Fairfield Connecticut Building Expert Directory

Allegations Confirm Duty to Defend Construction Defect Claims

June 11, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Relying upon the same case cited by the Hawaii Supreme Court in its seminal decision on duty to defend, the federal district court determined the allegations sufficiently established a duty to defend construction defect claims. Voeller Constr. v. Southern-Owners Ins. Co., 2014 U.S. Dist. LEXIS 61862 (M. D. Fla. May 5, 2014). The Bay Harbor Clearwater Condominium Association, Inc. sued Voeller Construction for statutory breach of warranty and building code violations which allegedly caused damage to the condominium structure. The complaint alleged that the damage was unknown to the unit owners at the time they purchased their units. The project was completed in 2007. Expert reports attached to the complaint listed July 7, 2010, as the earliest date of discovery of the damage to the property. The CGL policies were effective from January 24, 2007 to May 9, 2009. Therefore, the insurer argued there was no coverage because the alleged "property damage" was discovered for more than one year after the policies expired. The court determined there was a duty to defend. Citing Trizec Props., Inc. v. Biltmore Constr. Co., 767 F.2d 810 (11th Cir. 1985), the court noted that if the complaint alleged facts which created potential coverage under the policy, the duty to defend was triggered. The Hawaii Supreme Court relied on Trizec and made the same ruling in Dairy Road Partners v. Island Ins Co., Ltd., 92 Haw. 398, 412, 992 P.2d 93, 107 (2000). Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Nerves of Steel Needed as Firms Face Volatile Prices, Broken Contracts and Price-Gouging

December 06, 2021 — Richard Korman, Jonathan Barnes, & Greg Aragon - Engineering News-Record
When Elmhurst Group, a Pittsburgh-area developer, started collecting bids for a new mixed-use building last November, the price of the steel frame, roof and cladding panels for the $14-million project came in $382,000 higher than expected—a big enough disappointment to give Elmhurst pause. Overall material costs for the project were running more than $650,000 above what was originally calculated. Reprinted courtesy of Richard Korman, Engineering News-Record, Jonathan Barnes, Engineering News-Record and Greg Aragon, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

No Coverage for Construction Defect Claim Only Impacting Insured's Work

January 08, 2024 — Tred R. Eyerly - Insurance Law Hawaii
In a coverage dispute between two insurers over a claim for damages caused by faulty workmanship, the court found there was no right to equitable contribution or indemnity. Travelers Prop. Cas. Co. of Am. v. Mallcraft, Inc., 2023 Cal. Super. LEXIS 67568 (Cal. Super. Ct. Sept. 15, 2023). Mallcraft was the general contractor for a building project and was sued for construction defects. Travelers was an additional insured under a policy issued to a subcontractor, KitCor. Travelers defended Mallcraft in an arbitration. Travelers sought equitable contribution and equitable indemnity from Hartford, Mallcraft's insurer. Mallcraft and Travelers stiulated to a judgment agianst Mallcraft for all costs Travelers incurred in the arbitration. Travelers' insured, KitCor, was not implicated in the construction defect claims against Mallcraft. The judgment set forth findings, including the fact that the underlying plaintiff never made any claim that KitCor perfomred work on the project or casued property damage. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

This Times Square Makeover Is Not a Tourist Attraction

July 28, 2016 — Alisa Zevin - Engineering News-Record
The 80-year-old Bow Tie Building in the heart of New York City’s Times Square is undergoing a major renovation of retail space, but the tens of thousands of daily passersby will not see any construction activities: A 53-ft-tall dark-green plywood wall completely hides the 167,000-sq-ft structure. Read the court decision
Read the full story...
Reprinted courtesy of Alisa Zevin, Engineering News-Record
Ms. Zevin may be contacted at zevina@enr.com

Anti-Concurrent, Anti-Sequential Causation Clause Precludes Coverage

February 26, 2015 — Tred R. Eyerly – Insurance Law Hawaii
Where the building was damaged by both a covered cause and a non-covered cause, the policy's anti-concurrent/anti-sequential causation clause barred coverage for a collapsed building. Ashrit Realty LLC v. Tower Nat'l Ins. Co., 2015 N.J. Super. Unpub. LEXIS 107 (N.J. Super. Ct. App. Div. Jan. 20, 2015). The property sustained moderate damage during a storm on August 14, 2011. More extensive damage was caused by Hurricane Irene two weeks later. After the hurricane, a large hole formed due to the collapse of a pipe which ran underneath the property. Once the pipe collapsed, leaking water caused substantial soil erosion, which led to the collapse of the rear portion of the building. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Quick Note: COVID-19 Claim – Proving Causation

August 03, 2020 — David Adelstein - Florida Construction Legal Updates
In certain jurisdictions, the number of people testing positive for COVID-19 is on the rise. As this occurs, there is the possibility that a construction project will have to deal with one or more workers testing positive. That is the current reality. If the dialogue has not occurred before, now is the time to discuss any enhanced measures—above OSHA guidelines—that could be implemented to address this reality and mitigate the risk. Part of the reality, though, is that regardless of the enhanced measures and mitigation, it is impossible to truly prevent this risk. No one disputes COVID-19. There may be a dispute as to whether COVID-19 constitutes a force majeure event or some other event, however, before you start labeling it, you still NEED TO PROVE the impact caused by COVID-19. There needs to be a cause-and-effect relationship so you can address (i) how this impacted the critical path of your schedule and/or (ii) how this impacted labor productivity. In other words, you need to prove causation. Stating there was a delay or loss of productivity without establishing the cause-and-effect relationship (i.e, causation) provides no value because it does not support the production impact or time extension and, without either, there is no basis for additional compensation (even if you establish it should be deemed an excusable, compensable delay). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Just How Climate-Friendly Are Timber Buildings? It’s Complicated

February 12, 2024 — Eric Roston - Bloomberg
This article is part of the Bloomberg Green series Timber Town, which looks at the global rise of timber as a low-carbon building material. The number of people living in urban areas around the world will swell by upwards of 2 billion over the next three decades. Many of those people will need new homes. But building those with conventional materials would unleash a gusher of carbon dioxide: Concrete, steel, glass and bricks for construction make up a combined 9% of global CO2 emissions, according to research by the United Nations Environment Program. Enter engineered wood, a seemingly no-brainer solution. Mass timber is not the typical lumber that has structured single-family houses in North America for decades. The wood components are strong enough to hold up an office tower or apartment block, and building with them is thought to emit much less CO2 than using standard materials. And since wood is about 50% carbon, the material itself even stores a little carbon, to boot. Read the court decision
Read the full story...
Reprinted courtesy of Eric Roston, Bloomberg

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES