts Bay Insurance Company and denied a request for dismissal from ACT. Konover (KBE) was contracted by Wal-Mart to build a Wal-Mart store and a Sam’s Club in Port Covington, Maryland. Superus, Inc. was hired by KBE to build the masonry walls. Superus purchased a policy from Massachusetts Bay Insurance which named KBE as an additional insured. Wal-Mart hired ATC Associates to independently test and inspect the concrete structural steel, and masonry.



After the building was in use, a large crack appeared which was attributed a latent construction defect. Other cracks were discovered. Upon investigation, it was discovered that there were “voids or foam in the concrete block surrounding the reinforcing steel that should have been filled with grout,” and in some cases, “reinforcing steel was missing or not installed in accordance with the specifications.” KBE paid for the repair and remediation and Wal-Mart assigned all rights and interests against ATC to KBE.



KBE filed suit against ATC. ATC called for dismissal on the grounds that Wal-Mart had no claims as the problems had been remediated. Wal-Mart then provided KBE with additional agreements to give them enforceable rights against ATC and Superus. KBE filed a fourteen claims against ATC, Superus, and Massachusetts Bay. In the current case, Massachusetts Bay sought summary judgment and ATC sought dismissal of all claims against it.



Massachusetts Bay claims that they need not indemnify Superus, as “there is no evidence adequate to establish that Superus’ defective work caused any collateral and/or resulting damage that was not subject to an Impaired Property exclusion, and that, in any event, no damage occurred during the policy period.”



As Wal-Mart is headquarted in Arkansas, certain contracts were under Arkansas law. Under the Arkansas courts, “defective workmanship, standing alone and resulting in damages only to the work product itself, is not an ‘occurrence.’” The court determined that collateral or resultant damage would be covered. The court found that “it is clear under Arkansas law, and the parties appear to agree, that Massachusetts Bay is not obligated to indemnify KBE for any repairs to the masonry walls themselves, including any cracks or gaps in the walls.” The court also found that “there is no evidence adequate to prove that any allegedly resultant property damage was caused by Superus’ faulty construction of the walls.” The court also noted that “if the building code violation and structural integrity problem were ‘property damage,’ insurance coverage would be barred by the Impaired Property Exclusion.” Based on these findings, the court concluded that Massachusetts Bay is entitled to summary judgment.



While the court dismissed the case against Massachusetts Bay, the court declined ATC’s motion to dismiss. The court noted that ACT’s alleged negligence in conducting inspections “created only a risk of economic loss for KBE.” Although hired by Wal-Mart, ATC “transmitted its daily testing and inspection reports of the Wal-Mart and Sam’s Club projects directly to KBE.” The court found that “KBE has made a plausible claim.”



ATC also claimed that KBE contributed to the negligence due to the negligence of its subcontractor. The court concluded that it was plausible that “ATC will not be able to carry its burden of proving KBE was contributorily negligent.” The court was less sanguine about KBE’s fraud claim, but though it “may not now appear likely to have merit, it is above the ‘plausibility’ line.”



In conclusion, KBE may not continue its case against Massachusetts Bay. However, the judge allowed the other proceedings to continue.



Read the court’s decision…

 Read the court decision
Read the full story...
Reprinted courtesy of

---