Seattle Washington Building Expert Directory

Policyholder Fails to Build Adequate Record to Support Bad Faith Claim

May 19, 2011 — Tred R. Eyerly

The importance of careful preparation and documentation was the take away lesson in a Texas bad faith case, C.K. Lee v. Catlin Specialty Ins. Co., 2011 U.S. Dist. LEXIS 19145 (S.D. Tex. Feb. 28, 2011).

C.K. Lee owned a commercial shopping center in Houston. Catlin issued a commercial property policy to Lee. On September 12, 2008, Hurricane Ike hit and caused substantial property damage throughout the Texas Gulf Coast area. On September 24, 2008, Lee submitted a claim for damage to the roof of his shopping center to Catlin.

Catlin hired Engle Martin to represent its interests in adjusting the claim. Engle Martin eventually adjusted over 200 Ike-related claims for Catlin.

In November 2008, Engle Martin and Emergency Services Inc., retained by Lee, inspected Lee’s property. Engle Martin observed evidence of roof repairs that had apparently been made both before and after Hurricane Ike. Engle Martin decided it was necessary to use an infrared scan of the roof to help identify which damages, if any, were attributable to wind and which, if any, were attributable to sub par, prior repairs or natural deterioration.

Engle Martin retained Project, Time & Cost (PT&C) to conduct the infrared inspection. PT&C’s inspection determined there was no wind-related damage to the roof and no breaches or openings created by wind. Instead, the roof had exceeded its life expectancy and was in need of replacement due to normal wear and weathering. Consequently, Catlin decided that the damage to Lee’s roof was not caused by winds from Hurricane Ike.

Meanwhile, Lee’s contractor, Emergency Services, prepared a report estimating that the total cost of repairing the roof would be $871,187. Engle Martin’s estimate for repair of the roof was $22,864.

Lee filed suit for breach of contract, breach of the duty of good faith and fair dealing, and violations of the Texas Insurance Code. Catlin moved for summary judgment on all claims but breach of contract, arguing that because there was a bona fide dispute concerning the cause of the damages and whether they were covered under the policy, there was no evidence of bad faith or violations of the Texas Insurance Code.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

Duty to Defend Triggered by Damage to Other Non-Defective Property

February 20, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The court found the insurer must defend because there was a possibility of damage to property due to work not performed by the insured. B&W Paving & Landscape, LLC v. Employers Mut. Cas. Co., 2022 U.S. Dist. LEXIS 225783 (D. Conn. Dec. 15, 2022). In 2010, Whiting Turner Contracting Company (WT) contracted with United Illuminating Company (UI) to act as general contractor for the construction of UI's new central facility. WT subcontracted with Cherry Hill Construction, Inc. (Cherry Hill) for work underneath the parking lot and driveways, including installing base and sub base materials. WT also subcontracted with B&W Paving and Landscape, LLC (B&W) for the asphalt paving. In 2018, UI sued WT for defective and incomplete work. WT then filed a third-party compact against its subcontractors, including B&W. WT sued for contribution for any liability it may have to UI for the paving work. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

New Rule Prohibits Use of Funds For Certain DoD Construction and Infrastructure Programs and Projects

May 30, 2018 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
Recently, our colleagues Glenn Sweatt and Alex Ginsberg published their Client Alert titled DFARS Clause Blocks Funding for Unsafe Projects in Afghanistan, Recently published regulation implements the FY17 NDAA to prohibit use of funds for DoD construction and infrastructure programs and projects in Afghanistan that cannot be safely accessed by U.S. Government personnel. Takeaways include:

New rule prevents Government contracting officers from funding projects that are not able to be safely accessed by Government civilian or military personnel, as these may pose an increased risk of fraud, corruption or waste, or lack efficient oversight.

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

California Courts Call a “Time Out” During COVID-19 –New Emergency Court Rules on Civil Litigation

May 04, 2020 — Tara C. Dudum - Newmeyer Dillion
“We are at this point truly with no guidance in history, law, or precedent. To say that there is no playbook is a gross understatement of the situation.” -Chief Justice and Chair of the California Judicial Council, Tani G. Cantil-Sakauye Seeking to sustain essential court services while balancing weighty considerations, including litigants’ due process rights, access to justice, and stringent health and safety orders, the California Judicial Council has adopted Emergency Rules in response to the ongoing coronavirus pandemic (COVID-19). While many of the Emergency Rules focus on criminal and juvenile dependency matters, this update highlights the Emergency Rules immediately impacting civil litigation in California state courts. The following Emergency Rules remain in effect until 90 days after the Governor lifts the state of emergency or the rule is amended or repealed by the Judicial Council: Tolling of Statutes of Limitation in Civil Actions Effective April 6, 2020, the statutes of limitation (the time period in which to bring a claim) for all civil causes of action is tolled until such time as the rule is no longer in effect. The impact of this rule is that it provides plaintiffs with more time to bring claims and extends the time period that defendants may face legal action for alleged violations of the law. Read the court decision
Read the full story...
Reprinted courtesy of Tara C. Dudum, Newmeyer Dillion
Ms. Dudum may be contacted at tara.dudum@ndlf.com

Washington Trial Court Narrows Definition of First Party Claimant, Clarifies Available Causes of Action in Commercial Property Loss Context

January 04, 2021 — Kathleen A. Nelson & Jonathan R. Missen - Lewis Brisbois
The law in the State of Washington, albeit clear on issues regarding first party claimants, was recently challenged in the matter of Eye Associates Northwest, P.C. v. Sedgwick et. al. However, despite this challenge of first impression, the court limited the application of the term “first party claimant” (a term of art akin to “insured”) based upon the wording of a loss payee clause, as well as taking into consideration and harmonizing the wording of the leases, other provisions in the policy regarding tenant improvements, and the simple fact that Eye Associates was not named in the policy whatsoever. In Eye Associates, the plaintiff leased office space in a high-rise medical office building, insured by three separate insurance companies. A water loss caused damage to the plaintiff’s leased space, and the plaintiff brought suit against the owner of the building, its insurers, the property manager, a third-party administrator (TPA), and two individual adjusters assigned to inspect and adjust the water loss claim. Reprinted courtesy of Kathleen A. Nelson, Lewis Brisbois and Jonathan R. Missen, Lewis Brisbois Ms. Nelson may be contacted at Kathleen.Nelson@lewisbrisbois.com Mr. Missen may be contacted at Jonathan.Missen@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

Wildfire Risk Harms California Home Values, San Francisco Fed Study Finds

August 26, 2024 — Laura Curtis - Bloomberg
California’s wildfires are weighing on home prices more than in the past, and insurance availability does little to help in areas considered to be at higher risk, according to a Federal Reserve Bank of San Francisco study. “Our results suggest that property values have been more adversely impacted in recent years by being close to past wildfires than was the case previously,” economists Leila Bengali, Fernanda Nechio and Stephanie Stewart wrote in a paper published Monday on the Fed bank’s website. While the effect of the proximity may be relatively small now, the economists warned “this pattern may become stronger in years to come if residential construction continues to expand into areas with higher fire risk and if trends in wildfire severity continue,” the study cautioned. Read the court decision
Read the full story...
Reprinted courtesy of Laura Curtis, Bloomberg

Recovering Attorney’s Fees and Treble Damages in Washington DC Condominium Construction Defect Cases

April 03, 2023 — Nicholas D. Cowie - Cowie Law Group
DC Condominium Association’s Can Recover Attorney’s Fees, Litigation Costs and Treble Damages in Construction Defect Cases Involving Misrepresentation The District of Columbia Consumer Protection Procedures Act (“CPPA”) § 28-3905(k)(1)(A) creates a private legal claim (a/k/a “cause of action”) which can be asserted by a condominium unit owners association (“condominium association”) on behalf of two or more of its unit owner members who are misled by a condominium developer regarding the condition or quality of a newly constructed or newly converted condominium. Under the DC CPPA, a successful claimant is entitled to recover “treble damages” (i.e., three times the amount of damages it proves), plus recovery of “reasonable attorney’s fees” incurred in prosecuting the construction defect claim and “[a]ny other relief the court determines proper,” including non-attorney fee litigation expenses. DC CPPA § 28-3905(k)(2)(A), (B) and (F). The CPPA Creates the Legal Claim that Allows a Condominium Associations to Recover Attorney’s Fees, Litigation Costs and Treble Damages The DC CPPA is a consumer-oriented statute designed to protect Washington DC consumers misled in connection with the purchase of consumer “real estate,” including transactions involving the purchase of a condominium unit and interest in the condominium common elements. Typically, these cases involve the sale of a newly constructed or newly converted condominium, which, contrary to developer representations, contains latent construction defects. Read the court decision
Read the full story...
Reprinted courtesy of Nicholas D. Cowie, Cowie Law Group
Mr. Cowie may be contacted at ndc@cowielawgroup.com

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES