Fairfield Connecticut Building Expert Directory

Appraiser Declarations Inadmissible When Offered to Challenge the Merits of an Appraisal Award

March 14, 2018 — Valerie Moore and Christopher Kendrick - Publications & Insights
In Khorsand v. Liberty Mutual Fire Ins. Co. (No. B280273, filed 2/27/18), a California appeals court affirmed an appraisal award favorable to a homeowners insurer, ruling that it was improper to admit as evidence in opposition to a petition to confirm the award a declaration from the policyholders’ appraiser, except for the limited purpose of showing improprieties in the appraisal, bias, partiality or other improper conduct. The homeowners had a pipe leak and submitted a claim. The insurer responded to an estimate from the owners’ adjuster by retaining an expert and paying an undisputed amount that was significantly less. Eleven months later the owners had upper deck damage and submitted another claim. Relying on the same expert, the insurer paid another undisputed amount significantly less than the owner’s estimate. The owners requested appraisal but the insurer denied the request, contending that the dispute was over coverage and outside the scope of appraisal. The owners’ petition for appraisal was granted, with the court ordering separate listing of items the insurer disputed regarding coverage or causation. The appraisal panel issued an award stating that total damage was $132,293, of which $96,530 was contested by the insurer. The insurer filed a petition to confirm the award, which was granted despite the fact that the owners’ appraiser had refused to sign it. Reprinted courtesy of Valerie Moore, Haight Brown & Bonesteel LLP and Christopher Kendrick, Haight Brown & Bonesteel LLP Ms. Moore may be contacted at vmoore@hbblaw.com Mr. Kendrick may be contacted at ckendrick@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Wisconsin Supreme Court Upholds Asbestos Exclusion in Alleged Failure to Disclose Case

January 22, 2014 — Beverley BevenFlorez-CDJ STAFF
In the case Phillips v. Parmelee, the Wisconsin Supreme court ruled “that an asbestos exclusion in a liability policy barred a duty to defend and indemnify a building seller for claims that the seller failed to disclose that the building contained asbestos,” according to an article in Mondaq by Ruth S. Kochenderfer and Deanna P. Cook, both from Steptoe & Johnson LLP. The policyholder received a building report stating that the “heating ducts likely contained asbestos,” however, the buyers alleged that the policyholder never provided them the report. After the buyers purchased the property, contractors “cut through the heating ducts, unknowingly dispersing asbestos throughout the building.” According to Kochenderfer and Cook’s article, “The insurer intervened in the buyers' suit and sought summary judgment against the policyholder and buyers, arguing that an asbestos exclusion precluded coverage for the buyers' suit against the policyholder.” The buyers took the case to the Wisconsin Supreme court and “attacked the asbestos exclusion,” but the court rejected every argument. Kochenderfer and Cook stated that the “decision is significant because three courts, including Wisconsin's highest court, squarely rejected attempts to narrow a broad, clearly-worded asbestos exclusion. Further, it confirms that such an asbestos exclusion will apply to all causes of action, including an alleged failure to disclose the presence of asbestos.” Read the court decision
Read the full story...
Reprinted courtesy of

Fla. Researchers Probe 'Mother of All Sinkholes'

August 24, 2017 — Thomas F. Armistead - Engineering News-Record
It will take months to complete remediation of the largest sinkhole in Pasco County, Fla.’s recent history, county officials say. Seven houses have been lost or condemned since the sinkhole was reported at 7:21 a.m. on July 14. That day, two houses collapsed into the hole, which initially measured 225 ft long and 50 ft deep. As the cavity’s dimensions grew to between 260 ft and 180 ft, the county red-tagged five additional houses. Read the court decision
Read the full story...
Reprinted courtesy of Thomas F. Armistead, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Last, but NOT Least: Why You Should Take a Closer Look at Your Next Indemnification Clause

March 09, 2020 — Aimee Cook Oleson - Construction & Infrastructure Law Blog
Indemnification clauses appear in nearly every agreement, but they are often overlooked as mere boilerplate provisions after the parties have painstakingly negotiated all of the other terms. It is not uncommon for parties to simply re-use the indemnity language from a prior agreement without considering whether it is a good fit for their current project. This can be a big mistake that may lead to ambiguities and uncertainties if a dispute arises down the road. A standard or canned indemnification clause might work to undo all of the effort that has gone into properly allocating risk. These clauses often contain language such as “notwithstanding anything to the contrary herein,” or the like, which can alter and override other provisions in the agreement. Indemnification clauses are arguably the most important part of an agreement when an accident or dispute arises on a project. Therefore, they deserve an extra look before finalizing an agreement. Here are a few issues to keep in mind when reviewing your next indemnification clause:

Have you included all necessary parties?

Any party who could face potential liability should be included as an indemnified party. This often includes entities and persons related to the contracting parties, not just the parties themselves.
A well drafted indemnity clause will ensure that all parties are liable for the result of their own work and negligence and that of any party that they have hired to work on a project. This includes employees, agents, subcontractors, or any other similar party.

Read the court decision
Read the full story...
Reprinted courtesy of Aimee Cook Oleson, Sheppard Mullin
Ms. Oleson may be contacted at AOleson@sheppardmullin.com

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Trump Tower Is Now One of NYC’s Least-Desirable Luxury Buildings

July 08, 2019 — Shahien Nasiripour - Bloomberg
Trump Tower, once the crown jewel in Donald Trump’s property empire, now ranks as one of the least desirable luxury properties in Manhattan. The 36-year-old building has been turned into a fortress since Trump won the presidency, ringed with concrete barriers and the two main entrances partially blocked off. It hasn’t been substantially updated in years. And Trump’s name has been a huge turnoff in liberal New York City. For anyone who owns a unit in the tower, the past two years have been brutal. Most condo sales have led to a loss after adjusting for inflation, property records show. Several sold at more than a 20% loss. By contrast, across Manhattan, just 0.23% of homes over the past two years sold at a loss, according to real-estate data provider PropertyShark, although the firm doesn’t adjust for inflation. Read the court decision
Read the full story...
Reprinted courtesy of Shahien Nasiripour, Bloomberg

California Case Adds Difficulties for Contractors & Material Suppliers

August 20, 2014 — Beverley BevenFlorez-CDJ STAFF
Garret Murai in his California Law Blog declared that “things just got a lot tougher for contractors and material suppliers in the Golden State.” In his blog, Murai analyzed the recent case Golden State Boring & Pipe Jacking, Inc. v. Eastern Municipal Water District, Case No. E054618 (July 23, 2014), in which “the California Court of Appeals for the Fourth Appellate District found that a subcontractor’s public works payment bond claim was time barred because its stop payment notice was served ‘before’ a notice of completion was recorded.” Murai explained the importance of the ruling and how it changed the status quo: “Whereas before, it was commonly understood that you could serve a stop payment notice ‘during’ construction (after all, that was the point wasn’t it, to stop construction funds before they are paid out), now you may have only have a 30 day window (probably less) to serve a stop notice within 30 days after a notice of completion or notice of cessation is recorded.” Read the court decision
Read the full story...
Reprinted courtesy of

Surety’s Several Liability Under Bonds

March 20, 2023 — David Adelstein - Florida Construction Legal Updates
When a payment or performance bond is issued on behalf of its bond-principal, the surety is jointly and severally liable with its bond-principal. This means the surety has several liability under the bond, i.e., you don’t need to pursue the principal of the bond to pursue liability under the bond, which is a separate written intrument. Thus, if you are claiming damages of $500,000, by way of example, you can sue both the principal and surety under the bond, you can ONLY sue the principal under the bond (which is rarely practical), or you can ONLY sue the surety under the bond (which, oftentimes, is very practical). In many instances where I am pursuing a bond claim on behalf of a client, particularly a payment bond claim, I only sue the surety and do not sue the bond-principal unless there are certain strategic reasons in doing so. This is because of the surety’s several liability under the bond and there may be solvency issues with the principal or contractual reasons that, strategically, make much more sense to exclude the principal from the action. In MJM Electric, Inc. v. National Union Fire Ins. Co. of Pittsburgh, PA, 2023 WL 2163087 (M.D.Fla. 2023), an electrical subcontractor was hired to perform electrical work by the prime contractor. The prime contractor had a payment bond. The project was delayed for two years. The electrical subcontractor claimed the prime contractor failed to compensate it for significant delays and out of scope work. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES