Understanding Entitlement to Delays and Proper Support
December 10, 2024 —
Andrew G. Vicknair - The Dispute ResolverIn a previous
post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method.
Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay.
If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay.
Read the court decisionRead the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
Retired Judge Claims Asbestos in Courthouse gave him Cancer
November 05, 2014 —
Beverley BevenFlorez-CDJ STAFFAmos Saunders, retired Passaic County, New Jersey, Superior Court judge claimed "he got cancer as a result of coming into contact with asbestos at the courthouse during his time on the bench," the New Jersey Law Journal reported.
Saunders alleged "that he was exposed to asbestos throughout his tenure, up to and including an asbestos removal project at the Paterson, N.J., courthouse in the 1980s." The complaint filed, as quoted in the New Jersey Law Journal, stated that "he has been diagnosed with adenocarcinoma 'as a direct and proximate result' of 'inhalation and ingestion of dust particles and fibers' from asbestos products."
According to the complaint, A. H. Environment Inc. was the contractor and Alaimo Group was the consulting engineer.
Read the court decisionRead the full story...Reprinted courtesy of
Nine ACS Lawyers Recognized as Super Lawyers – Including One Top 10 and Three Top 100 Washington Attorneys
August 14, 2023 —
Travis Colburn - Ahlers Cressman & SleightOur blog articles usually cover construction-related issues, but Ahlers Cressman & Sleight, PLLC – once again – is honored to announce nine members of our firm were awarded the distinction of being a “Super Lawyer” in Washington.
To become a Super Lawyer, only the top attorneys are nominated by their peers. Once nominated, candidates are researched and evaluated by an independent third-party across twelve key categories, such as experience, honors/awards, verdicts/settlements, and others. Next potential Super Lawyers are evaluated by a highly-credentialed “Blue Ribbon Panel” of peers before final selection. The process is extremely competitive and only 5 percent of the total lawyers in Washington are nominated as Super Lawyers. The following – including one Top 10 and three Top 100 attorneys – are Ahlers Cressman & Sleight, PLLC’s Super Lawyers:
John P. Ahlers, one of the firm’s founding partners, was again recognized as a Top 10 Super Lawyer in Washington State for 2023 – this is his seventh year in a row in the Top 10. A founding member of Ahlers Cressman & Sleight, PLLC, he has been named a Super Lawyer in Construction Litigation since 2001—23 years in a row. To read Mr. Ahlers’ full profile, click
here.
Read the court decisionRead the full story...Reprinted courtesy of
Travis Colburn, Ahlers Cressman & SleightMr. Colburn may be contacted at
travis.colburn@acslawyers.com
Contractual Waiver of Consequential Damages
January 21, 2019 —
David Adelstein - Florida Construction Legal UpdatesContractual waivers of consequential damages are important, whether they are mutual or one-sided. I believe in specificity in that the types of consequential damages that are waived should be detailed in the waiver of consequential damages provision. Standard form construction agreements provide a good template of the types of consequential damages that the parties are agreeing to waive.
But, what if there is no specificity in the waiver of consequential damages provision? What if the provision just states that the parties mutually agree to waive consequential damages or that one party waives consequential-type damages against the other party? Let me tell you what would happen. The plaintiff will argue that the damages it seeks are general damages and are NOT waived by the waiver of consequential damages provision. The defendant, on the other hand, will argue that the damages are consequential in nature and, therefore, contractually waived. FOR THIS REASON, PARTIES NEED TO APPRECIATE WHAT DAMAGES ARE BEING WAIVED OR LIMITED, AND POTENTIALLY THOSE DAMAGES NOT BEING WAIVED OR LIMITED, WHEN AGREEING TO A WAIVER OF CONSEQUENTIAL DAMAGES PROVISION!
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
So You Want to Arbitrate? Better Make Sure Your Contract Covers All Bases
August 16, 2021 —
Stephanie Nolan Deviney - ConsensusDocsAs a General Contractor, you may prefer to arbitrate any contractual disputes rather than engage in protracted litigation. Many Courts favor arbitration clauses and will enforce them if there is a sufficient reason to do so. However, there are several issues that a General Contractor should consider when including an arbitration clause in its construction agreement with its client. When an arbitration clause is not properly crafted, questions can arise as to who must arbitrate? Who decides whether to arbitrate? Who selects the arbitrator? What will the subject matter of the arbitration be? A look at a recent case in Pennsylvania highlights the need for properly crafted arbitration clauses.
A Recent Case Highlights The Importance Of Arbitration Clauses
In TEC Construction, LLC v. Greg Rich and Lora Rich filed in the Court of Common Pleas, Allegheny County, Pennsylvania, TEC Construction, LLC (“TEC”) and Greg and Lora Rich (the “Riches”), entered into a Construction Agreement with an arbitration clause. Specifically, the parties to the Construction Agreement, TEC and the Riches, agreed to arbitrate any disputes with the American Arbitration Association. Five subcontractors completed the work under the Construction Agreement but none of the subcontractors agreed to arbitrate.
Read the court decisionRead the full story...Reprinted courtesy of
Stephanie Nolan Deviney, Fox Rothschild LLP (ConsensusDocs)Ms. Deviney may be contacted at
sdeviney@foxrothschild.com
Golden Gate Bridge's $76 Million Suicide Nets Near Approval
June 30, 2014 —
Alison Vekshin – BloombergOfficials of the agency that runs San Francisco’s Golden Gate Bridge today approved a $76 million funding plan to erect a suicide barrier along the span, where people plunge to their deaths at a rate of about once a week.
The Golden Gate Bridge Highway and Transportation District’s 19-member board voted unanimously to approve the funding, which includes $20 million from district reserves.
“We must fight mental illness on many fronts and this budget action is a critical component of saving the lives of people who might not see that their brightest days are ahead of them,” Senator Mark Leno, a Democrat from San Francisco, said in a news release yesterday ahead of the meeting.
Read the court decisionRead the full story...Reprinted courtesy of
Alison Vekshin, BloombergMs. Vekshin may be contacted at
avekshin@bloomberg.net
Enforceability of Contract Provisions Extending Liquidated Damages Beyond Substantial Completion
April 15, 2024 —
Stu Richeson - The Dispute ResolverThis post takes a look at the enforceability of contract provisions providing for liquidated delay damages after substantial completion. Typically, the assessment of liquidated delay damages ends at substantial completion of a project. However, various standard form contracts, including some of the ConsensusDocs and EJCDC contracts, contain elections allowing for the parties to agree on the use of liquidated damages for failing to achieve substantial completion, final completion, or project milestones. The standard language in the AIA A201 leaves it up to the parties to define the circumstances under which liquidated damages will be awarded.
Courts are split on the enforceability of provisions that seek to assess liquidated damages beyond substantial completions. Courts in some jurisdictions will not impose liquidated damages after the date of substantial completion on the ground that liquidated damages would otherwise become a penalty if assessed after the owner has put the project to its intended use. Perini Corp. v. Greate Bay Hotel & Casino, Inc., 129 N.J. 479, 610 A.2d 364 (1992). When the terms are clear, other jurisdictions will enforce contract terms providing for liquidated damages until final completion, even if the owner has taken beneficial use of the facility. Carrothers Const. Co. v. City of S. Hutchinson, 288 Kan. 743, 207 P.3d 231 (2009).
Read the court decisionRead the full story...Reprinted courtesy of
Stu Richeson, PhelpsMr. Richeson may be contacted at
stuart.richeson@phelps.com
10 Safety Tips for General Contractors
October 09, 2018 —
Eric Weisbrot – JW Surety BondsThe construction industry continues to grow each year, paving the way for general contractors to make a profitable, sustainable living when the job is done right. However, to do so effectively, safety standards need to be met with consistency and focus on each worksite. General
contractors who are licensed and bonded must take proactive steps to avoid potentially fatal injuries among their subcontractors and employees, even though this may be easier said than done. To create and maintain a safe worksite each and every time, general contractors should consider how to implement the following best practices and safety tips on the job.
1 – Know the Risks
The most crucial step toward maintaining a safe construction site is to first be aware of the risks involved. Each year, thousands of
construction workers experience injuries on the job, and some ultimately lose their life because of safety missteps at work. As a general contractor, it is your responsibility to know that construction risks run rampant given the nature of the work. Being tuned into the potential for falls, slips, and other common safety-related incidents is a necessary part of operating a safe worksite for you and your employees.
2 – Require Protective Gear
An often overlooked safety precaution on construction sites is the use of up-to-date and well-maintained protective gear. For many subcontractors and employees, it is easy to skip this necessary step in safeguarding themselves from potential safety issues. However, general contractors can take steps to make protective gear a requirement on the job. This may include mandating hardhats and steel-toed shoes, gloves, and eyewear when appropriate. All visitors and workers on a construction site should follow protective gear instructions to avoid unnecessary safety risks.
3 – Educate on Ladder Safety
According to the Bureau of Labor Statistics, ladder injuries account for a significant number of construction worker incidents each year, making up more than 200,000 accidents on average. Ladders have continuously ranked high on OSHA’s list of violations at construction sites because the prevalence of injuries is so high. General contractors can help thwart ladder-related injuries among workers by promoting ladder safety training, including reminders about the right ladder to use for each task. Workers should also be well aware of the importance of inspection before use, and they should always follow the three points of contact rule when going up or down a ladder.
4 – Recognize Equipment Pitfalls
Many construction workers experience injuries relating to equipment used on the job. This could be tied to getting on or off equipment, or loading and unloading materials from machinery. In any case, general contractors can encourage simple tactics to improve equipment safety measures. Paying close attention to secure footing while getting on or off a machine, having more than one person assist with loading and unloading, and ensuring everyone feels comfortable asking for help with these tasks reduces safety risks.
5 – Document Potential Hazards
A general contractor’s main responsibility is to manage the construction site efficiently from start to finish. Part of this duty is recognizing the possible issues on a worksite that may lead to accidents or injuries if not addressed at the beginning of a project. It is necessary to take the time to identify safety risks such as unstable working surfaces, dangerous trenches, or weather-related concerns that may impact the safety of subcontractors, suppliers, or other site visitors. Potential hazards should be documented and shared with site workers, and they should be updated as the project progresses.
6 – Maintain Equipment and Tools
Poorly maintained equipment and tools also cause issues on construction sites. The Infrastructure Health and Safety Association suggests that general contractors
remind workers to inspect tools, machines, handheld equipment, and vehicles before each use to ensure they are properly maintained. Additionally, understanding the maintenance standards for certain tools or equipment and following those guidelines is crucial to reducing injury on the job.
7 – Minimize Crowds
Crowded work areas can be a serious safety issue for general contractors, subcontractors, and vendors and suppliers on site. It is common for crowds to gather during the use of heavy equipment or when a significant task is being completed. However, general contractors should discourage crowd-forming for spectating purposes. This can be done by limiting the number of people allowed to be in an area when certain activities are taking place, and enforcing these rules at every possible opportunity.
8 – Hire Licensed Subcontractors
General contractors may have full- or part-time employees as part of their business model, or there may be a heavy presence of subcontractors not directly tied to the main business. In either case, it is essential to have faith in the capabilities of workers, including their willingness and commitment to follow safety standards. General contractors can help ensure each worker is more likely to take safety seriously when they hire licensed contractors who follow through with
licensing requirements as mandated by the state or city.
9 – Focus on Training
Even after vetting subcontractors and employees based on their licensing status, general contractors also need to ensure training and education are a priority. Several online and in-person courses focus on construction safety training which workers should be encouraged to attend. Safety
education programs from OSHA and other reputable sources are crucial to decreasing accidents on the job.
10 – Be Present
Finally, general contractors can only have an impact on the safety of the job site when they are purposefully present. It is common for some GCs to stop by a project when they are needed or to check on progress periodically. However, new safety hazards, lacking worker training, and other risks are not easily fixed when the general contractor is not consistently on site. Reducing the potential for falls, slips, trips, and fatalities on the job requires communication with workers, and that takes place most effectively when general contractors are in person.
Eric Weisbrot is the Chief Marketing Officer of JW Surety Bonds. With years of experience in the surety industry under several different roles within the company, he is also a contributing author to the surety bond blog.
Read the court decisionRead the full story...Reprinted courtesy of
