Seattle Washington Building Expert Directory

Attorneys' Fees Awarded as Part of "Damages Because of Property Damage"

October 07, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court for the district of Hawaii found that an arbitrator's award of attorneys' fees was part of the "damages because of property damage" and covered under a CGL policy. Ass'n of Apt. Owners of the Moorings v. Dongbu Ins. Co., 2016 U.S. Dist. LEXIS 110283 (Aug. 18, 2016 D. Haw). The Moorings AOAO was the named insured under the policy issued by Dongbu. Jo-Anne and Brent Braden, owners of a residential unit at the Moorings, filed a demand for arbitration against the AOAO. The Bradens alleged that the AOAO had failed to repair and maintain their lanai roof, which caused water damage to their unit. The arbitrator awarded the Bradens $6,103.49 in special damages, which was the amount they paid to repair their roof and interior damage. The arbitrator also awarded $85,644.30 in attorneys' fees and $8,515.91 in costs to the Bradens. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Review your Additional Insured Endorsement

March 26, 2014 — Beverley BevenFlorez-CDJ STAFF
In his blog, Construction Contractor Advisor, Craig Martin explained the importance of reviewing your additional insured endorsement. Martin pointed out that in Mississippi, the “Fifth Circuit Court of Appeals recently ruled in Woodward, LLC v. Acceptance Indemnity Insurance Company, that a general contractor, named as an additional insured, did not have coverage for claims that a subcontractor performed faulty work.” The problem “was the language in the additional insured endorsement, which provided coverage for ongoing operations, not completed operations.” While Martin admitted that the case applies to Mississippi, he concluded that “the issue Midwestern readers should consider is the court’s conclusion that non-conformance with the plans, in essence a construction defect claim, arises from completed operations.” Read the court decision
Read the full story...
Reprinted courtesy of

Local Government’s Claims on Developer Bonds Dismissed for Failure to Pursue Administrative Remedies

March 22, 2017 — David R. Cook - Autry, Hanrahan, Hall & Cook, LLP
The Georgia Court of Appeals recently affirmed a trial court’s dismissal of a county’s claim on developer bonds based on its failure to exhaust administrative remedies. Douglas County v. Hamilton State Bank, — Ga. App. –, A16A1708 (Mar. 16, 2017). Specifically, because the bank was under FDIC receivership, the County was required to pursue administrative remedies under the Financial Institutions Reform, Recovery, and Enforcement Act of 1989 (the “Act”). Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

CSLB Reminds California Public Works Contractors to Renew Their Public Works Registration

October 02, 2015 — Garret Murai – California Construction Law Blog
A friendly reminder from the Contractors State License Board . . . CSLB Urges Public Works Contractors to Renew Dept. of Industrial Relations Registration before October 1 to Avoid Hefty Penalty SACRAMENTO — A mandatory renewal deadline is approaching for licensees who work on public works projects. Contractors whose registration with the California Department of Industrial Relations (DIR) expired June 30, 2015, and have ongoing public works projects or plan to bid on new ones, must pay the $300 renewal fee before October 1, 2015, or face an additional $2,000 late penalty after that date. As a result of Senate Bill (SB) 854, all contractors have been required since April 1, 2015, to register with DIR to be awarded a public works contract, even if the project did not go out to bid. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Long-Planned Miami Mega Mixed-Use Development Nears Initial Debut

September 25, 2018 — Jim Parsons - Engineering News-Record
Economic crises, lawsuits and other complications have thrown multiple wrenches into plans for downtown Miami’s massive Worldcenter mixed-use project over the past 12 years. But to hear the master development group’s managing principal Nitin Motwani tell it, the timing for the $2-billion “city within a city” to finally come to fruition couldn’t be better. Read the court decision
Read the full story...
Reprinted courtesy of Jim Parsons, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Resulting Loss Provision Does Not Salvage Coverage

April 06, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The court confirmed that there was no coverage for damage to the policyholder's building caused by a large volume of water. Praetorian Ins. Co. v. Arabia Shrine Ctr. Houston, 2016 U.S. Dist. LEXIS 20186 (S.D. Texas Feb. 19, 2016). The damage occurred when water began seeping through the baseboards of the Shrine. Employees saw a large amount of water entering the building. Eventually, the city shut off a water main valve. It was later determined that an 8 inch diameter fire suppression metal pipe failed at the elbow, causing over one million gallons of water to be released into the building. Damages were estimated at nearly $1.7 million. Clean up and repair costs amounted to $237,156. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Supreme Court Opens Door for Challenges to Older Federal Regulations

August 05, 2024 — Jane C. Luxton - Lewis Brisbois
Washington, D.C. (July 1, 2024) – On July 1, 2024, the U.S. Supreme Court issued another end-of-term major decision limiting the scope of federal agency actions in Corner Post, Inc. v. Board of Governors of the Federal Reserve System. Adding to the tectonic shift in the regulatory landscape created by the Court’s June 27 and 28 rulings constraining the role of administrative law judges and overturning longstanding “Chevron deference” by courts to federal agency expertise, the decision in Corner Post establishes a newly expanded time frame for affected entities to challenge final agency action. Instead of confirming that final agency action is subject to a default six-year statute of limitations, the Court held that under the Administrative Procedure Act (APA), the time limit for appeal begins to run when a plaintiff is injured by the agency's action, not when the action becomes final. This decision has important implications for businesses and others affected by federal regulations. The case arose when Corner Post, a truck stop and convenience store in North Dakota that opened in 2018, challenged a 2011 Federal Reserve Board regulation (Regulation II) that set maximum interchange fees for debit card transactions. Corner Post filed suit in 2021, arguing that Regulation II allowed higher fees than permitted by statute. The lower courts dismissed the suit as time-barred under 28 U.S.C. § 2401(a), which effectively requires APA claims to be filed "within six years after the right of action first accrues." Read the court decision
Read the full story...
Reprinted courtesy of Jane C. Luxton, Lewis Brisbois
Ms. Luxton may be contacted at Jane.Luxton@lewisbrisbois.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES