FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

When is Construction Put to Its “Intended Use”?

July 31, 2013 — Brady Iandiorio, Higgins, Hopkins, McLain & Roswell, LLC
Defining words and phrases in the law can be a tricky proposition. In everyday life one would presume to know what the phrase “intended use” would mean, but when it comes to litigation, oftentimes the definitions become much more nuanced. On March 12, 2013, in the Bituminous Cas. Corp. v. Hartford Cas. Ins. Co. v. Canal Ins. Co., WL 950800 (D. Colo. 2013) case, Senior District Court Judge Wiley Y. Daniel denied Third-Party Defendant Canal Insurance Company’s (“Canal”) motion to dismiss Third-Party Plaintiff Hartford Casualty Insurance Company’s (“Hartford”) third-party complaint. The case arose out of a liability insurance coverage dispute related to an underlying construction defect lawsuit. In the construction defect suit, a plaintiff homeowner’s association brought a suit against a developer and a general contractor (“GC”) among others. While the underlying action was settled, a dispute remained between Bituminous Casualty Corporation, which insured the GC, and Hartford, which insured the developer. Hartford asserted third-party claims against Canal seeking a declaration of Canal’s obligations and contribution in the event Hartford owed any defense or indemnity obligations to the GC. Hartford’s claims are based on the premise that Canal owed a duty to defend and/or indemnify the GC in the underlying action. Read the court decision
Read the full story...
Reprinted courtesy of Brady Iandiorio
Brady Iandiorio can be contacted at Iandiorio@hhmrlaw.com

---

Multiple Occurrences Found For Claims Against Supplier of Asbestos Products

May 07, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court found that various claims for bodily injury against a supplier of asbestos products arose from multiple occurrences, increasing indemnity amounts available under the policy. Westfield Ins. Co. v. Continental Ins. Co., 2015 U.S. Dist. LEXIS 45437 (N.D. Ohio April 7, 2015). Mahoning Valley Supply Company (MVS) was sued by numerous claimants who alleged that they had been injured by asbestos-containing products manufactured by third parties, but supplied by MVS. The claimants alleged exposure to asbestos fibers at a variety of job sites, on numerous dates, and under a variety of conditions. Two insurers shared defense and indemnity costs. In 2013, Continental informed MVS that the three policies issued to MVS were nearly exhausted. Therefore, the parties disputed whether MVS' asbestos claims arose out of a single "occurrence" rather than multiple occurrences. The policies defined "occurrence" as "an accident, including continuous or repeated exposure to conditions, which results in bodily injury or property damage neither expected nor intended from the standpoint of the insured." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Sean Shecter to Join American University Environmental and Energy Law Alumni Advisory Council

November 01, 2021 — Lewis Brisbois
Fort Lauderdale, Fla. (October 6, 2021) – Fort Lauderdale Partner Sean P. Shecter will join his alma mater American University Washington College of Law’s Environmental and Energy Law Alumni Advisory Council, advising on environmental, social, and governance (ESG) related issues and helping support the program. The Program on Environmental and Energy Law (PEEL) provides an interdisciplinary education on domestic environmental, energy, and natural resources law, international and comparative environmental and energy law, environmental and climate justice, and animal law. Its mission is to foster passion for the environment and cultivate legal excellence, cultural competency, and global awareness. “The professors, staff, and members of the PEEL are global leaders in their field, and so it is an absolute privilege to reconnect with my law school so that I can help support this amazing program,” said Mr. Schecter on the invitation. “I am also looking forward to counseling students on issues concerning the accurate reporting of ESG data and the intersection between ESG and my white collar practice.” Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Houston Office Secures Favorable Verdict in Trespass and Nuisance Case Involving Subcontractor’s Accidental Installation of Storm Sewer Pipe on Plaintiff’s Property

June 12, 2023 — Lewis Brisbois Newsroom
Houston, Texas (May 26, 2023) - Houston Partners Joelle Nelson and Matt Begley secured a defense verdict on behalf of a gasoline services company following a four-day trial in the 284th District Court of Montgomery County, Texas. In this case, Lewis Brisbois represented a client who hired a contractor to install a storm sewer line to mitigate flood risks to the client’s property. The contractor, however, deviated from the engineering plans and installed the storm sewer line on a neighboring property owned by the plaintiff. The storm sewer line then remained on the plaintiff’s property for five years while the parties attempted to negotiate potential solutions to the situation. The plaintiff refused multiple reasonable settlement attempts and ultimately sued the client and the contractor for continuous trespass and private nuisance. The contractor’s carrier denied coverage, making the client the target defendant. The matter proceeded to trial. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Pre-Judgment Interest Not Awarded Under Flood Policy

January 17, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The court granted the insurer's motion to dismiss state law and extracontractual claims, including pre-judgment interest. Hurley v. Wright Nat'l Flood Ins. Co., 2022 U.S. Distl. LEXIS 203803 (W.D. La. Nov. 8, 2022). The insured suffered damage from Hurricane Delta. He filed suit, alleging that Wright National Flood Insurance Company breached the Standard Flood Insurance Policy (SFIP). The insured sought damages for state law claims for bad faith, diminution in value, actual repair costs, attorney's fees , litigation costs, and interest. Wright moved to dismiss the extracontractual state law causes of action for bad faith and various claims for damages, other than the damages sought for the alleged breach of the SFIP. The court explained that the Write-Your-Own (WYO) Program carriers issuing flood insurance under the National Flood Insurance Program (NFIP) arranged for the adjustment, settlement, payment, and defense of all claims arising from the policy. Congress underwrote all operations of the NIFP, including claims adjustment, through United States Treasury funds. A judgment against a WYO Program carrier constituted a judgment against FEMA, and consequently, a direct charge on the United States Treasury.  Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

PA Supreme Court to Rule on Scope of Judges' Credibility Determinations

April 20, 2016 — Max Kimbrough – White and Williams LLP
In IA Construction v. WCAB (Rhodes), the Commonwealth Court reversed the WCJ’s decision to deny the employer’s Modification Petition on the basis that the employer’s medical expert was not credible. In the underlying case, the claimant was determined to have sustained compensable work injuries to his head, neck and back. The employer subsequently filed a Modification Petition, seeking to modify benefits to Partial Disability based on an Impairment Rating Evaluation (IRE) which found that the claimant had a 34% whole body impairment. The WCJ ultimately denied the employer’s Modification Petition, finding that the IRE physician's categorization of the claimant's injuries and interpretation of the claimant's impairment level from his brain injury was not credible. Read the court decision
Read the full story...
Reprinted courtesy of Max Kimbrough, White and Williams LLP
Mr. Kimbrough may be contacted at kimbroughm@whiteandwilliams.com

---

Recent Changes in the Law Affecting Construction Defect Litigation

October 19, 2017 — David M. McLain - Colorado Construction Litigation
On May 23, 2017, Governor Hickenlooper signed HB17-1279 into law. The bill states that before an HOA’s executive board can institute a construction defect action, it must provide notice of the anticipated commencement of the action to each of the HOA’s unit owners, along with certain disclosures about the anticipated action. The bill also requires that the HOA executive committee convene a meeting of the unit owners to consider the action, and that the construction professionals against which the claim is being brought have the opportunity to address the members of the HOA. The bill also states that the HOA executive committee may only initiate a construction defect action if it is approved by “owners of units to which a majority of votes in the association are allocated.” Read the court decision
Read the full story...
Reprinted courtesy of David M. McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

---