Fairfield Connecticut Building Expert Directory

Ready, Fire, Aim: The Importance of Targeting Your Delay Notices

November 08, 2021 — Bradley Sands, Jones Walker LLP - ConsensusDocs
Providing written notice of delay to subcontractors when a project is behind schedule is a regular part of good project documentation practices. A properly targeted delay notice is an important, project correspondence that is an appropriate response to a subcontractor’s specific delay or ongoing delays. However, when a project falls behind schedule and the project management team is in the fog of war, it could seem like a good idea to start firing off project delay notices to any and every subcontractor. While these delay notices may provide a short term burst of productivity, you could find that those same notices are aimed back at you in a future litigation. This article identifies two potential unintended consequences of sending delay notices that a contractor should keep in its sights and then provides recommendations for properly calibrating future delay notices in light of these potential consequences. Acceleration: You Might Get What You Ask For A delay notice to a subcontractor could be interpreted as—or expressly state—direction to the subcontractor to accelerate its work. When a subcontractor is directed to accelerate its work, it may incur additional costs for premium, extended, or overtime labor, additional crews, increased supervision costs, increased overhead costs, and losses due to productivity impacts from the acceleration (e.g., stacking of trades and fatigue). A subcontractor may be entitled to recover these increased costs that are caused by a direction to accelerate. Read the court decision
Read the full story...
Reprinted courtesy of Bradley Sands, Jones Walker LLP
Mr. Sands may be contacted at bsands@joneswalker.com

Contractors Can No Longer Make Roof Repairs Following Their Own Inspections

July 02, 2018 — Jason Feld & Alex Chazen - Kahana & Feld LLP
California law mandates that any person who conducts roof inspections for a fee can no longer effectuate the actual repairs to the same property. Effective January 1, 2018, Business & Professions Code Section 7197 (Unfair Business Practices) deems it to be an unfair business practice for a home inspector who charges a homeowner a monetary fee for inspecting the property, to perform or offer to perform additional repairs due to the inherent financial interest and conflict raised by identifying alleged defects necessitating repairs. The new law is a result of California AB 1357, which was signed into law on October 5, 2017. The goal of the new law is to disincentivize a roof inspector from creating a report for the sole purpose of obtaining a bid to perform those documented repairs. The roof contractor can perform repairs identified in their report only after a twelve month “cooling period” which provides the homeowner an opportunity to obtain multiple bids/estimates for repairs based upon the inspector’s report. The new law also discourages home inspectors from providing a list of contractors who provide monetary referral fees back to the home inspector upon receiving repair work from the homeowner based exclusively on the home inspection report. The California Business & Professions Code Section 7195(a)(1) defines a “home inspection” as a “non-invasive, physical examination, performed for a fee in connection with the transfer…of the real property…or essential components of the residential dwelling.” Home inspection includes “any consultation regarding the property that is represented to be a home inspection or any confusingly similar term.” Business & Professions Code section 7195(a)(2) further defines a “home inspection” as including energy efficiency and solar. A “home inspection report” is a written report prepared for a fee issued after an inspection. Business & Professions Code section 7195(c). It is noted that a home inspector does not have to be a licensed architect, professional engineer, or general contractor with a Class “B” license issued by the California Contractors State License Board, but “it is the duty of a home inspector who is not licensed as a general contractor, structural pest control operator, or architect, or registered as a professional engineer to conduct a home inspection with the degree of care that a reasonably prudent home inspector would exercise. Business & Professions Code section 7196. Reprinted courtesy of Jason Feld, Kahana & Feld LLP and Alex Chazen, Kahana & Feld LLP Mr. Feld may be contacted at jfeld@kahanalaw.com Mr. Chazen may be contacted at achazen@kahanafeld.com Read the court decision
Read the full story...
Reprinted courtesy of

Phillips & Jordan Awarded $176M Everglades Restoration Contract

March 01, 2021 — Thomas F. Armistead - Engineering News-Record
Construction of the next major project for the Everglades Agricultural Area Reservoir south of Lake Okeechobee is set to begin in April following the South Florida Water Management District's award of a $175.8-million lump-sum contract to Phillips and Jordan Inc. Reprinted courtesy of Thomas F. Armistead, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

The EEOC Targets Construction Industry For Heightened Enforcement

May 15, 2023 — Meghan Douris & Andrew Scroggins - The Construction Seyt
Seyfarth Synopsis: On January 10, 2023, the Equal Employment Opportunity Commission (EEOC) released for public comment its draft 2023-2027 Strategic Enforcement Plan (“SEP”)—a document that will guide the Commission’s enforcement priorities for the next five years. The EEOC’s prior Strategic Plan described how it would pursue its enforcement goals. (See our earlier blog on the Strategic Plan here). The Strategic Enforcement Plan, on the other hand, describes what the EEOC’s enforcement priorities will be. Earlier actions by the EEOC suggested that it might be turning its attention to the construction industry. In the SEP, the EEOC makes its intentions explicit, putting the construction industry—and especially those receiving federal funding—squarely in its sights. History of the SEP The EEOC’s first SEP covered Fiscal Years 2013-2016 (the EEOC’s fiscal years begin on October 1) and identified six broad subject-matter priorities. The EEOC’s second SEP set the course for enforcement priorities for FY2017-2022. The latest proposed SEP, published in the Federal Register for comment for the first time, provides notable additional details that put the employer community on notice of the Commission’s intentions for FY2023-2027.[1] Reprinted courtesy of Meghan Douris, Seyfarth and Andrew Scroggins, Seyfarth Ms. Douris may be contacted at mdouris@seyfarth.com Mr. Scroggins may be contacted ascroggins@seyfarth.com Read the court decision
Read the full story...
Reprinted courtesy of

BP Is Not an Additional Insured Under Transocean's Policy

April 01, 2015 — Tred R. Eyerly – Insurance Law Hawaii
Responding to a certified question from the Fifth Circuit, the Texas Supreme Court determined that BP was not an additional insured under Transocean's liability policy and had no coverage under the policy for the deaths caused by the explosion of the Deepwater Horizon. In re Horizon, 2015 Tex. LEXIS 141 (Tex. Feb. 13, 2015). We have previously posted on this case in the federal courts here and here. Transocean owned the Deepwater Horizon, a mobile offshore drilling unit operating in the Gulf of Mexico pursuant to a contract with BP. After an explosion in April 2010, the rig caught fire, killing eleven crew members. Both Transocean and BP sought coverage under Transocean's primary and excess policies. Although they did not dispute that BP was an additional insured, Transocean and its insurers argued that BP was not entitled to coverage for pollution-related liabilities arising from subsurface oil releases in connection with the Deepwater Horizon accident. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Remodel Gets Pricey for Town

December 30, 2013 — CDJ STAFF
Usually when home gets remodeled, it’s the homeowners who encounter unexpected expenses, but in Clearwater, Florida, it’s the town. Clearview has spent about $40,000 trying to determine if changes to a home are a “substantial improvement,” and the bill could get bigger, according to TBNweekly.com. The home in question, that of David and Aileen Blair, is in a flood zone, and city rules would require the alterations to comply with flood drainage-resistance provisions, but only if it is a “substantial improvement.” The Blairs applied for the remodel permit in April 2001, and it was granted more than 10 years later, in July 2011. Work started soon after until the city put a stop to it. The Blairs sued, claiming that as the city issued the permit, they assumed the plans were approved, and that the partially-completed renovation now diminishes the value of their home. The city has approved an additional $160,000 in outside legal counsel to respond to the Blair’s lawsuit. Read the court decision
Read the full story...
Reprinted courtesy of

Wilke Fleury Secures Bid Protest Denial

March 16, 2020 — Wilke Fleury LLP
After the City of Vacaville, following a sealed bid process, awarded a significant well drilling contract to Roadrunner Drilling & Pump Company, second-place bidder Nor-Cal Pump and Well Drilling filed a protest with the City on January 30, claiming that Roadrunner’s bid failed to meet certain requirements of the proposed contract. Roadrunner hired Wilke Fleury to defend the bid protest. After Wilke Fleury partner Dan Baxter transmitted a letter to the City explaining why the disgruntled bidder’s protest was factually and legally unsupported, the City—a mere nine days after receiving Dan’s letter—rejected the bid protest, and maintained its award of the project to Roadrunner as the lowest responsive and responsible bidder. Wilke Fleury LLP Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Fannie-Freddie Elimination Model in Apartments: Mortgages

April 08, 2014 — Sarah Mulholland – Bloomberg
The apartment-lending units of Fannie Mae (FNMA) and Freddie Mac were among their few money makers after the U.S. housing collapse. Now they should help transform the U.S. mortgage industry. Lawmakers seeking to eliminate the two government lenders, which were seized by regulators during the 2008 credit crisis, see an antidote to the reckless lending that blew up the U.S. housing market in the structure of the firms’ multifamily operations, which share risks with lenders. Senate Banking Committee Chairman Tim Johnson and Republican Mike Crapo are proposing legislation to create a new government-backed reinsurer of mortgage bonds that would require private investors to bear losses on the first 10 percent of capital. The model for the provision mirrors Fannie Mae and Freddie Mac (FMCC)’s multifamily lending operations, requiring lenders to shoulder some of the risk on loans they originate. Read the court decision
Read the full story...
Reprinted courtesy of Sarah Mulholland, Bloomberg
Ms. Mulholland may be contacted at smulholland3@bloomberg.net

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES