CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

When Is a Project Delay Material and Actionable?

January 11, 2022 — Rick Erickson - Snell & Wilmer Real Estate Litigation Blog
Welcome to 2022! This year, the construction industry will undoubtedly reflect on the last two years as unprecedented times plagued by construction project delays. The COVID-19 pandemic contributed to suspension of work and closure of construction projects worldwide in 2020. The end of 2021 brought additional delays caused by an inexplicable clog in the supply chain of construction materials. The combined impact of these events on project milestones and completion deadlines led our clients to ask, with unusual and particular urgency, who is liable for such delays and how do contracting parties lessen the consequences from such unexpected and uncontrollable delays. Granted that project delays are nothing new or unusual. They were common enough before inflation caused shipping complications and pandemic decimated the construction labor force. All delays, whatever the source, variably cause loss to all players on a construction project. But not all delays matter when it comes to claims and remedies available to the contracting parties in dispute resolution, where the determinative focus is on material delays impacting the entire project and on delays the claimant can credibly prove. Most, if not all, jurisdictions interpret actionable delays from the contract documents for the project. The contract is definitely where you should start before pursuing any delay remedies. Delay remedies may be a time extension only, or a time extension plus your additional general conditions. Some delay remedies may be barred by the contract’s express terms and may be enforced adversely by the courts when such contract terms are indisputable. See Quinn Constr. v. Skanska USA Bldg., Inc., 730 F. Supp. 2d 401, 411 (D.C. Pa. 2010) (enforcing the subcontractor’s contractual waiver of claims for delay and disruption damages). On the other hand, delay damages that are expressly allowed by the contract—like overtime necessitated by the delays—are usually actionable and recoverable. Id. However, not only the contract terms, but applicable law, may affect the outcome. Read the court decision
Read the full story...
Reprinted courtesy of Rick Erickson, Snell & Wilmer
Mr. Erickson may be contacted at rerickson@swlaw.com

---

A Brief Discussion – Liquidating Agreements

June 27, 2022 — Gerard J. Onorata - Peckar & Abramson, P.C.
During a construction project, it is not uncommon for disputes to arise between a general contractor and a subcontractor. Frequently, these disputes involve claims for extra work and delay damages that can be attributed to the owner of the project due to deficient design or unforeseen conditions. When these occasions arise, the parties can often resolve these claims without the need for litigation or arbitration by entering into a “liquidating agreement.” What is a Liquidating Agreement? Because there is no direct contractual relationship between a subcontractor and an owner, there does not exist a legal basis for a subcontractor to assert a breach of contract claim against a project owner. In legal parlance, this is known as “lack of contractual privity.” A liquidating agreement bridges this contractual gap and allows a subcontractor to pass its claim against the owner through the general contractor. Essentially, with a liquidating agreement, the general contractor acts as a conduit for passing through the subcontractor’s claim. Read the court decision
Read the full story...
Reprinted courtesy of Gerard J. Onorata, Peckar & Abramson, P.C.
Mr. Onorata may be contacted at gonorata@pecklaw.com

---

What is Bad Faith?

April 04, 2022 — Stacy M. Manobianca - Saxe Doernberger & Vita, P.C.
As a policyholder, you may have heard the term “bad faith” in the context of litigation against your insurer. Bad faith in the insurance context is a catch-all term for a broad category of claims that can be brought against your insurer. Bad faith claims are common in insurance coverage litigation, and they can be a powerful tool in a policyholder’s arsenal. This post will serve as an introduction to some basic concepts surrounding bad faith litigation.

Table of Contents
• Bad Faith Defined:
• Statutory vs. Common Law Bad Faith Claims
• Breach of Contract vs. Tort Bad Faith Claims
• Substantive vs. Procedural Bad Faith Claims
• Best Practices Throughout the Claims Process:
• Involve an Experienced Coverage Attorney
• Conclusion

Read the court decision
Read the full story...
Reprinted courtesy of Stacy M. Manobianca, Saxe Doernberger & Vita, P.C.
Ms. Manobianca may be contacted at SManobianca@sdvlaw.com

---

General Contractor Supporting a Subcontractor’s Change Order Only for Owner to Reject the Change

December 09, 2019 — David Adelstein - Florida Construction Legal Updates
The opinion in Westchester Fire Ins. Co, LLC v. Kesoki Painting, LLC, 260 So.3d 546 (Fla. 3d DCA 2018) leads to a worthy discussion because it involves a common scope of work occurrence on construction projects involving a general contractor and subcontractor. The contractor submits a subcontractor’s change order request to the owner and the owner rejects the change order. What happens next is a scope of work payment dispute between the general contractor and subcontractor. Yep, a common occurrence. In this case, a general contractor hired a subcontractor to perform waterproofing and painting. A scope of work issue arose because the specifications did not address how the window gaskets should be cut and then sealed. The owner wanted the window gaskets cut at a 45-degree angle and the subcontractor claimed this resulted in increased extra work. The general contractor agreed and submitted a change order to the owner to cover these costs. The owner rejected the change order claiming it was part of the general contractor’s scope of work even though the cutting of window gaskets at a 45-degree angle was not detailed in the specifications. After the subcontractor filed a suit against the general contractor’s payment bond surety, the project architect further rejected the change order because gasket cutting was part of the specification requirements. (Duh! What else was the architect going to say? It was not going to concede there was an omission that resulted in a change order to the owner, right?) Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Don MacGregor To Speak at 2011 West Coast Casualty Construction Defect Seminar

January 01, 2011 — CDJ STAFF

“Challenges for Experts in Construction Defect Claims and Litigation” will be held Thursday May 13, 2011 between 1:30 and 3:00 PM at this year’s West Coast Casualty Construction Defect Seminar. Among the various topics covered will be of Right to Repair/Opportunity to Repair statutes, improper testing methodologies, new challenges where a case involves a Wrap Policy, OCIPS, CCIPS, and other owner controlled insurance programs, as well as the need for realistic testing protocols for the party the expert is retained to represent.



During the presentation Mr. MacGregor will be working in connection with a group of construction and design experts each of which have extensive experience with construction defect and claims related litigation. This particular session is expected to attract a standing-room only crowd, drawing in excess of 1700 attendees.



The West Coast Casualty Construction Defect Seminar is the largest seminar of its type. This year’s event is scheduled for will take place on May 12 and 13, 2011, at The Disneyland Hotel and Resort. For more information regarding the years event please visit http://www.westcoastcasualty.com/dyncat.cfm?catid=3322

http://www.westcoastcasualty.com/dyncat.cfm?catid=3322 Read the court decision
Read the full story...
Reprinted courtesy of

---

Texas Supreme Court Holds Anadarko’s $100M Deepwater Horizon Defense Costs Are Not Subject To Joint Venture Liability Limits

February 27, 2019 — Sergio F. Oehninger & Michael S. Levine - Hunton Andrews Kurth
Reversing a Texas Court of Appeals decision that allowed Anadarko’s Lloyd’s of London excess insurers to escape coverage for more than $100 million in defense costs incurred in connection with claims from the Deepwater Horizon well blowout, the Supreme Court of Texas held that the insurers’ obligations to pay defense costs under an “energy package” liability policy are not capped by a joint venture coverage limit for “liability” insured. Anadarko Petroleum Corp. et al. v. Houston Casualty Co. et al., No. 16-1013 (Tex. Jan. 25, 2019). While the Lloyd’s of London insurers had agreed to pay Anadarko $37.5 million for damages, they declined to cover $100 million-plus in defense fees, arguing that both Anadarko’s liability and defense expenses are subject to the $37.5 million joint venture limit for “liability” insured. Anadarko asserted that only amounts paid as damages to third parties are subject to that limit. Defense costs, however, are not amounts paid as damages to a third party and, thus, are not a “liability.” Those amounts, therefore, are not subject to the joint venture limit and are instead subject to the policy’s $150 million coverage limit. Reprinted courtesy of Sergio F. Oehninger, Hunton Andrews Kurth and Michael S. Levine, Hunton Andrews Kurth Mr. Oehninger may be contacted at soehninger@HuntonAK.com Mr. Levine may be contacted at mlevine@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Excessive Corrosion Cause of Ohio State Fair Ride Accident

August 10, 2017 — David Suggs – Bert L. Howe & Associates, Inc.
The manufacturer of the Fire Ball ride at the Ohio State Fair claims that excessive corrosion “led to the accident that killed a teenager and injured seven others…in July.” According to a statement by KMG International, reported by ABC News, “Corrosion on the interior of the support beam reduced the beam's thickness, which led to the accident at the fair.” Furthermore, “The company said it conducted an investigation into the incident, which included a visit to the scene and a review of video footage of the incident. The company also conducted a metallurgical inspection of the ride.” A U.S. Consumer Product Safety Commission (CPSC) spokesperson said “it is aware of 22 deaths associated with amusement attractions since 2010, including Wednesday's incident, but excluding water park and work-related fatalities.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Mississippi Floods Prompt New Look at Controversial Dam Project

March 16, 2020 — Autumn Cafiero Giusti - Engineering News-Record
Flooding from the Pearl River in Mississippi has created a renewed sense of urgency for regional flood prevention efforts, with officials set to decide in six months whether to approve a controversial flood control plan, says an attorney for the region’s flood control district. Autumn Cafiero Giusti, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---