Cambridge Massachusetts Building Expert Directory

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

Is Ohio’s Buckeye Lake Dam Safe?

March 12, 2015 — Beverley BevenFlorez-CDJ STAFF
According to Columbus Business First, a report by the U.S. Army Corps of Engineers that “assessed the structural integrity of the Buckeye Lake Dam [located in Ohio] and found serious problems that present significant risks to the public.” Problems arose, allegedly, from “construction of homes [and] pools and patios that have been built into the earthen embankment.” The U.S. Army Corps of Engineers report stated (according to Columbus Business First) “there was a potential for an eight-foot wave of water, mud and debris that would inundate an area as far as Hebron, more than two miles away.” Read the court decision
Read the full story...
Reprinted courtesy of

Claims for Breach of Express Indemnity Clauses Subject to 10-Year Statute of Limitations

October 08, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Thomas G. Cronin of Gordon & Rees LLP (published in Association of Corporate Counsel), “[i]n 15th Place Condominium Association v. South Campus Development Team LLC, the Appellate Court for the First District of Illinois held that a claim for breach of an express indemnity clause within a construction agreement was subject to the 10-year statute of limitations for written contracts instead of the four-year statute of limitations for construction claims.” In 2008, the condo association sued the developer alleging “it had discovered latent design and construction defects in the condominium towers. In 2011, the developer filed a third-party complaint against the general contractor alleging breach of express indemnity.” While the general contractor prevailed in the first trial, the appellate court reversed the decision, “concluding that the nature of the developer’s express indemnity claim against the general contractor related to the failure to indemnify rather than to a construction-related activity.” Read the court decision
Read the full story...
Reprinted courtesy of

A Court-Side Seat: Citizen Suits, “Facility” Management and Some Nuance for Your Hazard Ranking

September 28, 2020 — Anthony B. Cavender - Gravel2Gavel
Some very interesting and fairly complex environmental law rulings have been released in the past few days. U.S. Supreme Court—Trump, et al. v. Sierra Club, et al. On July 31, 2020, in a 5-to-4 decision, the Supreme Court denied a motion to lift the stay entered by the Court a few days earlier. The earlier action stayed a preliminary injunction issued by the U.S. District Court for the Northern District of California, which had enjoined the construction of a wall along the Southern Border of the United States which was to be constructed with redirected Department of Defense funds. The merits will be addressed by the lower court and perhaps the U.S. Court of Appeals for the Ninth Circuit. U.S. Court of Appeals for the District of Columbia Circuit—Meritor, Inc. v. EPA In a case involving EPA’s administration of the Superfund National Priority List (NPL) of priority Superfund sites requiring expedited cleanup, the court held that EPA had acted in accordance with the law and its implementing rules, and denied relief. Meritor was spun off from Rockwell Corporation, and is responsible for Rockwell’s environmental liabilities, including sites Meritor never operated. In 2016, EPA added the Rockwell International Wheel & Trim facility in Grenada, Miss., to the NPL list. Meritor alleged that this listing was arbitrary and capricious, pointing to EPA’s failure to adequately consider the impact of a mitigation measure added to the facility to address vapor intrusion, a factor EPA must consider in its application of the agency’s hazard ranking system. However, the court was not impressed by these arguments, and denied relief. The court’s discussion of the nuances of the hazard ranking system is very instructive Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Homebuilder Confidence Takes a Beating

October 21, 2013 — CDJ STAFF
Homebuilder confidence dropped to fifty-five percent in October, the lowest percentage seen in the last four months. The score had been rising on the strength of renewed home sales. The current slump is attributed to increases in interest rates, which have made home purchases more expensive for prospective buyers, and the uncertainty of the budget struggle in Washington. John Stumpf, the chairman and CEO of Wells Fargo said that “home price appreciation remains strong and affordability remains excellent.” Mr. Strum has “guarded optimism” over the effects of the budget struggle. Read the court decision
Read the full story...
Reprinted courtesy of

Will Colorado Pass a Construction Defect Reform Bill in 2016?

December 17, 2015 — Beverley BevenFlorez-CDJ STAFF
According to blogger Jill Jamieson-Nichols of the Colorado Real Estate Journal, another construction defects bill may be debated in Colorado next year. Representative Dan Pabon told Jamieson-Nichols that “the answer lies in ‘thinking about the insurance piece’ so condominium developers can afford insurance against litigation that might arise.” She also stated that the city of Denver is considering ways to increase funding to increase affordable housing in the area. Read the court decision
Read the full story...
Reprinted courtesy of

Construction Defect Lawsuit Came too Late in Minnesota

June 28, 2013 — CDJ STAFF
The Minnesota Court of Appeals has upheld a summary judgment in a construction defect case, Lee v. Gorham. Minnesota law requires that contractors warranty that the home will be free of major construction defects during the first ten years, but claims must “be brought within two years of the discovery of the breach.” The Lees received a home inspection report in 2009 that identified a variety of defects, including “several possible structural defects.” The court noted that the report stated, “Contact your builder in writing of the findings, and discuss your options with an attorney.” The Lees contacted the contractor, Gorham Builders. After initial silence, Gorham told the Lees that problems would “have to be ‘turned over to [the] insurance company.’” Rodney noted in his testimony that he had two choices, to either sue Gorham or hire an outside contractor. Mr. Lee had concluded that the legal costs were likely to be equal to the cost of the contractor. In June, 2011, the Lees changed their mind about bringing a suit. Gorham sought and received a summary judgment dismissing the case on the grounds that too much time had passed since the Lees learned of the construction defect. The Lees appealed. The appeals court upheld the summary judgment. The Lees claimed that the 2009 home inspection did not alert them of a “major construction defect,” but the court concluded that the language of the report fit within the Minnesota statutory definition of a “major construction defect.” Nor was the appeals court convinced that at any time did Gorham provide “assurances that it would cure the defects to the home.” Within the same month as the May 2009 inspection, Gorham had made it clear that any problems were an issue for the insurance company. Thus, the appeals court concluded that the Lee’s equitable-estoppel argument was without merit. The Lees also brought to appeal the new argument that they did not realize they were dealing with “major construction defects” until they received a subsequent home inspection in 2011. The court noted that the second report does not detail “new defects or structural issues not identified in the 2009 inspection report.” In addition to being “without merit,” the court noted that this claim was not made in the district court and so the appeals court “need not consider this issue on appeal.” Read the court decision
Read the full story...
Reprinted courtesy of

Before and After the Storm: Know Your Insurance Rights, Coverages and Obligations

October 04, 2021 — Hunton Insurance Recovery Blog
This year, like last, the National Oceanic and Atmospheric Administration predicts an extremely active hurricane season. As we write this alert, the Gulf Coast, Mid-Atlantic, New York, and New England regions are just now realizing the devastation Ida has left in her path. Now is the time to ensure your insurance program is hurricane-ready. In this client alert, our insurance coverage team provides critical steps that you should take now to ensure that you protect your assets and maximize recovery in the unfortunate event of a hurricane claim. Know Your Coverage: What Does Your Policy Say and Where Can It Be Found? Obtain copies of your relevant property insurance forms and read them now. Knowing your coverage, even on a general level, will help you anticipate the immediate steps to take following a loss, including how to notify your insurer of losses to your covered property. Read the court decision
Read the full story...
Reprinted courtesy of Hunton Andrews Kurth

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES