Fairfield Connecticut Building Expert Directory

The Requirement to Post Collateral Under General Agreement of Indemnity Is Real

May 16, 2022 — David Adelstein - Florida Construction Legal Updates
In prior postings, I have discussed the all-powerful General Agreement of Indemnity (click here and here). This is the document a bond-principal executes to obtain bonds (e.g., performance and payment bonds). Not only does the bond-principal execute this General Agreement of Indemnity, but typically, so do other indemnitors such as the company’s principals and their spouses, other related companies, etc. The objective is that the surety has financial comfort that if a claim is made against the bond, there are avenues where it will get reimbursed and indemnified for any cost it incurs, or payment it makes, relative to that claim against the bond. When a surety issues bonds, the objective is that all losses it incurs gets reimbursed because the bonds are NOT insurance policies. One of the powerful tools the surety can exercise in the General Agreement of Indemnity is to demand the bond-principal and other indemnitors to post collateral in an amount the surety deems sufficient to cover any losses it may incur. This is a right in any General Agreement of Indemnity I have seen and is a right the surety can rightfully exercise. A recent example is shown from the opinion in Philadelphia Indemnity Ins. Co. v. Quinco Electrical, Inc., 2022 WL 1230110 (M.D.Fla. 2022), which pertains to the surety’s motion for preliminary injunction. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Liability policy covers negligent construction: GA high court

October 31, 2010 — Michael Bradford in Business Insurance

ATLANTA—Negligent construction that results in damage to surrounding property constitutes an occurrence under a commercial general liability policy, the Georgia Supreme Court has ruled.

In a 6-1 opinion Monday in American Empire Surplus Lines Insurance Co. Inc. vs. Hathaway Development Co. Inc., the Georgia high court upheld a lower court ruling that the general contractor’s claim for damage caused by a subcontractor’s faulty plumbing work was covered.

The ruling on construction defects is the latest in number of such cases across the United States

Read Full Story...

Reprinted courtesy of Michael Bradford of Business Insurance.

Read the court decision
Read the full story...
Reprinted courtesy of

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SIG Earnings Advance 21% as U.K. Construction Strengthens

August 13, 2014 — Benjamin Katz – Bloomberg
SIG Plc (SHI) earnings surged 21 percent in the first half as the distributor of building products benefited from a strengthening recovery in the U.K. housing market as well as procurement savings. Underlying operating profit rose to 47.8 million pounds ($80 million) from 39.6 million pounds a year earlier, the Sheffield, England-based company said in a statement today. Sales in the U.K. and Ireland from continuing operations climbed 14 percent to 650 million pounds, offsetting flat revenue in continental Europe. “Trading conditions in the U.K. have continued to gather momentum, led by the revival in the housing market,” Chief Executive Officer Stuart Mitchell said in the statement. “The group’s first-half performance and progress on its strategic initiatives provide a strong base on which to achieve its full-year expectations.” Read the court decision
Read the full story...
Reprinted courtesy of Benjamin Katz, Bloomberg
Mr. Katz may be contacted at bkatz38@bloomberg.net

Navigating Threshold Arbitration Issues in Construction Contracts

April 29, 2024 — Daniel D. McMillan and TJ Auner - The Dispute Resolver
Including an arbitration clause in your construction contract may not mean that your dispute will be confined to arbitration. Instead, parties often find themselves in court litigating threshold issues related to the existence and/or enforceability of an arbitration clause. Common issues include whether the underlying contract containing the arbitration clause is valid, whether the dispute falls within the scope of the clause, whether the parties complied with contractual prerequisites to arbitration, whether issues related to arbitrability are decided by the court or arbitrator, and whether one of the parties has waived their right to arbitrate. This blog post highlights two recent construction cases addressing threshold issues that a party seeking to enforce—or oppose enforcing—an arbitration clause might face. Seifert v. United Built Homes, LLC: Delegating Issues of Arbitrability to the Arbitrator In Seifert, an owner sued a homebuilder in Texas federal court for breach of contract and sought damages and declaratory relief. No. 3:22-CV-1360-E, 2023 WL 4826206 (N.D. Tex. July 27, 2023). The builder moved to compel arbitration. The owner opposed and argued that: (1) there was no agreement to arbitrate because the underlying contract was null and void, and (2) its claim for declaratory relief fell outside the scope of the arbitration clause. The court did not address the merits of either argument. Instead, it determined that these were issues for the arbitrator to decide. Reprinted courtesy of Daniel D. McMillan, Jones Day and TJ Auner, Jones Day Mr. McMillan may be contacted at ddmcmillan@jonesday.com Mr. Auner may be contacted at tauner@jonesday.com Read the court decision
Read the full story...
Reprinted courtesy of

2025 Construction Law Update

January 07, 2025 — Garret Murai - California Construction Law Blog
It’s that time of year again. The second half of the 2023-2024 legislative session saw the introduction of 2,124 bills, of which, 1418 were signed into law. Among the bills signed by the governor impacting contractors is an increase in the small work licensing exemption for $500 to $1,000, the licensing of Indian tribes by the CSLB, and a number of project-specific bills, as is typical, related to project-specific alternative project delivery methods. Wishing you and yours a great 2025! Licensing AB 2622 – Increases the small work licensing exemption from $500 to $1,000 provided that the work: (1) does not require a building permit; and (2) does not involve the employment of others to perform or assist in the work. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

No Coverage for Faulty Workmanship Based Upon Exclusion for Contractual Assumption of Liability

August 06, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The Supreme Court for West Virginia determined the policy's contractual assumption exclusion barred coverage for the general contractor based upon claims of faulty workmanship. J.A. St & Assocs. v. Bitco Gen. Ins. Corp., 2019 W. Va. LEXIS 205 (May 1, 2019). J.A. Street & Associates, Inc. entered a contract with the developer, Thundering Herd Development, L.L.C., to build a commercial shopping center on seventy-eight acres of land. Street agreed to oversee the site preparation for the development and the construction of many of the buildings. Thundering Herd retained an engineering firm, S&ME, Inc. to do geotechnical exploration and to provide advice regarding land preparation for the shopping center. Thundering Heard also entered an agreement with the Target Corporation to construct a store on a pad to be prepared at the shopping center. Street hired subcontractors to prepare the site by grading the land and installing fill material. A slope was constructed at the rear of the proposed Target site, but it failed, causing a landslide, damage to the pad, and damage to adjacent property owned by a third party. Thundering Heard incurred $721,875 in additional costs to repair this slope, reconstruct the Target site, and compensate the neighbor for the damage to the adjacent property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Construction Contract Clauses That May or May Not Have Your Vote – Part 3

November 23, 2016 — Garret Murai – California Construction Law Blog
Scope, time and cost provisions may be the most important clauses in your construction contract but they’re not the only ones which can impact your bottom line. The third in a multi-part series, here are some other important construction contract clauses that may determine whether you come out a winner.

Provision: Supervisory Personnel, Employees, and Authority to Bind Provisions

Typical Provision: ”At all times during performance of the Work, Subcontractor shall have at the job site a competent supervisor approved by Owner. Subcontractor’s supervisor shall be deemed a representative of Subcontractor and all communications given to Subcontractor’s supervisor shall be as binding as if such communications were given to Subcontractor. Should Contractor object to Subcontractor’s supervisor’s presence at the job site, or the presence at the job site, or the presence at the job site of any other employee or agent of Subcontractor or any employee or agent of Subcontractor of Subcontractor, Subcontractor shall cause such persons to be replaced immediately as directed by Contractor.”
What it Means: Higher-tiered parties have a legitimate interest in ensuring that only competent individuals are allowed to perform work on a project and in ensuring that there are peaceable relations at a job site. Higher-tiered parties also have an interest in ensuring that directives and agreements made and reached in the field are followed. However, it is unreasonable for higher-tiered party or to require that such personnel be able to bind that lower-tiered party to agreements best decided by others.
What You Can Do: Lower-tiered parties should seek to include language which provides that only “reasonable” changes to personnel are allowed and, as necessary, limit by category or issue the types of items on-site personnel can bind the lower-tiered party to.

Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES