Seattle Washington Building Expert Directory

Constructive Suspension (Suspension Outside of an Express Order)

December 13, 2022 — David Adelstein - Florida Construction Legal Updates
In the federal procurement arena, there is a concept known as “constructive suspension.” Constructive suspension, while known in the federal arena, should reasonably apply to all projects when work is stopped outside of an express order to stop the work based on the law below. An unreasonable suspension is an unreasonable suspension and an express order to stop the work does not negate the effects of what really amounts to a suspension. “Constructive suspension occurs when work is stopped absent an express order by the contracting officer and the government is found to be responsible for the work stoppage.” P.R. Burke Corp. v. U.S., 277 F.3d 1346, 1359 (Fed. Cir. 2002). The government delay must be unreasonable to support a constructive acceleration claim. Id. “To demonstrate such a constructive suspension of work, the contractor must show that the delay (1) was for an ‘unreasonable length of time,’ (2) was proximately caused by the government’s actions, and (3) resulted in some injury to the contractor.” Fireman’s Fund Ins. Co. v. U.S., 2001 WL 36415627, *6 (Fed.Cl. 2001) (citation omitted). “Relative to proving that the delay was directly caused by the government, the contractor must concomitantly show that it was not delayed by any concurrent cause that would have independently generated the delay during the same time period even if it does not predominate over the government’s action as the cause of the delay.” Beauchamp Const. Co. v. U.S., 14 Cl.Ct. 430, 437 (Cl.Ct. 1988). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

The “Unavailability Exception” is Unavailable to Policyholders, According to New York Court of Appeals

September 10, 2018 — William S. Bennett & Warsame Y. Hassan - Saxe Doernberger & Vita, P.C.
The New York Court of Appeals recently upheld a prior appellate division decision finding that policyholders facing environmental claims, spanning multiple years, cannot force their insurers partially on the risk to provide coverage for years where the insurers did not issue policies, even though pollution insurance was unavailable in the marketplace. In Keyspan Gas E. Corp. v. Munich Reins. Am., Keyspan Gas East Corporation (“Keyspan”) argued other insurers should cover the period when pollution property insurance was unavailable in the marketplace, according to their pro-rata share of coverage. 31 N.Y.3d 51 (2018). In a unanimous decision, the Court emphasized the Appellate Division’s prior ruling that stated, “spreading risk should not by itself serve as a legal basis for providing free insurance to an insured.” Read the court decision
Read the full story...
Reprinted courtesy of William S. Bennett, Saxe Doernberger & Vita, P.C.
Mr. Bennett may be contacted at wsb@sdvlaw.com

Guarantor’s Liability on Partially Secured Debts – The Impacts of Pay Down Provisions in Serpanok Construction Inc. v. Point Ruston, LLC et al.

October 24, 2021 — Margarita Kutsin - Ahlers Cressman & Sleight
In Serpanok Construction, Inc. v. Point Ruston, LLC, Division Two of the Washington Court of Appeals decided an issue of first impression in Washington—whether a guarantor of a partially secured debt remains liable until the last dollar of the entire debt is paid off. After examining cases from other jurisdictions, the court held that that a guarantor is liable until the underlying debt is paid in full unless the agreement contains an express pay down provision. A pay down provision sets forth the guarantor’s right to reduce its obligation to the extent of any payment toward the debt, and it establishes that the guaranty applies only until an amount equivalent to the guaranteed amount is paid off. The Serpanok decision addressed several other issues, but the published portion of this part-published case focused on whether an entity involved in a real estate development, Point Ruston LLC, was discharged from its guaranty obligation following a foreclosure sale where the proceeds did not cover the entire debt owed to a subcontractor. Point Ruston LLC, Point Ruston Phase II LLC (“Phase II”), and Century Condominiums (“Century”) were affiliated entities (collectively “Point Ruston parties”) that constructed retail and residential structures on a site in Point Ruston. Serpanok Construction Inc. (“Serpanok”) entered into subcontract agreements with Phase II and Century to perform concrete and steel work on a parking garage and movie theater for the project. Point Ruston LLC was not a party to either subcontract. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

Quick Note: Independent Third-Party Spoliation Of Evidence Claim

June 18, 2019 — David Adelstein - Florida Construction Legal Updates
In an earlier posting I discussed the difference between first-party spoliation of evidence and third-party spoliation of evidence. There is NO independent cause of action for first-party spoliation of evidence because that can be dealt with directly in the underlying lawsuit. This deals with the assertion that an actual party to a lawsuit spoiled evidence. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

JPMorgan Blamed for ‘Zombie’ Properties in Miami Lawsuit

June 18, 2014 — Christie Smythe – Bloomberg
JPMorgan Chase & Co. (JPM) engaged in a “pattern of discriminatory” lending that led to foreclosures, the city of Miami said in a lawsuit filed last week in federal court, the latest in a series of similar claims against the nation’s largest banks. Last month, Banco Santander SA’s (SAN) U.S. unit was sued by the city of Providence, Rhode Island, over claims it stopped issuing mortgages in minority neighborhoods after the housing bubble burst. Santander Bank, previously named Sovereign Bank, pulled out of the neighborhoods and focused on white communities after being acquired by the Madrid-based lender in 2009, the city alleged. Miami and Los Angeles are among cities to have filed similar lawsuits against Bank of America Corp., Citigroup Inc. (C) and Wells Fargo & Co. (WFC) for allegedly “red-lining” black and Hispanic areas as no-loan zones, and then “reverse red-lining,” flooding the areas with predatory mortgages even when minorities qualified for better terms. Read the court decision
Read the full story...
Reprinted courtesy of Christie Smythe, Bloomberg
Ms. Smythe may be contacted at csmythe1@bloomberg.net

Meet Some Key Players in 2020 Environmental Litigation

May 04, 2020 — Ellen M. Gilmer - Bloomberg
U.S. courts are set to take up critical environmental law issues in 2020, with pipeline approvals, wildlife protections, and climate change all on the docket for the new year. Judges will weigh the Trump administration’s deregulatory efforts, the impacts of the president’s promised border wall, and just how far states can go to address climate change. Leading the legal battles are lawyers from private practice, environmental organizations, local governments, and the Justice Department. Here are some of the players in environmental law in 2020. Read the court decision
Read the full story...
Reprinted courtesy of Ellen M. Gilmer, Bloomberg
Ms. Gilmer may be contacted at egilmer@bloombergenvironment.com

New York Public Library’s “Most Comprehensive Renovation” In Its History

May 13, 2014 — Beverley BevenFlorez-CDJ STAFF
Manhattan’s New York Public Library’s renovation plans have been revised after being “the subject of at least three lawsuits and repeated protests by academics, activists, writers and historians,” according to Construction Digital. The previous $300 million plan by Foster & Partners would have required the circulation collections to be relocated during the renovation process. Now, that plan has been abandoned for one that New York Public Library President Anthony Marx calls “the most comprehensive renovation in its history.” “Instead of removing the central stacks and placing the Mid-Manhattan Library in that space, we are proposing to renovate Mid-Manhattan Library at its current site,” Marx told Construction Digital. “This renovation will add much-needed computer labs and an adult education center, and an inspiring, comfortable space for browsing our largest circulating collection.” Read the court decision
Read the full story...
Reprinted courtesy of

Client Alert: Expert Testimony in Indemnity Action Not Limited to Opinions Presented in Underlying Matter

February 18, 2015 — R. Bryan Martin and Kristian B. Moriarty – Haight Brown & Bonesteel, LLP
In National Union Fire Insurance Co. of Pittsburgh Pa. v. Tokio Marine and Nichido Fire Insurance Co. (filed 2/4/2015, B24899 and B247258), the California Court of Appeal, Second District, held that the insurer of Costco Wholesale Corporation, in a subsequent indemnity action, could offer expert opinions which were not developed by the third-party plaintiff’s experts in an underlying dispute. Jack Daer filed suit against Costco and Yokohama Tire Corporation, alleging a tire manufactured by Yokohama (and sold by Costco), was defective and caused an accident resulting in Mr. Daer’s injuries. The case proceeded through expert discovery and depositions. On the first day of trial, Costco settled with Daer for $5.5 million, and Yokohama settled for $1.1 million. Reprinted courtesy of R. Bryan Martin, Haight Brown & Bonesteel LLP and Kristian B. Moriarty, Haight Brown & Bonesteel LLP Mr. Martin may be contacted at bmartin@hbblaw.com, Mr. Moriarty may be contacted at kmoriarty@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES