Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
Huh? Action on Construction Lien “Relates Back” Despite Notice of Contest of Lien
May 01, 2023 —
David Adelstein - Florida Construction Legal UpdatesNot every case law you read makes sense. This sentiment goes to the uncertainty and grey area of certain legal issues. It is, what you call, “the nature of the beast.” You will read cases that make you say “HUH?!?” This is why you want to work with construction counsel to discuss procedures and pros / cons relative to construction liens.
An example of a case that makes you say “HUH” can be found in Woolems, Inc. v. Catalina Capstone Creations, Inc., 2023 WL 2777506 (Fla. 3d DCA 2023) dealing with a construction lien foreclosure dispute.
Here, a contractor filed a lawsuit against a subcontractor with a summons to show cause why the subcontractor’s construction lien should not be discharged. This is a specific complaint filed under
Florida Statute s. 713.21(4). This statute requires the lienor to essentially foreclose on its construction lien within 20 days after it was served with a “show cause” summons. The subcontractor filed its answer and counterclaim but did NOT assert a claim to foreclose its construction lien.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Construction Manager’s Win in Michigan after Michigan Supreme Court Finds a Subcontractor’s Unintended Faulty Work is an ‘Occurrence’ Under CGL
August 03, 2020 —
Gabrielle Szlachta-McGinn - Newmeyer DillionOn June 29, 2020, the Michigan Supreme Court overturned a longstanding precedent that commercial general liability (“CGL”) insurers have historically relied upon to deny insurance coverage for claims involving pre-1986 CGL policies. See Hawkeye-Security Ins. Co. v. Vector Const. Co., 185 Mich. App. 369, 372, 460 N.W.2d 329, 331 (1990). In its recent ruling, the state Supreme Court unanimously agreed that an Insurance Services Office, Inc. (“ISO”) 1986 standard CGL policy, which is sold to construction contractors across the United States, provides coverage for property damage to a policyholder’s work product that resulted from a subcontractor’s unintended faulty workmanship. Skanska USA Bldg. Inc. v. M.A.P. Mech. Contractors, Inc., No. 159510, 2020 WL 3527909 (Mich. June 29, 2020).
In 2008, Skanska USA Building, Inc., the construction manager on a renovation project for Mid-Michigan Medical Center, signed a subcontract with defendant M.A.P. Mechanical Contractors (“MAP”) to install a new heating and cooling (“HVAC”) system. Id. During the renovation, MAP installed some of the expansion joints in the new HVAC system backwards. Id. The defective installation caused approximately $1.4 million in property damage to concrete, steel and the heating system, which Skanska discovered nearly two years after MAP completed the project. Id. After performing the repairs and replacing the damaged property, Skanska sought repayment for the repair costs from MAP and also submitted a claim to Amerisure seeking coverage as an insured under the CGL policy. Id. When Amerisure rejected Skanska’s claim, Skanska sued both parties. Id. Amerisure relied on the holding in Hawkeye and argued that MAP’s defective workmanship was not a covered “occurrence” under the CGL policy, which the policy defined as an accident. Id. at *4.
The Michigan Court of Appeals ignored the express language contained in the CGL policy and applied a prior appellate court precedent from Hawkeye, finding that MAP’s faulty work was not an “occurrence” and thus, did not trigger CGL coverage. Id. at *4. The Court of Appeals further reasoned that Skanska was an Amerisure policyholder and that the only property damage was to Skanska’s own work, which was not covered under the CGL policy. Id. at *5.
In a landmark decision, the Michigan Supreme Court reversed, holding unanimously that the Court of Appeals incorrectly applied the holding of Hawkeye because it failed to consider the impact of the 1986 revisions to standard CGL insurance policies. Id. at *10. Chief Justice Bridget M. McCormack explained that the Hawkeye decision rested on the 1973 version of the ISO form insurance policy, which specifically excluded certain business risks from coverage such as property damage to a policyholder’s own work. Id. The Supreme Court agreed that while Hawkeye was correctly decided, it did not apply here because the 1986 revised ISO policy includes an exception for property damage caused by a subcontractor’s unintentional faulty work. Id.
The Supreme Court said that under the plain reading of the current CGL policy language, an “accident” could include a subcontractor’s unintentional defective work that damaged a policyholder’s work product and thus, may qualify as an “occurrence” covered under the policy. Id. at *9. The Supreme Court defined an “accident” (which was not defined in the Amerisure policy) as “an undefined contingency, a casualty, a happening by chance, something out of the usual course of things, unusual, fortuitous, not anticipated, and not naturally to be expected.” Id. at *5; see Allstate Ins. Co. v. McCarn, 466 Mich. 277, 281, 645 N.W.2d 20, 23 (2002). The Supreme Court noted that there was no evidence suggesting that MAP purposefully installed the expansion joints backwards, nor was there evidence indicating that the parties affected by MAP’s negligence anticipated, foresaw, or expected MAP’s defective installation or property damage. Skanska, 2020 WL 3527909, at *4. Therefore, the Supreme Court concluded that an “occurrence” may have happened, which would trigger coverage under the CGL policy. Id. at *10.
Although this landmark decision changes Michigan law, the decision is limited to cases involving the 1986 ISO policy language revisions to CGL insurance policies. Id. The Supreme Court's decision does not overturn Hawkeye, but rather limits Hawkeye’s authority to cases involving the 1973 ISO form. Id.
Gabrielle Szlachta-McGinn was a summer associate at Newmeyer Dillion as part of the firm's 2020 summer class. You may learn more about Newmeyer Dillion's construction litigation services and find the group's key contacts at https://www.newmeyerdillion.com/construction-litigation/.
Read the court decisionRead the full story...Reprinted courtesy of
Berkeley Researchers Look to Ancient Rome for Greener Concrete
June 28, 2013 —
CDJ STAFFWhile modern concrete often crumbles after fifty years, some concrete laid down during the Roman Empire is still strong, even after 2,000 years. Researchers at UC Berkeley have been puzzling over the secrets of Roman concrete, using samples from a breakwater near Naples. The breakwater was built about 37 BC, and the concrete is still strong. Unlike modern concrete, the Romans made theirs with a mixture of lime and volcanic ash.
Paulo Monteiro, a professor of civil and environmental engineering at Berkeley, noted that one of the drawbacks of Roman cement was that it hardens more slowly than modern concrete. An advantage is that it is more environmentally friendly, and the researchers are trying to determine if volcanic ash cement would be a good substitute. Professor Montiero hopes that fly ash and volcanic ash cements “could replace 40 percent of the world’s demand for Portland cement.”
Read the court decisionRead the full story...Reprinted courtesy of
These Pioneers Are Already Living the Green Recovery
June 01, 2020 —
Laura Millan Lombrana & Akshat Rathi - BloombergIn the wake of the historic global economic shutdown in response to the Covid-19 pandemic, governments are unleashing trillions of dollars in a bid to create jobs and spur economic recovery. The scale of this stimulus is unprecedented, in some cases amounting to more than 10% of countries’ gross domestic product. At the same time, an overwhelming number of economists, finance ministers, and business leaders are saying that much of that money needs to help—and certainly not hinder—our ability to cut emissions.
If that advice is heeded, these funds will go to emerging technologies that would have sounded like science fiction not so long ago. Now they have ambitions to help lower greenhouse gas emissions on an industrial scale.
Leading the way is the European Union, which was planning a green transformation even before the outbreak began. It aims to make the 27-member bloc the first carbon neutral continent by 2050, and the pandemic hasn’t changed that.
Read the court decisionRead the full story...Reprinted courtesy of
Laura Millan Lombrana & Akshat Rathi, Bloomberg
Investigators Eye Fiber Optic Work in Deadly Wisconsin Explosion
July 18, 2018 —
Jeff Yoders – Engineering News-RecordA hole punched into a 4-in.-dia gas pipeline during fiber-optic line laying is blamed for an explosion that killed a 34-year-old fire captain and injured nine other people, including four firefighters, in downtown Sun Prairie, Wis., on July 10. The injured were treated at nearby hospitals and have since been released.
Read the court decisionRead the full story...Reprinted courtesy of
Jeff Yoders, ENRMr. Yoders may be contacted at
yodersj@enr.com
You Are on Notice: Failure to Comply With Contractual Notice Provisions Can Be Fatal to Your Claim
September 26, 2022 —
Jenifer B. Minsky - ConsensusDocsImagine your firm is the construction manager on a multi-million-dollar project. At the end of the project you are five million dollars out-of-pocket. You have a stack of claims for additional and extended work which led to the overrun, payment for which will easily cover the shortfall. However, the owner refuses to compensate you until you can satisfactorily answer their inquiry: “Where are the notices that are expressly required under the terms of the contract?” You had a good relationship with the owner’s field representative who was aware you were performing the work and understood that your company was compiling claims. The once cooperative owner, now suffering financial restraints of their own, is resolute in their refusal leaving you no choice but to expend substantial sums of money to litigate the claims, the success of which is far from assured.
What Contract Language Can Be A Trap For An Unwary Contractor?
While courts are generally hesitant to order a forfeiture and some courts disfavor condition precedents, a judge’s hands may be tied by particular contract language requiring the strict enforcement of notice requirements. Such provisions may include: (1) an explicit clause that there be precise compliance with notice requirements; (2) express consequences for noncompliance (e.g., if the required notice is not provided the claim will be waived, forfeited or abandoned); (3) a statement that the notice requirements are a condition precedent to recovery; (4) language such as “if,” “provided that,” “or else” or “on condition that” (e.g., the owner shall review the claim, “provided such claim” was received within the applicable notice period) or (5) prohibition of any waiver of the notice requirement. To the extent the notice provision includes such language, a contractor can be without recourse even when the owner has actual knowledge of the claims or cannot show prejudice by the lack of notice.
Read the court decisionRead the full story...Reprinted courtesy of
Jenifer B. Minsky, Peckar & Abramson, P.C.Ms. Minsky may be contacted at
jminsky@pecklaw.com
Newmeyer & Dillion Announces Three New Partners
March 16, 2017 —
Newmeyer & Dillion LLPNEWPORT BEACH, Calif. – FEBRUARY 7, 2017 – Prominent business and real estate law firm Newmeyer & Dillion LLP is pleased to announce that three of the firm’s attorneys – Ben Ammerman, Anne Kelley and Rondi Walsh – have been elected to partnership. Their promotions are effective immediately.
“The elevation of these three attorneys is a testament to their leadership, hard work, and unwavering commitment to superior service for our clients and the firm,” proclaimed Jeff Dennis, Newmeyer & Dillion’s Managing Partner. “This is an exciting time for the firm as we look forward to their continued success and contributions.”
Ammerman (based in Newport Beach, CA) focuses his practice in the areas of business, real estate, and tort litigation. In addition to his private practice, Ammerman presently serves as a Commander in the Navy Reserve Judge Advocate General’s Corps. He's also an active alumnus, currently named co-chair of the University of Southern California’s 20th Reunion Committee.
Kelley (based in Walnut Creek, CA) concentrates primarily in construction litigation and insurance coverage matters. She has over 12 years of experience working closely with builders, developers, contractors and subcontractors throughout Northern California developing legal strategies specific to the needs of each matter and the client’s business and goals. Kelley has litigated a wide variety of complex insurance coverage disputes.
Walsh (based in Newport Beach, CA) has incorporated into her practice the representation of policyholders in first and third-party insurance coverage, and business lawsuits involving contracts, property disputes, products liability and construction defect issues. She also has litigated numerous political and election law matters and has worked both professionally and as a volunteer on numerous political campaigns. Walsh is also an active member with the National Charity League.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
