Important Information Regarding Colorado Mechanic’s Lien Rights.
November 07, 2012 —
David McLain, Colorado Construction LitigationWith payment problems in the construction economy having accelerated over the past few years, there has been a substantial increase in mechanic’s lien activity and associated litigation. The typical mechanic’s lien claimant is a material supplier, a trade subcontractor, or even a general contractor that has not been paid by the developer/owner of the construction project. The reason for filing a mechanic’s lien claim is that it offers the prospect in many cases to make the unpaid construction professional a priority creditor, with a lien on the real estate that is superior to the construction lender.
One of the primary rules governing a mechanic’s lien claim is that the creditor’s formal written “Notice of Intent to File a Mechanic’s Lien” (hereafter “Lien Notice”) must be (1) served on the owner of the property for which the work was done or the materials used, and (2) served at the same time on the general contractor who has handled the construction project. After the creditor has made service of the lien claim by USPS certified mail (using the green return receipt card for proof of service) or separate personal delivery of the notice to the property owner and general contractor, ten full days must pass (not including the date of mailing of the notices) before the lien notice is filed in the public records.
After ten days have expired following the date of mailing using certified mail, or personal delivery of the notice to the property owner and the general contractor, the lien notice can be filed to make the lien valid.
Read the court decisionRead the full story...Reprinted courtesy of
David M. McLain, Higgins, Hopkins, McLain & Roswell, LLC.Mr. McLain can be contacted at
mclain@hhmrlaw.com
Distressed Home Sales Shrinking
October 22, 2014 —
Beverley BevenFlorez-CDJ STAFFAccording to Molly Boesel in CoreLogic, “Distressed sales (REO and short sales) accounted for 11.2 percent of total home sales in August 2014, the lowest share since December 2007 and a strong improvement from the same time a year ago when this category made up 15 percent of total sales.”
Michigan had the largest amount of distressed sales, with 25.5 percent in August, while California “saw the largest improvement from peak distressed sales share of any state, falling 55.3 percent from the January 2009 peak share of 67.4 percent.”
Read the court decisionRead the full story...Reprinted courtesy of
Potential Coverage Issues Implicated by the Champlain Towers Collapse
March 21, 2022 —
Theresa A. Guertin & Holly A. Rice - Saxe Doernberger & Vita, P.C.In June 24, 2021, the Champlain Towers South in Surfside, Florida collapsed, killing nearly 100 individuals (the “Collapse”). As experts uncover more information regarding the cause of the Collapse, those individuals who have filed lawsuits as well as the potentially culpable defendants are looking to insurers for coverage of their bodily injury and property damage claims.
Contractors, engineers, and other professionals are or anticipate being sued for their roles in the Collapse. Those professionals have professional liability policies and/or director and officer liability policies. Likewise, the condominium association’s commercial general liability (CGL) policies and its business property policy may have a duty to defend and/or indemnify their insureds as well. Finally, individual unit owners/renters may look to their homeowners’ insurance, auto insurance, health insurance, and/or life insurance policies for coverage.1
The potential breadth of insurance coverage issues raised by the Collapse is beyond the scope of this article. The article will consider some concerns that could impact insurance coverage under a standard CGL policy in the case of a building collapse.
Reprinted courtesy of
Theresa A. Guertin, Saxe Doernberger & Vita, P.C. and
Holly A. Rice, Saxe Doernberger & Vita, P.C.
Ms. Guertin may be contacted at TGuertin@sdvlaw.com
Ms. Rice may be contacted at HRice@sdvlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Construction Termination Part 2: How to Handle Construction Administration When the Contractor Is Getting Fired
August 01, 2023 —
Melissa Dewey Brumback - Construction Law in North CarolinaIf you’ve been working as a design professional for any length of time, you know that you must be a chameleon on the construction project. You need to “step into the skin” of both the Owner and the Contractor to determine who is at fault, and who should pay.
You are usually the Initial Decision Maker (IDM), and so you have a duty under the AIA documents to act fairly and impartially in making those decisions. See AIA B101§3.6.2.4.
Even if you are not under an AIA contract, you still have that duty if you are the IDM or handling construction administration for the project. More often than not, however, it will be the owner asking you to support its termination of the contractor “for cause.”
Should you do so?
Read the court decisionRead the full story...Reprinted courtesy of
Melissa Dewey Brumback, Ragsdale LiggettMs. Brumback may be contacted at
mbrumback@rl-law.com
Clearly Determining in Contract Who Determines Arbitrability of Dispute
April 26, 2021 —
David Adelstein - Florida Construction Legal UpdatesAs you know from prior postings: “Arbitration provisions are creatures of contract and must be construed ‘as a matter of contract interpretation.’ ” Fallang Family Limited Partnership v. Privcap Companies, LLC, 46 Fla.L.Weekly D639e (Fla. 4th DCA 2021) (citation omitted). Thus, if you prefer to arbitrate potential disputes, instead of litigating potential disputes, you want to include an arbitration provision in your contract. While there are positives and negatives to arbitration, no different than litigation, these positives and negatives should be considered during the contract negotiation process when dealing with the dispute resolution process in the contract.
Generally, under the law, the arbitrability of a dispute is determined by the court. However, this can be deferred to the arbitrator with clear and unmistakable language in the contract.
By way of example, the American Arbitration Association includes a rule that allows an arbitrator to rule on the arbitrability of the dispute, i.e., the claims asserted are subject to the governing arbitration provision in the contract. Recent law has suggested that if the objective is to authorize an American Arbitration Association arbitrator to make this determination, the contract clearly and unmistakably needs to state this intent and generally referring to the American Arbitration Association rules is not good enough. For this reason, I have included in arbitration provisions language that specifically states, “In the event of any dispute as to the arbitrability of any claim or dispute, the parties agree that an appointed arbitrator within the American Arbitration Association shall make this determination.” I have also included in arbitration provisions the converse so that if there is a dispute as to the arbitrability of a claim or dispute, the court, and not the arbitrator, will make this determination.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
California Commission Recommends Switching To Fault-Based Wildfire Liability Standard for Public Utilities
June 25, 2019 —
Lawrence J. Bracken II, Sergio F. Oehninger, Paul T. Moura & Alexander D. Russo - Hunton Insurance Recovery BlogA state-appointed panel advised last week that California should change the standard for determining whether utilities are liable for wildfires. Under the current system, California’s Public Utilities Code § 2106 provides a private right of action by any person or entity that has suffered loss, damages, or injury caused by prohibited or unlawful acts of a public utility. Relying on this statute, property owners have asserted wildfire-related claims directly against allegedly culpable electric utility companies. Public utilities in California also face inverse condemnation claims arising out of wildfires. Under inverse condemnation, where private property is taken for public use and later damaged by the state or its agency, the state or agency is strictly liable to the property owner.
In an effort to reduce the financial impact on public utilities resulting from wildfires—as exemplified by Pacific Gas and Electric Co.’s recent filing for Chapter 11 protection in January—the California Commission on Catastrophic Wildfire Cost and Recovery recommended changing the current laws to reflect a fault-based standard. According to the panel, this change would reduce the risk of bankruptcy and decrease the cost of capital. The commission also recommended establishing a wildfire victims’ fund and setting up an electric utility wildfire board to handle the prevention and mitigation of utility-related wildfires.
Reprinted courtesy of Hunton Andrews Kurth attorneys
Lawrence J. Bracken II,
Sergio F. Oehninger,
Paul T. Moura and
Alexander D. Russo
Mr. Bracken may be contacted at lbracken@HuntonAK.com
Mr. Oehninger may be contacted at soehninger@HuntonAK.com
Mr. Paul may be contacted at pmoura@HuntonAK.com
Mr. Alexander may be contacted at arusso@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Did You Get a Notice of Mechanic’s Lien after Project Completion? Don’t Panic!
October 20, 2016 —
Christopher G. Hill – Construction Law MusingsSo, you own a piece of property. You decided to have some work done and after what you thought was proper due diligence, you hire a general contractor to build a great office building on the property. Your architect designs the space, you sign the construction contract for a price you find fair and that the bank approves. Construction starts and with a few minor hiccups, a couple of written changes and one minor but slightly annoying change required by the local building inspector, completes relatively on schedule. You write the final check to the general contractor for its final draw and start the process of leasing the space out. All is right with the world as best you can tell.
A month later, you walk to your mailbox and lo and behold, you have a certified mailing containing a notice that the plumbing subcontractor has recorded a mechanic’s lien on your property. After counting to 10 to let the various emotions pass, you call the general contractor to see what is going on. You’re told that there is a dispute regarding a change order about which you knew nothing and that the general contractor feels it is in the right and should not have to pay the money represented in the memorandum of lien so it won’t be paying the subcontractor unless and until it is told to do so by a court or an arbitrator.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, The Law Office of Christopher G. Hill, PCMr. Hill may be contacted at
chrisghill@constructionlawva.com
Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com