Presenting a “Total Time” Delay Claim Is Not Sufficient
September 12, 2022 —
David Adelstein - Florida Construction Legal UpdatesWhen presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss.
In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Contractor Removed from Site for Lack of Insurance
October 28, 2011 —
CDJ STAFFThe MetroWest Daily News reports that a demolition firm was told to leave the construction site at Natick High School since their failure to have workers compensation insurance makes them unable to work on the project. The contractor, Atlantic Dismantling and Site Construction, Inc. may have been working illegally since September.
The equipment that Atlantic had rented for the job was repossessed in August. Brait Builders Corp, the general contractor for the site had rented equipment so Atlantic could continue their work.
Their lack of insurance was discovered when a worker had a minor job-related injury. The state had issued a stop-work order for the firm and they could not legally bid on public projects. The school system did not receive any notice of this, and the school’s facilities director said of the general contractor, “chances are Brait never heard of anything either.”
Read the full story...
Read the court decisionRead the full story...Reprinted courtesy of
The Prompt Payment Rollercoaster
February 23, 2016 —
Garret Murai – California Construction Law BlogThis past year we
wrote about a case involving California’s prompt payment laws and the current state of confusion with the prompt payment statutes which are
scattered throughout the state Code and which are inconsistent in the use of their terminology and, thus importantly, application.
In
United Riggers & Erectors, Inc. v. Coast Iron & Steel Co., California Court of Appeals for the Second District, Case No. B258860 (December 18, 2015), the Court of Appeals for the Second District addressed whether under one of the prompt payment statutes, Civil Code section 8814, a general contractor may withhold retention without being subject to prompt payment penalties if there is a dispute of any kind between the general contractor and the subcontractor, or only when the dispute relates to the retention itself.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
Affordable Housing should not be Filled with Defects
November 26, 2014 —
Jesse Howard Witt – Acerbic WittPrime Time for Condos: Today’s Denver Business Journal presents a feature on Colorado’s hot market for condominiums and other forms of affordable housing. In several stories, reporter Molly Armbrister discusses how high demand for apartments and low construction of new condominium projects have put a premium on existing property.
Addressing the argument that lawsuits have made builders reluctant to develop multifamily housing, she quotes The Witt Law Firm’s Jesse Witt, who said that both homeowner and builder advocates would like to see changes to Colorado’s existing statutes. Current laws do little to prevent defective work and often leave consumers no choice but to pursue claims in court or binding arbitration if they want a builder to correct code violations and other mistakes.
Read the court decisionRead the full story...Reprinted courtesy of
Jesse Howard Witt, The Witt Law FirmMr. Witt welcomes comments at www.wittlawfirm.net
“Slow and Steady Doesn’t Always Win the Race” – Applicability of a Statute of Repose on Indemnity/Contribution Claims in New Hampshire
November 24, 2019 —
Rahul Gogineni - The Subrogation StrategistIn Rankin v. South Street Downtown Holdings, Inc., 2019 N.H. LEXIS 165, the Supreme Court of New Hampshire considered, pursuant to a question transferred by the trial court, whether RSA 508:4-b, the statute of repose for improvements to real property, applies to indemnity and contribution claims. The court concluded that based upon the plain reading of the statute, it applies to indemnity and contribution claims. As noted by the court, a holding to the contrary would violate the intent of a statute of repose, which is to establish a time limit for when a party is exposed to liability.
In Rankin, after falling and injuring himself while leaving a building, John Rankin and his wife brought an action against the property owner, South Street Downtown Holding, Inc. (South Street) in 2017. South Street subsequently filed a third-party complaint against multiple parties including an architectural company, Wagner Hodgson, Inc. (Wagner), who was involved in a renovation project at the property. The project was substantially complete in 2009. Wagner responded by moving to dismiss the action, arguing that South Street’s indemnification and contribution claims were barred by the applicable statute of repose.
RSA 508:4-b specifically states,
Except as otherwise provided in this section, all actions to recover damages for injury to property, injury to the person, wrongful death or economic loss arising out of any deficiency in the creation of an improvement to real property, including without limitation the design, labor, materials, engineering, planning, surveying, construction, observation, supervision or inspection of that improvement, shall be brought within 8 years from the date of substantial completion of the improvement, and not thereafter. (Emphasis added).
Read the court decisionRead the full story...Reprinted courtesy of
Rahul Gogineni, White and Williams LLPMr. Gogineni may be contacted at
goginenir@whiteandwilliams.com
“Bee” Careful: Unique Considerations When Negotiating a Bee Storage Lease Agreement
March 27, 2019 —
Colton Addy - Snell & Wilmer Real Estate Litigation BlogAs demand for commercial bees used to pollinate crops (such as almond trees) has grown, so has the demand for facilities to store bees. Entering a lease agreement for the storage of live bees presents some unique issues the parties need to consider when negotiating the lease agreement.
Don’t Bee Short-Sighted: Bees are often transported to different areas depending on the time of year, which means bees are not stored in the same facility all year. The lease agreement will often only provide for the storage of bees during the season when the bees are used for pollination in that particular area, but that does not mean the parties must limit the term of the lease agreement to a single season. The parties may consider entering into a lease agreement for multiple years that only applies during the pollination season each year.
Bee Mindful of the Rent: Whereas the parties usually base rent in a typical commercial lease agreement off of the square footage of space the tenant uses in the premises, it often makes more sense for both parties negotiating a lease for the storage of bees to base the rent on the number of beehives or bee colony boxes stored at the facility. Basing the rent on the number of beehives or bee colony boxes provides the landlord with flexibility in storing the bees of multiple tenants in the same facility, and it can give the tenant flexibility with the number of bees it may need stored at the facility in any given season. With such a rental arrangement, a landlord should consider asking for a commitment from the tenant to deliver at least a certain number of beehives or colonies for storage, and the tenant should consider asking for a commitment from the landlord to reserve space in the facility for at least that same number of beehives or colonies as the tenant is giving a commitment for. Additionally, the parties will need to determine when rent will be paid. In a general commercial lease agreement, rent is usually paid monthly. With a bee storage lease agreement, however, a landlord may want to require the tenant to pay all of the rent for the season upon delivery of the bees, and the landlord may also want the tenant to pay a percentage of the rent to reserve space in the facility prior to delivery of the bees. This allows the landlord to get an early indication of what space in the facility it will have available in the facility for other tenants given the somewhat flexible rental arrangement of the parties.
Read the court decisionRead the full story...Reprinted courtesy of
Colton Addy, Snell & WilmerMr. Addy may be contacted at
caddy@swlaw.com
Pinnacle Controls in Verano
February 21, 2013 —
CDJ STAFFThe California Court of Appeals has applied the California Supreme Court’s recent Pinnacle decision to a new case, Verano Condominium Association v. La Cima Development. As in Pinnacle, La Cima sought to compel arbitration of construction defect claims with a homeowners association. The trial court denied La Cima’s attempt to compel arbitration on the grounds that the arbitration agreement was made with the individual homeowners and not the homeowners association. Further, it was determined that the CC&Rs “were unenforceable due to unconscionability.”
La Cima appealed, and the appeals court affirmed in part and reversed in part. After Pinnacle, La Cima sought a review. The Supreme Court of California directed the appeals court to vacate their earlier decision and reconsider, based on Pinnacle.
The Fourth Circuit Court has concluded that this conflicted with the ruling in Pinnacle. There, as in Verano, homeowners signed agreements that disputes with the developer would be settled through binding arbitration. The appeals court had found for the community association, but on review, the California Supreme Court reversed this decision.
The California Court of Appeals had two issue to consider in this review: whether the arbitration provisions applied to the homeowners association, and whether these provisions were unconscionable. The court concluded that “in light of Pinnacle it is clear the arbitration provisions set forth in the Verano CC&Rs constitute a valid agreement to arbitrate.” On the second question, the Verano CC&Rs were described by the court as “materially indistinguishable” from those in the earlier case. As the state Supreme Court found that those were not unconscionable, clearly neither were these.
The case was remanded for further proceedings and La Cima is entitled to recover the costs of the appeal.
Read the court decisionRead the full story...Reprinted courtesy of
The Irresistible Urge to Build Cities From Scratch
November 21, 2018 —
Monte Reel - BloombergEmbedded in the cerebral folds of every city planner who’s ever lived, there’s a cluster of neurons that lights up like Las Vegas when confronted with the possibility of a blank slate. It started with Hippodamus, the man Aristotle claimed was the father of urban planning. When the Persians destroyed his hometown of Miletus, Hippodamus discovered a bright side to catastrophe: The attackers had erased all the regrettable improvisations that, over the centuries, had made a mess of the place. Tasked with rebuilding, he seized his chance to impose order upon chaos. And so the concept of the urban grid was born.
Ever since, the dream of carte blanche has proved an all-but-irresistible seduction. Leonardo da Vinci drafted detailed sketches of an “ideal city” after the plague ravaged Milan, and a few hundred years later, Frank Lloyd Wright designed a metropolis that solved the problem of vehicular congestion via a network of helicopter taxis. Every so often, this urge in city planners breaks out into a full-scale epidemic, such as the one that spread throughout Europe and North America in the early 1900s. Known as the “garden city movement,” it aimed to counter the indignities of the Industrial Revolution by creating planned communities with plenty of green space.
Read the court decisionRead the full story...Reprinted courtesy of
Monte Reel, Bloomberg
