SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Policy's Limitation Period for Seeking Replacement Costs Not Enforced Where Unreasonable

March 12, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The New York Court of Appeals determined that a two year period for obtaining replacement costs for damage to property was unenforceable where the property could not be reasonably replaced in two years. Executive Plaza, LLC v. Peerless Ins. Co., 2014 WL 551251 (N.Y. Ct. App. Feb. 13, 2014). Plaintiff's office building was severely damaged in a fire on February 23, 2007. It cost more than a million dollars to restore the building to its previous condition. Plaintiff had $1 million in coverage from Peerless. The policy provided that replacement costs for any loss would be paid after the damaged property was repaired. The insured was required to make the repairs as soon as possible. Further, the policy provided that any legal action against the insurer had to be brought within two years of the loss. Peerless paid the "actual cash value" of the destroyed building pursuant to the policy in the amount of $757,812.50. Peerless informed the plaintiff that it would have to provide documentation of the completion of repairs to collect the full replacement value, another $242,187.50. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Florida trigger

May 18, 2011 — CDCoverage.com

In Johnson-Graham-Malone, Inc. v. Austwood Enterprises, Inc., No. 16-2009-CA-005750-XXXX-MA (Fla. 4th Cir. Ct. Duval County, April 29, 2011), insured JGM was the general contractor for an apartment project completed in 1998. In 2007, the project owner sued JGM seeking damages for defective construction resulting in moisture penetration property damage. JGM tendered its defense to Amerisure. Amerisure denied a defense. JGM defended and settled the underlying suit and then filed suit against Amerisure seeking recovery of defense and settlement costs. The trial court granted JGM’s motion for partial summary judgment. The court first addressed Amerisure’s duty to defend. Applying Florida law, the court held that, although the underlying complaint alleged that the property damage was not discovered until after expiration of the Amerisure policies



Read the full story…



Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Update: Supreme Court Issues Opinion in West Virginia v. EPA

August 03, 2022 — Anne Idsal Austin, Shelby L. Dyl & Sheila McCafferty Harvey - Pillsbury
Takeaways

• The Supreme Court sided with a coalition of states and coal mining companies constraining EPA’s ability to regulate CO2 emissions from power plants.
• The Supreme Court’s deployment of the “major questions doctrine” could have far-reaching implications for agencies’ authority to take actions that are politically and economically significant.
• The Court also announced a broad interpretation of standing, finding that the challengers could bring their suit notwithstanding EPA’s announced nonenforcement of the Clean Power Plan and intent to engage in a rulemaking to replace it.

Introduction On June 30, 2022, the Supreme Court issued its opinion in West Virginia v. EPA, invalidating the 2015 Obama-era Clean Power Plan (CPP). Chief Justice John Roberts delivered the opinion of the court, holding that Section 111(d) of the Clean Air Act does not authorize EPA to devise emissions caps based on “generation shifting”—the approach EPA took in the CPP wherein power plants would be required to transition from higher-emitting (e.g., coal) to lower-emitting (e.g., natural-gas) to then even lower-emitting (e.g., wind and solar) electricity production. The Court’s holding that the case was justiciable despite the Biden administration’s stated intent to repeal the Clean Power Plan and engage in a new rulemaking, as well as its deployment of the “major questions doctrine,” is likely to have far-reaching implications for legal challenges to all administrative agency actions. Reprinted courtesy of Anne Idsal Austin, Pillsbury, Shelby L. Dyl, Pillsbury and Sheila McCafferty Harvey, Pillsbury Ms. Austin may be contacted at anne.austin@pillsburylaw.com Ms. Dyl may be contacted at shelby.dyl@pillsburylaw.com Ms. Harvey may be contacted at sheila.harvey@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Unpredictable Opinion Regarding Construction Lien (Reinstatement??)

January 17, 2023 — David Adelstein - Florida Construction Legal Updates
Here comes the discussion of an appeal I was intimately involved in dealing with a construction lien. See Suntech Plumbing and Mechanical Corp. v. Bella Isla, LLC, 2022 WL 14672765 (Fla. 3d DCA 2022). Unfortunately, it was a losing result on my end but not a losing result to the issue at-hand. You should ask what in the world does this mean. I will tell you. Here is the fact pattern. A subcontractor files a construction lien foreclosure lawsuit against an owner for unpaid contract balance. In the same lawsuit, the subcontractor sues the general contractor for breach of contract and unjust enrichment associated with an approximate three-year delay on a construction project. The project was scheduled to be completed in 2019. It was not. The project was pushed into COVID and into 2022. (The subcontractor did not sue the general contractor for amounts subject to the lien foreclosure claim.) The general contractor, assuming the defense of the owner, moved to stay the lawsuit pending the outcome of arbitration based on an arbitration provision in the subcontract. The subcontractor did not dispute the arbitration provision, but argued that arbitration provision should not extend to the owner that was (a) not bound by the subcontract, (b) would not be a party to the arbitration, and (c) the amounts pled against the general contractor did not include the amounts subject of the lien foreclosure lawsuit. At a minimum, the lawsuit should be stayed, not dismissed. Nevertheless, the trial court dismissed the entire lawsuit in an order that states that it is a final order with language that the lien may be “reinstated” after the outcome of the arbitration (that the owner is not a party to). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

5 Impressive Construction Projects in North Carolina

February 04, 2014 — Melissa Dewey Brumback – Construction Law in North Carolina
What are your top construction building projects in North Carolina? Do you have a “short list”? Author Ralitsa Golemanova of JW Surety Bonds does, and she has the reasoning behind them. Ralista’s Top 5, which all “present a different facet of exceptional modern design and construction” are presented below. For her full commentary and some great pictures of the projects, check out her full article. Her list, in no particular order, includes: 1. The North Carolina Museum of Art’s West Building Expansion The 127,000 square-feet West Building Expansion of the North Carolina Museum of Arts won the 2011 American Institute of Architects (AIA) Honor Award for Architecture. The Building is largely made of aluminum panels. One of its specificities is that it does not have any windows. Instead, visibility is ensured through 360 skylights that allow delicate natural light to enter the inner galleries. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Construction Law in North Carolina
Ms. Brumback can be contacted at mbrumback@rl-law.com

---

When Is a Project Delay Material and Actionable?

January 11, 2022 — Rick Erickson - Snell & Wilmer Real Estate Litigation Blog
Welcome to 2022! This year, the construction industry will undoubtedly reflect on the last two years as unprecedented times plagued by construction project delays. The COVID-19 pandemic contributed to suspension of work and closure of construction projects worldwide in 2020. The end of 2021 brought additional delays caused by an inexplicable clog in the supply chain of construction materials. The combined impact of these events on project milestones and completion deadlines led our clients to ask, with unusual and particular urgency, who is liable for such delays and how do contracting parties lessen the consequences from such unexpected and uncontrollable delays. Granted that project delays are nothing new or unusual. They were common enough before inflation caused shipping complications and pandemic decimated the construction labor force. All delays, whatever the source, variably cause loss to all players on a construction project. But not all delays matter when it comes to claims and remedies available to the contracting parties in dispute resolution, where the determinative focus is on material delays impacting the entire project and on delays the claimant can credibly prove. Most, if not all, jurisdictions interpret actionable delays from the contract documents for the project. The contract is definitely where you should start before pursuing any delay remedies. Delay remedies may be a time extension only, or a time extension plus your additional general conditions. Some delay remedies may be barred by the contract’s express terms and may be enforced adversely by the courts when such contract terms are indisputable. See Quinn Constr. v. Skanska USA Bldg., Inc., 730 F. Supp. 2d 401, 411 (D.C. Pa. 2010) (enforcing the subcontractor’s contractual waiver of claims for delay and disruption damages). On the other hand, delay damages that are expressly allowed by the contract—like overtime necessitated by the delays—are usually actionable and recoverable. Id. However, not only the contract terms, but applicable law, may affect the outcome. Read the court decision
Read the full story...
Reprinted courtesy of Rick Erickson, Snell & Wilmer
Mr. Erickson may be contacted at rerickson@swlaw.com

---

Builder’s Risk Coverage—Construction Defects

August 20, 2019 — Brian Hearst - Construction Executive
This is the second of three articles bringing clarity to the complex and challenging course of construction exposures and providing solutions for mitigating risk through builder’s risk insurance coverage. Part I, Builder’s Risk Coverage – Language Matters, addressed a select few critical exposures to projects under the course of construction. Part II addresses how a standard builder’s risk policy may respond to a loss arising from defective construction and alternative insurance market offerings that can help with specific costs associated with construction defect loss. Coverage for Loss Ensuing from Faulty Workmanship Part I tackled the standard builder’s risk exclusion that applies to losses arising from faulty materials or workmanship. Traditionally, carriers do not have an appetite for covering a contractor’s failure to perform their work properly. There is one exception, which is coverage is available for ensuing loss – or the resulting damage to other property from faulty workmanship. If the excluded cause of loss (i.e., faulty workmanship) causes resultant damage, the builder’s risk policy will cover the damages to the extent the peril of fire is covered. The ensuing loss exception limits the faulty work exclusion to costs directly related to repairing or replacing the faulty work. For example, suppose faulty wiring work leads to a fire which damages part of a structure under construction. The faulty workmanship exclusion would apply to the actual faulty wiring work, but if fire is a covered peril under the policy (this is nearly always the case), the policy would respond to the structure’s fire damage. Reprinted courtesy of Brian Hearst, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Hearst may be contacted at Brian.Hearst@lockton.com

---

Is a Violation of a COVID-19 Order the Basis For Civil Liability?

April 20, 2020 — Robert Devine, James Burger & Douglas Weck - White and Williams
Thinking about ignoring your state or local COVID-19 shutdown orders? Think again. Social-distance measures may create a new source of liability for businesses operating during the COVID-19 pandemic. Infection-based litigation is normally limited to businesses operating in the healthcare sector. But, social-distancing measures to stop the spread of infection may expand that litigation to other sectors. State and local governments across the country are taking extraordinary measures to combat the spread of COVID-19, a novel coronavirus that can cause life-threatening respiratory illness. Those measures encourage and even mandate “social distance” between people to limit physical transmission of the virus. Hard-hit states like New York, New Jersey, Pennsylvania and California have been aggressive in their responses, shuttering businesses, confining people to their homes, and requiring people to stay six feet apart. Common mandates include: quarantines, business and school closures, stay-home orders, curfews, travel restrictions, occupancy limits and physical-distance mandates, among other things. Reprinted courtesy of White and Williams attorneys Robert Devine, James Burger and Douglas Weck Mr. Devine may be contacted at deviner@whiteandwilliams.com Mr. Burger may be contacted at burgerj@whiteandwilliams.com Mr. Weck may be contacted at weckd@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---