Application Of Two Construction Contract Provisions: No-Damages-For-Delay And Liquidated Damages
February 14, 2022 —
David Adelstein - Florida Construction Legal UpdatesA recent Florida opinion between a prime contractor and a Florida public body touches upon two important issues: (1) the application of a no-damage-for-delay provision; and (2) the application of a liquidated damages provision. Both provisions find there way into many construction contracts. Unfortunately, the opinion is sparse on facts. Nevertheless, the application of these provisions is worthy of consideration.
In this opinion, Sarasota County v. Southern Underground Industries, Inc., 2022 WL 162977 (Fla. 2d DCA 2022), a county hired a contractor to install sanitary and water piping underneath a waterway. During construction, a nearby homeowner complained that vibration from the drilling caused damage to his home. As a result, the county stopped the contractor’s work to address a potential safety issue, as it was contractually entitled to do. The contractor hired a structural engineer to inspect the house and the engineer issued a report determining that any alleged damage was cosmetic and that there was sufficient monitoring of the vibrations to prevent future damage. The contractor also had an insurance policy to cover any homeowner claim for damage. However, upon receipt of the engineer’s report, the county did not lift its stop work order. Rather, the stop work order remained in place for an additional 71 days.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
The Ghosts of Projects Past
December 17, 2015 —
Craig Martin – Construction Contractor AdvisorSean Minahan, one of my partners, and I were discussing a construction dispute the other day and we commented again and again about the significant organization required to get a construction project to completion. From the contracts, to the schedule, to the funding—everything has to be in lock step or there will be problems that could bring the project to a halt, or worse yet litigation.
The same is true of construction claims. To present a claim effectively, it has to be simple. But, to make it simple will require substantial documentation and organization of all aspects of a claim.
This point was driven home this week when I received Long International’s Construction Claims Analysis Checklist Long International. The Checklist is 11 pages long and identifies various aspects of a claim, from the simple to the complicated.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
DIR Public Works Registration System Down, Public Works Contractors Not to be Penalized
July 15, 2024 —
Garret Murai - California Construction Law BlogIn a bit of a major freak-out this past Friday, June 28, 2024, public works contractors with Department of Industrial Relations (“DIR”) registrations expiring on June 30, 2024 were unable to renew their public works registrations. Those who had submitted checks were not receiving responses, DIR was not accepting online payments, and there was no telephone number or address to contact the DIR about the issue.
This, of course, could have been a big deal since Labor Code section 1725.5 prohibits contractors and subcontractors from bidding on, being listed in a bid, or being awarded a public works contract unless registered with the DIR.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Newmeyer & Dillion Welcomes Three Associates to Newport Beach Office
January 26, 2017 —
Newmeyer & Dillion LLPNEWPORT BEACH, Calif. – JANUARY 24, 2017 – Enjoying rapid expansion in many primary practice areas, Newmeyer & Dillion LLP is pleased to welcome new associates
Jenny Guzman and
Jason Moberly Caruso, and welcomes back
Lily (Toubi) Razai to the Newport Beach office. The addition of these three associates fortifies the firm’s commitment to provide unparalleled service to our clients.
Firm Managing Partner,
Jeff Dennis, explained that each hire addresses the immediate and long-term needs of our clients, and firm's desire for strategic growth. "We always remain focused on what will allow us to better represent our clients, not just now but far into the future. We are excited to bring these three talented lawyers aboard as we continue to expand our capabilities across practice areas.”
Guzman, Caruso and Razai each practice business and real estate litigation, with Razai’s practice including land use and eminent domain matters. Caruso also practices construction law and Guzman's practice also focuses on business and real estate transactions.
Each attorney has unique strengths that continue to diversify the firm’s approach to their clients. In addition to serving clients in state and federal courts, Razai has extensive experience in alternative dispute resolution proceedings, and has served as a mediator in state courts. Awarded Super Lawyers 2016 Rising Star, Caruso utilizes his extensive judicial experience to argue on behalf of his clients at various levels from arbitration to the Ninth Circuit Court of Appeals. Guzman draws on her past experience in private equity and venture capital to protect businesses and help them achieve their full potential. These three associates, along with their diverse experience and cohesive strengths, further reinforce N&D’s foundation for continued growth and excellence.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season
January 13, 2020 —
David Adelstein - Florida Construction Legal UpdatesThere are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be.
For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:
[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season.
Meridian Engineering, 2019 WL at *7 (internal citations omitted)
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Real Estate & Construction News Roundup (7/10/24) – Strong Construction Investment in Data Centers, Increase Use of Proptech in Hospitality and Effects of Remote-Work on Housing Market
August 05, 2024 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, renters stay in their units longer, GenAI change how commercial real estate operates, and banks continue high exposure due to commercial real estate.
- Strong investor interest, particularly in opportunistic and value-add segments, signals a strong market for construction firms specializing in high-yield projects. (Sebastian Obando, Construction Dive)
- A growing number of renters are staying in their units for longer periods of time than they did a decade ago with over one-third of U.S. renters have lived in the same apartment for more than five years. (Mary Salmonsen, Multifamily Dive)
- Several U.S. regional and mid-sized banks continue to face the squeeze from high exposure to the commercial real estate sector that has been shaken by higher-for-longer interest rates and empty office buildings. (Reuters)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Cameron Kalunian to Speak at Casualty Construction Defect Seminar
October 04, 2021 —
Cameron Kalunian - Lewis BrisboisLos Angeles Partner Cameron Kalunian will speak at the Annual West Coast Casualty Construction Defect Seminar, hosted on October 6-8 at the Aria Hotel and Casino in Las Vegas.
In a session on Friday, October 8 at 9:30 a.m. PT titled “Maintaining Relationships in the Storm of Multi-Party Construction Litigation,” Mr. Kalunian, along with one construction general counsel and one insurance coverage counsel, will discuss the impact of litigation on continuing business relationships. The session will specifically focus on balancing risk transfer with business goals in the context of multi-tiered contractor construction projects.
The panel will discuss the best practices for communications between and among clients, indemnitors, claims handling professional, coverage counsel and defense counsel. This session is a must for insurance professionals that handle claims involving bodily injury or property damage claims arising out of construction disputes related to projects with multi-tiered contractors. CLE credits will be available for attorneys, along with CEU credits for insurance claims handlers.
Read the court decisionRead the full story...Reprinted courtesy of
Cameron Kalunian, Lewis BrisboisMr. Kalunian may be contacted at
Cameron.Kalunian@lewisbrisbois.com
Hurry Up and Wait! Cal/OSHA Hits Pause on Emergency Temporary Standards for COVID-19 Prevention
June 14, 2021 —
Michael Studenka & Jasmine Shams - Newmeyer DillionEmployers scrambling to prepare for the June 15th Reopening announced by Governor Newsom have spent the last week pouring over the revised Emergency Temporary Standards for COVID-19 Prevention (“Revised ETS”) approved by the Cal/OSHA Standards Board on June 3, 2021. After last night’s meeting of the Standards Board, however, it’s time to hit pause.
Last night, the Cal OSHA Standards Board held a specialty meeting to reconsider its Revised ETS in light of the latest guidance on face coverings issued by the California Department of Public Health (“CDPH”) on June 7, 2021. Following a presentation by the CDPH and extensive public comment, the Cal OSHA Standards Board voted unanimously to withdraw the Revised ETS and to take up the issue again at its next scheduled meeting on June 17, 2021. The net result in the interim is that California employers who intend to reopen on June 15 must initially comply with all of the requirements of the Cal/OSHA Standards Board Emergency Temporary Standards for COVID-19 Prevention as originally issued on November 20, 2020, including but not limited to, its social distancing, physical partitioning and mask wearing requirements.
Reprinted courtesy of
Michael J. Studenka, Newmeyer Dillion and
Jasmine Shams, Newmeyer Dillion
Mr. Studenka may be contacted at michael.studenka@ndlf.com
Ms. Shams may be contacted at jasmine.shams@ndlf.com
Read the court decisionRead the full story...Reprinted courtesy of
