How the Cumulative Impact Theory has been Defined
November 30, 2020 —
David Adelstein - Florida Construction Legal UpdatesLargely in the federal contract arena, there is a theory referred to as “cumulative impacts” used by a contractor to recover unforeseeable costs associated with a multitude of changes that have an overwhelming ripple effect on its efficiency, particularly efficiency dealing with its original, base contract work. In other words, by dealing with extensive changes, there is an unforeseeable impact imposed on the contractor relative to its unchanged or base contract work. Under this theory, the contractor oftentimes prices its cumulative impact under a total cost approach with an examination on its cost overrun. However, this is not an easy theory to prevail on because there needs to be a focus on the sheer number of changes, causation supporting the impact, and whether there were concurrent impacts or delays that played a role in the ripple effect. See, e.g., Appeals of J.A. Jones Const. Co., ENGBCA No. 6348, 00-2 BCA P 31000 (July 7, 2000) (“However, in the vast majority of cases such claims are routinely denied because there were an insufficient number of changes, contractor-caused concurrent delays, disruptions and inefficiencies and/or a general absence of evidence of causation and impact.”).
To best articulate how the cumulative impact theory has been defined, I want to include language directly from courts and board of contract appeals that have dealt with this theory. This way the contractor knows how to best work with their experts with this definition in mind–and, yes, experts will be needed–to persuasively package and establish causation and damages stemming from the multitude of changes. While many of these definitions are worded differently, you will see they have the same focus dealing with the unforeseeable ripple effect of the extensive changes.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Jury's Verdict for Loss Caused by Collapse Overturned
September 18, 2023 —
Tred R. Eyerly - Insurance Law HawaiiThe Florida Court of Appeal overturned the jury's verdict findng loss caused by collapse. Universal Prop. & Cas. Ins. Co. v. Caboverde, 2023 Fla. App. LEXIS 4474 (Fla. Ct. App. June 28, 2023).
The insured homeowners had two claims. One was a 2016 ceiling collapse; the second was loss caused by Hurricane Irma in 2019. The homeowners' policy covered collapse defined as "an abrupt falling down or caving in of a building or any part of a building with the result that the building . . . cannot be occupied for its intended purpose." Collapse had to be caused by, among other things, decay or insect damage that was hidden from view.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Adaptive Reuse: Creative Reimagining of Former Office Space to Address Differing Demands
March 27, 2023 —
Cait Horner, Allan C. Van Vliet & Adam J. Weaver - Gravel2Gavel Construction & Real Estate Law BlogEmpty office buildings downtown. A housing shortage in almost every major market. Is there a way to address both issues at once by converting historic but underutilized office buildings into apartments and condos in city centers? It’s an idea that has been discussed, and in some cities, implemented in recent years. But while the idea seems simple enough—repurpose existing office space for residential and mixed-use projects—there are some real challenges limiting the feasibility of large-scale office to residential conversion.
The commercial real estate market is facing an uncertain future. Even as some companies have started requiring that their workers return to the office, many continue to operate under their hybrid or fully remote working models, which companies may commit to permanently. And while some big cities have seen office occupancy levels increase in the past few months (CBRE notes that Austin and Houston both saw occupancy levels above 60% in January, up around 25% from 2022 levels), the ongoing impact of COVID-19 and uncertainty in the global financial markets are keeping many office buildings empty in major cities around the country. Those tenants who are returning to the office are focusing their search for office space on high-quality, sustainable, amenity-filled spaces to entice workers to return to the office. This flight to quality leaves some older and, in many cases, architecturally relevant, office buildings behind. As a result, there are growing opportunities for the potential adaptive reuse of these existing underutilized structures.
Reprinted courtesy of
Cait Horner, Pillsbury,
Allan C. Van Vliet, Pillsbury and
Adam J. Weaver, Pillsbury
Ms. Horner may be contacted at cait.horner@pillsburylaw.com
Mr. Van Vliet may be contacted at allan.vanvliet@pillsburylaw.com
Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of
The Project “Completion” Paradox in California
April 06, 2016 —
Garret Murai – California Construction Law BlogWe’ve written before about why the date of “completion” on a California construction project is important, and why, if I may be blunt, determining that date can be as frustrating as a one-legged man in a game of kickass.
You see, in California the deadline to record a mechanics lien, serve a stop payment notice, or make a payment bond claim – important construction payment remedies the California State Legislature saw fit to help you get paid – often depends on when a project is “completed.” So, for example, the deadline for direct contractors to record a mechanics lien is 90 days from completion of the project.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
When Construction Defects Appear, Don’t Choose Between Rebuilding and Building Your Case
October 11, 2021 —
Curtis Martin - ConsensusDocsWhen construction defects occur during construction, they intensify pressure from a schedule that may already be tight. Defects must be analyzed, confirmed, removed, and replaced and this can be time consuming. Or course, a construction schedule rarely anticipates defects, demolition, and rework and the owner will still expect the project to be completed on time; however, pressing forward with immediate remediation may have unintended consequences.
Before starting demolition, consider the evidentiary doctrine of spoliation. Spoilation occurs when a party destroys or unreasonably deprives another party of evidence and courts have imposed sanctions on a party that deprives an opponent of evidence. The doctrine has historically concerned documents, but its application has extended to electronic data, and courts also apply it to building conditions in construction defects cases. So, before tearing out or fixing defective work, consider the need to allow the opposing party to inspect, test and document it.
Imagine this scenario. The concrete in a slab placed by your subcontractor shows low compressive strength results in the 28-day cylinder tests. Tearing out the slab and replacing it will put you at least a month behind schedule and you don’t want to waste any time before removing and replacing it. Nevertheless, while you’re rebuilding the defective slab, be mindful that you are also building a case. If you plan to recover the costs you incur because of the defective concrete from the responsible parties, you should allow the subcontractor (and possibly the concrete supplier and other implicated parties) to examine, preserve, and/or test the work in question. Failure to do so may subject you to spoliation sanctions and jeopardize your right to recover damages.
Read the court decisionRead the full story...Reprinted courtesy of
Curtis Martin, Peckar & AbramsonMr. Martin may be contacted at
cmartin@pecklaw.com
Factual Issues Prevent Summary Judgment Determination on Coverage for Additional Insured
May 01, 2014 —
Tred R. Eyerly – Insurance Law HawaiiNumerous factual issues prevented the court from deciding at the summary judgment stage whether the additional insured was covered for a personal injury claim that happened on a construction site. Paynes Cranes v. Am States Ins. Co., 2014 U.S. Dist. LEXIS 40485 (E.D. N.Y. March 26, 2014).
Intermetal Fabricators, Inc. hired Paynes to provide a crane and driver for the construction of a store. A construction worker was injured while working with the crane. The injured worker sued several defendants, including Paynes.
Intermetal had coverage for the project that included additional insureds. The policy provided, “Any person or organization . . . for whom you [Intermetal] are required by written contract, agreement or permit to provide insurance is an insured, subject to the following additional provisions: a. The contract, agreement or permit must be in effect during the policy period . . . and must have been executed prior to the ‘bodily injury,’ ‘property damage,’ 'person and advertising injury.’”
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
What to Expect From the New Self-Retracting Devices Standard
November 29, 2021 —
Andre Pelland - Construction ExecutiveOne of the latest and most anticipated changes to occur this year relevant to fall protection is the publishing of the ANSI/ASSP Z359.14 2021 revision. Although the effective date isn’t until August 2022, this change is prompting the need for end user to prepare for using and understanding the new terminology performance requirements that will ultimately alter equipment selection criteria.
The reason for its relevance is mostly due to its industry dependence and the increasing popularity of these types of devices. This voluntary consensus standard accounts for a vast portion of the fall protection market equipment and has been adopted as the industry standard, even though it is not the legal requirement. To assure a smooth transition, the immediate priority should be to understand the changes and what it means from a usability standpoint. A clear understanding of what changes devices need to comply will allow users to proceed with a comprehensive transition plan.
What Are the Most Relevant Changes for the User?
Classes
The most significant changes are for Class A and B devices used to designate arrest distances and forces and the introduction of the Class 1 and 2 devices. These classes were known as designators for arresting falls at 24 inches and under with higher forces (Class A), and 54 inches and under with lower forces (Class B). Class 1 devices allow anchoring on overhead anchorages only and limitg freefall to no more than two feet.
Reprinted courtesy of
Andre Pelland, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Pelland may be contacted at
andre.pelland@puresafetygroup.com
New WA Law Caps Retainage on Private Projects at 5%
May 29, 2023 —
Brett M. Hill & Ryanne S. Mathisen - Ahlers Cressman & Sleight PLLCThis month, Governor Jay Inslee signed into law a new statute that caps retainage on private construction projects to five percent (5%), provides a mechanism for subcontractors to get paid their retainage prior to project completion, and allows for contractors and subcontractors to post a retainage bond and get paid their retainage early. For those interested in reading the full text of this new law, the statute can be found
here.
The new statute goes into effect on July 23, 2023. Under the statute, when a contractor or subcontractor considers their work under a contract subject to retainage complete, they may notify the party they contracted to perform the work for. Within 15 days of receiving the notice of completion of work, the party receiving the notice must respond with either (1) notice of acceptance of work or (2) notice of uncompleted items to the contractor or subcontractor.
If the party receiving notice does not provide notice of uncompleted items within 15 days or fails to respond to the notice of completion entirely, the unpaid retainage will begin to accrue interest at a rate of one percent (1%) per month, 30 days after the initial 15-day period. However, this interest will not accrue against a contractor who has not been paid the retainage by an upper-tier contractor or owner until payment has been received, so long as that contractor has submitted its subcontractor’s notice of completion to the upper-tier contractor or owner within 30 days of receipt.
Reprinted courtesy of
Brett M. Hill, Ahlers Cressman & Sleight PLLC and
Ryanne S. Mathisen, Ahlers Cressman & Sleight PLLC
Mr. Hill may be contacted at brett.hill@acslawyers.com
Ms. Mathisen may be contacted at ryanne.mathisen@acslawyers.com
Read the court decisionRead the full story...Reprinted courtesy of