Fairfield Connecticut Building Expert Directory

"Repair Work" Endorsements and Punch List Work

May 20, 2019 — Jeremiah M. Welch - Saxe Doernberger & Vita, P.C.
The recent white paper on Repair Work Endorsements by Jeremiah Welch, drew a storm of responses. Most were appreciative and included follow up questions, but there were those that lamented along the lines of: “How can that be? We’ve been doing it this way for years…”. For the skeptics, the best approach to test the premise of the paper (that most “repair work endorsements” are at best redundant with the PCO extension and at worst restrictive) is to try to formulate a scenario where coverage would be available under a “repair work endorsement” but not under a PCO extension. Several folks asked about the impact of PCO extensions and repair work endorsements on “punch list” work. “Punch list” work presents a related but different problem. The first issue is understanding what is meant by the term “punch list”. You won’t find that term in an ISO CGL policy. You may find it defined in a construction contract and a Google search will yield several similar definitions. In general, our industry uses the term “punch list” to describe items identified toward the end of a project (often after the contractually defined point of “substantial completion”) which must be completed in order to fully comply with the contract requirements/scope. In short, “punch list” items are items necessary to complete the work. Read the court decision
Read the full story...
Reprinted courtesy of Jeremiah M. Welch, Saxe Doernberger & Vita, P.C.
Mr. Welch may be contacted at jmw@sdvlaw.com

Is it the Dawning of the Age of Strict Products Liability for Contractors in California?

March 30, 2016 — Garret Murai – California Construction Law Blog
It was the Age of Aquarius. And everything was changing. Politically, socially . . . and legally. Through the 19th Century the doctrine of caveat emptor, literally “let the buyer beware,” was the rule of law. Under the doctrine a buyer was expected to protect him or herself against both obvious and hidden defects in a product. It wasn’t until the late 1800s that U.S. courts began to impose implied warranties – for merchantability and fitness for a particular purpose – to protect consumers. But implied warranties were premised on their being a contract between the manufacturer and the user of a defective product, and by the mid 20th Century it was increasingly uncommon for consumers to purchase products directly from a manufacturer. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Part II: Key Provisions of School Facility Construction & Design Contracts

July 21, 2018 — David R. Cook - Autry, Hall & Cook, LLP
In Part I of this article, published in late April, we discussed the performance risk and time risk involved with construction and design contracts, and in Part II, we will cover cost risk and political risk. Cost Risk School budgets are limited for many reasons, and the construction budget is no exception. As a result, contracts should guard against unwarranted cost increases and claims. In the absence of a written change order signed by the appropriate officer, the contract should absolutely prohibit additional compensation for changes in the work. It should forbid claims for all events except those within the school authority’s sole control. Even for permitted claims, the contractor must provide written notice so that the authority might alleviate the problem and control its costs. To encourage the contractor to limit costs and claims, the contract could include a shared-savings clause, which grants an incentive payment for completion within the budget. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Real Estate & Construction News Round-Up (08/17/22) – Glass Ceilings, Floating Homes and the Inflation Reduction Act

September 12, 2022 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
This week’s round-up features the construction industry’s latest happenings: the Inflation Reduction Act, women shattering the glass ceiling, eco-friendly floating homes, and more.

The Inflation Reduction Act contains approximately $5 billion for programs to accelerate the construction industry’s shift toward green building materials. (Julie Strupp, Construction Dive)
According to a new analysis from consultancy Rider Levett Bucknall, the speed of growth for construction costs has only gotten faster. (Erik Sherman, Globe St.)
Record vacancies in the construction industry has created the opportunity for women to step into what’s previously been an all-male business. (Craig Torres & Maria Paula Mijares Torres, Bloomberg)
A midlife crisis hits office buildings, with the late-30s/early-40s stable of office product accounting for about a third of the national market today. (Commercial Observer)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

The Impact of Sopris Lodging v. Schofield Excavation on Timeliness of Colorado Construction Defect Claims

January 26, 2017 — Jean Meyer - Colorado Construction Litigation
On October 20, 2016, the Colorado Court of Appeals announced the Sopris Lodging, LLC v. Schofield Excavation, Inc.[1] decision. The Sopris decision significantly altered the potential pitfalls awaiting a general contractor in pursuit of third-party claims as well as potential defenses available for a subcontractor defending against third-party claims. By way of background, the Sopris construction defect case arose out of the following facts: TDC was the general contractor for the construction of a hotel owned by Sopris Lodging. On March 11, 2011, Sopris Lodging sent TDC a notice of claim regarding alleged construction defects. On May 24, 2013, Sopris Lodging filed a complaint in district court asserting construction defect claims against one of the subcontractors of the hotel, and against the general contractor’s principals, but not the general contractor. Contemporaneous with the filing of the suit, Sopris Lodging and TDC entered into an agreement to toll the statute of limitations on Sopris Lodging’s potential claims against TDC. In August 2013, Sopris Lodging joined the general contractor to the suit. A year later, in 2014, the general contractor joined a variety of subcontractors as third-party defendants. Read the court decision
Read the full story...
Reprinted courtesy of Jean Meyer, Higgins, Hopkins, McLain & Roswell, LLC
Mr. Jean may be contacted at meyer@hhmrlaw.com

MSJ Granted Equates to a Huge Victory for BWB&O & City of Murrieta Fire Department!

May 30, 2022 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
BWB&O Partner Tyler D. Offenhauser and Senior Associate Kevin B. Wheeler prevailed on their Motion for Summary Judgment (“MSJ”) on behalf of a public entity, the City of Murrieta Fire Department today! As a matter of background, authorities were first called to a residence in Murrieta after a report of a gas line rupture. Firefighters and Southern California Gas Company responded to the call. As a crew from SoCalGas was trying to shut off the gas an explosion happened, leveling the home and killing 31-year-old SoCalGas employee Wade Kilpatrick. 30 surrounding homeowners have now alleged personal injuries, including TBI, as a result of the explosion. News agencies reported that Plaintiff Anthony Borel sustained a severe head injury and was placed in a coma. Plaintiff’s injuries included an epidural hematoma, subarachnoid hemorrhage, bilateral corneal abrasions, right orbital fracture, right temporal fracture, right maxillary fracture, frontal skull fracture, 18% partial-thickness burns to the face, abdomen, arms and legs, and a severe TBI with cognitive deficiencies. Plaintiff claimed damages in excess of $20,000,000.00. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Close Enough Only Counts in Horseshoes and Hand Grenades

March 08, 2021 — Garret Murai - California Construction Law Blog
In State Farm General Insurance Company v. Oetiker, Inc., Case No. B302348 (December 18, 2020), a manufacturer sued in subrogation action under the Right to Repair Act almost got away. Almost. The Oetiker Case James and Jennifer Philson’s home was substantially completed, and a notice of completion was recorded, in 2004. In 2016, the Philsons tendered a claim to their homeowner’s insurance carrier, State Farm General Insurance Company, after their home experienced significant water damage due to a defective stainless steel ear clamp. In 2018, after paying the Philson’s claim, State Farm filed a subrogation action against the manufacturer of the ear clamp, Oetiker, Inc. State Farm’s complaint, which included causes of action for negligence, strict products liability and breach of implied warranty, alleged that the home was “damaged by a water leak from the failure of a defective stainless steel ear claim on a water PEX fitting” and that the ear clamp was “defective when it left the control of [Oetiker].” Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES