Municipalities Owe a Duty to Pedestrians Regardless of Whether a Sidewalk Presents an “Open and Obvious” Hazardous Condition. (WA)
February 25, 2014 —
Natasha Khachatourians – Scheer & Zehnder LLP Liability NewsletterIssue: Does a municipality owe a duty to pedestrians to keep sidewalks reasonably safe for their intended use even if the condition of the sidewalk is an open and obvious hazard? YES
Facts: Plaintiff Nanci Millson liked to walk in Lynden, Washington. While plaintiff regularly walked through her neighborhood and knew that various areas of the sidewalk were cracked and lifted, she continued to walk through her neighborhood nonetheless. Plaintiff felt that the sidewalks closer to her neighborhood were in better condition and when she reached an area a block away from her home, she picked up speed even though she was in an area of sidewalk she previously had not walked before. Plaintiff became distracted, tripped on an elevated sidewalk and fell, suffering various injuries.
Plaintiff sued the City of Lynden (“City”) for negligently failing to maintain the sidewalk in a reasonably safe condition. The City argued that the tripping hazard was “open and obvious”, and the trial court granted the City summary judgment. The issue before the Court of Appeals was whether an “open and obvious” condition is a matter of law to be decided by the court.
Read the court decisionRead the full story...Reprinted courtesy of
Natasha Khachatourians, Scheer & Zehnder LLP Ms. Khachatourians may be contacted at
natashak@scheerlaw.com
Reminder: In Court (as in life) the Worst Thing You Can Do Is Not Show Up
September 28, 2017 —
Christopher G. Hill - Construction Law MusingsAs long time (and possibly recent) readers of Construction Law Musings know, I am a Virginia Supreme Court Certified Mediator. In that capacity, I spend quite a bit of time sitting in general district court courtrooms in places like Goochland and Caroline Counties “court sitting” awaiting a referral from the judge of a case with parties ready and willing to take advantage of the mediation process.
As I sit there wearing my mediator “hat,” I see case after case be called for the first return date. Without fail, several cases are called where the defendant fails to appear after being served with process. There are even a case or two where the plaintiff (the party that picked the return date in the first place) fails to appear. In the first instance, where the defendant doesn’t appear, the judge almost inevitably enters a judgment for the amount sued for by the plaintiff. In the latter instance, the case is dismissed without prejudice to the plaintiff with a shake of the head by the judge at the wasted time and filing fee. This post focuses on the first case.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, Law Offices of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Fire Raging North of Los Angeles Is Getting Fuel From Dry Winds
June 17, 2024 —
Brian K Sullivan - BloombergA wildfire raging north of Los Angeles has sent smoke billowing south and forced more than 1,000 people to evacuate — and with dry winds raking the hills, the blaze is poised to intensify.
A red flag fire warning has been raised in the area around the Post Fire, which is forecast to be whipped with winds reaching at least 20 miles (32 kilometers) per hour, according to the California Department of Forestry and Fire Protection, commonly called Cal Fire. The flames, which have burned more than 14,000 acres (5,700 hectares), are only about 8% contained and the smoke has prompted air quality alerts in parts of Los Angeles County and Ventura County.
“Crews are working to establish perimeter fire lines around the fire’s edges,” Cal Fire said in a report. “Aircraft are being utilized to halt the fire’s forward progress but are facing challenges due to limited visibility.”
Along with the Post Fire, crews are battling 10 other blazes throughout the state that flared up over the weekend in an ominous start to wildfire season. While California had heavy snow and rain this past winter, that doesn’t mean a respite from fires. The moisture that kept drought away allowed for grasses and brush to grow, meaning more wildfire fuel as California enters its driest months.
Read the court decisionRead the full story...Reprinted courtesy of
Brian K Sullivan, Bloomberg
Evolving Climate Patterns and Extreme Weather Demand New Building Methods
May 22, 2023 —
Annette Rubin - Construction ExecutiveCompared to the rest of the world, most buildings in the United States are relatively young. But most residential and commercial properties could use a makeover. Buildings constructed over twenty, fifty and one hundred years ago are, unsurprisingly, not as energy-efficient or as safe as new builds following modern methods—especially when considering the effects of climate change and more frequent extreme weather events on the integrity of that infrastructure.
According to the National Association of Home Builders, over 90% of new homes built in the United States today are wood-framed. These homes are incapable of withstanding a tornado or hurricane, yet they are still being built directly in the path of storms. Even buildings constructed in some of the most earthquake-prone areas of the U.S. may contain design flaws that make them susceptible to damage because they are built using a non-ductile concrete method, which experts say has an inadequate configuration of steel reinforcing bars—making the building vulnerable when shaken. While this building method was banned for new construction, it is not yet required to retrofit older construction to improve safety and structural integrity.
Reprinted courtesy of
Annette Rubin, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Late Progress Payments on Local Public Works Projects Are Not a Statutory Breach of Contract
May 10, 2022 —
Ted Senet & Christopher Trembley - Gibbs GidenCalifornia local public agencies and their contractors should take note of a recent appellate decision pertaining to late progress payments on public works projects. In Clark Bros., Inc. v. North Edwards Water Dist., 2022 Cal. App. LEXIS 331, filed on April 22, 2022, the Court of Appeal for the Fourth Appellate District held that a local agency’s late progress payments to a general contractor did not constitute breach of contract under the prompt payment penalty statute, Public Contract Code § 20104.50. Notwithstanding this holding, the contractor recovered damages, interest, fees, and costs in excess of its contract amount.
In 2013, the North Edwards Water District awarded a $6.2 million contract to Clark Bros., Inc. to construct a water treatment facility. The District’s water contained excessive levels of arsenic, and the project was sponsored by the State of California with funds earmarked to provide safe drinking water. The State agreed to disburse funds to the District during construction upon the State’s review and approval of the contractor’s progress payment applications. The contract required completion of the work within one year following the District’s issuance of a notice to proceed to the contractor.
As a result of factors arguably outside the control of the contractor, including unforeseen site conditions and the failure of the District’s equipment supplier to meet delivery deadlines, the project was significantly delayed beyond the deadline for completion. The District nonetheless terminated the contractor, which in turn filed suit against the District and the State. The contractor asserted claims for breach of contract, including breach of contract for the District’s failure to pay the contractor’s progress payment applications within the time specified under Public Contract Code § 20104.50. Subsection (b) of the statute provides:
Any local agency which fails to make any progress payment within 30 days after receipt of an undisputed and properly submitted payment request from a contractor on a construction contract shall pay interest to the contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure.
Reprinted courtesy of
Ted Senet, Gibbs Giden and
Christopher Trembley, Gibbs Giden
Mr. Senet may be contacted at tsenet@gibbsgiden.com
Mr. Trembley may be contacted at Ctrembley@gibbsgiden.com
Read the court decisionRead the full story...Reprinted courtesy of
Georgia Federal Court Says Fact Questions Exist As To Whether Nitrogen Is An “Irritant” or “Contaminant” As Used in Pollution Exclusion
May 20, 2019 —
Lawrence J. Bracken II, Michael S. Levine & Alexander D. Russo - Hunton Andrews KurthThe Southern District of Georgia recently ruled that Evanston Insurance Company is not entitled to summary judgment on whether its policies’ pollution exclusion bars coverage for the release of nitrogen into a warehouse. The case stems from an incident at Xytex Tissue Services, LLC’s warehouse, where Xytex stored biological material at low temperatures. Xytex used an on-site “liquid nitrogen delivery system” to keep the material properly cooled. This system releases liquid nitrogen, which would vaporize into nitrogen gas and cool the biological material. On February 5, 2017, a Xytex employee, Deputy Greg Meagher, entered the warehouse to investigate activated motion detectors and burglar alarms. Deputy Meagher was overcome by nitrogen gas and died as a result. Following Deputy Meagher’s death, his heirs filed suit against Xytex and other defendants. Evanston denied coverage based on the pollution exclusion in its policy. Evanston then brought a declaratory judgment action to confirm its coverage position.
In denying Evanston’s summary judgment motion, the Southern District of Georgia reasoned that the type of injury sustained is essential in analyzing whether the pollution exclusion applies. Specifically, Xytex argued, and the court agreed, that the underlying lawsuit alleged that the bodily injury was caused by a lack of oxygen, not exposure to nitrogen. The court also distinguished prior decisions, explaining that injury caused by a lack of oxygen is not a contamination or irritation of the body in the same way as injury resulting from exposure to carbon monoxide or lead. The court also found that Xytex “reasonably expected that liability related to a nitrogen leak would be insured.”
Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys
Lawrence J. Bracken II,
Michael S. Levine and
Alexander D. Russo
Mr. Bracken may be contacted at lbracken@HuntonAK.com
Mr. Levine may be contacted at mlevine@HuntonAK.com
Mr. Russo may be contacted at arusso@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Run Spot...Run!
November 18, 2024 —
Daniel Lund III - Lexology"The 'classic' definition of spot zoning is 'the process of singling out a small parcel of land for a use classification totally different from that of the surrounding area for the benefit of the owner of such property and to the detriment of other owners.’ Anderson’s American Law of Zoning, 4th Edition, § 5.12 (1995)” (from plannersweb.com).
A wireless carrier rebuffed in Jennings, Louisiana, on an application to rezone residential property to site a monopole cell tower sought relief from the federal court for the Western District of Louisiana. The city lacked any wireless tower provisions in its ordinances, and the carrier asserted that existing “commercial property within the appropriate range” was unavailable.
Read the court decisionRead the full story...Reprinted courtesy of
Daniel Lund III, PhelpsMr. Lund may be contacted at
daniel.lund@phelps.com
Texas res judicata and co-insurer defense costs contribution
March 23, 2011 —
CDCoverage.comIn Truck Ins. Exchange v. Mid-Continent Casualty Co., No. 03-08-00526-CV (Tex. App. 3d Aug. 27, 2010), insured contractor DCI was sued by the project owner seeking damages for defective construction. DCI tendered its defense to its CGL insurers Truck and Mid-Continent. Truck agreed to defend while Mid-Continent denied a defense. While the underlying suit was pending, Mid-Continent sued DCI, but not Truck, and obtained a judicial declaration of no duty to defend or indemnify DCI in the underlying suit. After settling the underlying suit, Truck sued Mid-Continent seeking contribution towards defense costs and indemnity payments. The state trial court entered summary judgment for Mid-Continent. The intermediate appellate court affirmed.
Read the full story...
Reprinted courtesy of CDCoverage.com
Read the court decisionRead the full story...Reprinted courtesy of
