Seattle Washington Building Expert Directory

Steven Cvitanovic Recognized in JD Supra's 2017 Readers' Choice Awards

April 05, 2017 — Steven M. Cvitanovic - Haight Brown & Bonesteel LLP
JD Supra named Partner Steven Cvitanovic among the Top 10 Authors in the construction industry in its 2017 Readers’ Choice Awards, which recognizes the excellence and achievement of firms and authors who published their substantive work on JD Supra in 2016. JD Supra editors chose the 25 industries and topics covered in these awards for their timeliness as well as their proven, ongoing importance. In each category, one firm and ten authors were recognized for consistently achieving the highest readership and engagement for all of 2016. Read the court decision
Read the full story...
Reprinted courtesy of Steven M. Cvitanovic, Haight Brown & Bonesteel LLP
Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com

Defects in Texas High School Stadium Angers Residents

March 07, 2014 — Beverley BevenFlorez-CDJ STAFF
According to WFAA News, many residents of Allen, Texas were upset when their tax dollars were spent on a new high school football stadium, and they are angry now that alleged construction defects may cause the stadium to close, and perhaps not even reopen again this fall. There “is a disproportionately large amount of our tax dollars that goes just to Allen ISD," Rachel Palmer, an Allen resident, told WFAA News. However, Ben Pogue, president of Pogue Construction, the stadium’s general contractor called the situation “a road bump.” WPAA News also interviewed Dr. Simon Chao of the Department of Civil Engineering at the University of Texas at Arlington: "Cracking is fairly common in concrete," Chao stated. "The problem is the damage water may cause by getting in the cracks.” Read the court decision
Read the full story...
Reprinted courtesy of

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

2021 California Construction Law Update

December 29, 2020 — Garret Murai - California Construction Law Blog
This Christmas looks to be a Blue Christmas as the nation grapples with rising infection, hospitalization and death rates due to COVID. But there’s always 2021 to look forward to, which, of course, also means new laws impacting the construction industry. Due to COVID there were two unscheduled breaks during the second half of the 2019-2020 legislative session as legislators sheltered-in-place. As a result, there were fewer bills introduced and enacted than in previous legislative session. A total of 2,223 bills were introduced in 2020 compared to 2,625 bills in 2019, of which 428 bills made it to the Governor’s desk, and 372 were signed into law. Among the bills signed into law were bills, unsurprisingly, related to COVID. In addition, the 2020 legislative session saw the passage of legislation creating a new licensing classification for residential renovation contractors, new laws expanding and clarifying when prevailing wages are required to be paid, and legislation extending the period during which seniors can cancel certain contracts. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Let it Shine: California Mandates Rooftop Solar for New Residential Construction

May 16, 2018 — Garret Murai - California Construction Law Blog
California. Birthplace of the Frisbee, skateboard, television, canned tuna and (yup) fortune cookies has added another first to the list: California has become the first state in the nation to mandate the use of solar panels for new residential construction. On May 9, 2018, the California Energy Commission (CEC) unanimously approved the state’s 2019 Building Energy Efficiency Standards. The 2019 Energy Efficiency Standards update the California Building Standards Codes found at Title 24 of the California Code of Regulations which are updated every three years. The 2019 Energy Efficiency Standards go into effect on January 1, 2020. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Update: New VOSH Maximum Penalties as of July 1

July 26, 2017 — Christopher G. Hill - Construction Law Musings
As those who read Construction Law Musings know, as a construction attorney, I want to assure that not only are my clients successful in their litigation/dispute resolution endeavors, but that they stay out of trouble. I take my problem solving and advising roles quite seriously. As part of this role as advisor, I want to let those that read Musings know that as of July 1, 2017 the Virginia Occupational Safety and Health Administration increased their maximum penalties for safety violations. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Defenses Raised Three-Years Too Late Estop Insurer’s Coverage Denial

February 21, 2022 — Michael S. Levine & Yaniel Abreu - Hunton Insurance Recovery Blog
Liability insurance typically affords broad defense coverage. But insurers sometimes reserve their right to challenge the insured’s right to a defense, or even outright terminate the defense. When this occurs after the insurer has been in exclusive control of the defense, some courts recognize that the consequences can be catastrophic for the insured defendant. Insurers, therefore, may be estopped from denying coverage where doing so will prejudice the insured. This is exactly what transpired in RLI Ins. Co. v. AST Engineering Corp., No. 20-214 (2d Cir. Jan. 12, 2022), where the Second Circuit affirmed the district court’s decision that an insurer’s attempt to withdraw the defense it had provided to its insured for three years would prejudice the insured. In AST Engineering, RLI sought a declaration that it did not have to defend the insured, AST, in two underlying cases in which AST was sued as a third-party defendant. The underlying cases concerned a construction project in New York City for which AST provided engineering drawings on October 28, 2012. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Yaniel Abreu, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Abreu may be contacted at yabreu@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Architect Sues School District

November 20, 2013 — CDJ STAFF
SFL+A Architects is suing the Marlboro County, South Carolina School District over $690,000 that the architect claims is owed to it by the school district. The firm did design work for the Blenheim Elementary Middle School, which opened in January. The architectural firm contends that the school district refused to pay for anything outside of basic services and failed to pay the full amount on those either. Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES