Think Twice Before Hedging A Position Or Defense On A Speculative Event Or Occurrence
July 13, 2020 —
David Adelstein - Florida Construction Legal UpdatesSometimes, hedging a position on a potential occurrence is not prudent. Stated differently, hedging a position on a contingent event is not the right course of action. The reason being is that a potential occurrence or contingent event is SPECULATIVE. The occurrence or event may not take place and, even if it does take place, the impact is unknown.
An example of hedging a defense on such a potential occurrence or contingent event can be found in a construction dispute involving a federal project out of the Eastern District of Virginia, U.S. f/u/b/o Champco, Inc. v. Arch Insurance Co., 2020 WL 1644565 (E.D.Va. 2020). In this case, the prime contractor hired a subcontractor to perform electrical work, under one subcontract, and install a security system, under a separate subcontract. The subcontractor claimed it was owed money under the two subcontracts and instituted a lawsuit against the prime contractor’s Miller Act payment bond. The prime contractor had issued the subcontractor an approximate $71,000 back-charge for delays. While the subcontractor did not accept the back-charge, it moved for summary judgment claiming that the liability for the back-charge can be resolved at trial as there is still over $300,000 in contract balance that should be paid to it. The prime contractor countered that the delays caused by the subcontractor could be greater than $71,000 based on a negative evaluation in the Contractor Performance Assessment Reporting System (“CPARS”). A negative CPARS rating by the federal government due to the delays caused by the subcontractor would result in a (potential) loss of business with the federal government (i.e., lost profit) to the prime contractor. The main problem for the prime contractor: a negative CPARs rating was entirely speculative as there had not been a negative CPARs rating and, even if there was, the impact a negative rating would have on the prime contractor’s future business with the federal government was unknown. To this point, the district court stated:
In this case, [prime contractor’s] claim for damages is wholly speculative. [Prime contractor] has not produced any evidence that its stated condition precedent—a negative CPARS rating—will actually occur and will have a negative impact on its future federal contracting endeavors. Specifically, [prime contractor] has not identified any facts that indicate that it will be subject to a negative CPARS rating or any indication of the Navy’s dissatisfaction with its work as the prime contractor on the Project… Further, a CPARS rating is only one aspect taken into consideration when federal contracts are awarded. In sum, there is no evidence of the following: (1) a negative CPARS rating issued to [prime contractor]; (2) [prime contractor’s] hypothetical negative rating will be the result of the delay [prime contractor] alleges was caused by [subcontractor]; or (3) [prime contractor’s] hypothetical negative CPARS rating will result in future lost profits.
U.S. f/u/b/o Champco, Inc., supra, at *2 (internal citation omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
New Highway for Olympics Cuts off Village near Sochi, Russia
February 07, 2014 —
Beverley BevenFlorez-CDJ STAFFA new highway costing $635 million was built in Sochi, Russia to support this month’s Winter Olympic Games—but the “shining” highway has cut off residents of the Village of Akhtyr, according to The Spokesman-Review. The online publication reports that while the Olympics will showcase the “luxury malls, sleek stadiums and high-speed train links, thousands of ordinary people in the Sochi area put up with squalor and environmental waste: villagers living next to an illegal dump filled with Olympic construction waste, families whose homes are sinking into the earth, city dwellers suffering chronic power cuts despite promises to improve electricity.”
One of the Sochi residents told KPAX News that what was once a “15-minute walk to get the bus to work has become a two-hour, cross-country trek. Military guards block their way to the rickety footbridge they used to use.” Furthermore, KPAX News claimed, “Heavy construction and traffic have chewed up the road through town and turned it into a dust bowl.”
Read the full story at The Spokesman-Review...
Read the full story at KPAX News... Read the court decisionRead the full story...Reprinted courtesy of
The Condominium Warranty Against Structural Defects in the District of Columbia
July 24, 2023 —
Nicholas D. Cowie - Cowie Law GroupTHE CONDOMINIUM WARRANTY AGAINST STRUCTURAL DEFECTS
Condominium developers in Washington DC are required by statute to warrant against structural defects in residential condominiums. District of Columbia Condominium Act (“DC Condo Act”) § 42-1903.16(b). The warranty applies to both condominium common elements and each condominium unit. It requires a developer to repair structural defects, including any resulting damage to the condominium caused by a common element structural defect. DC Condo Act § 42-1903.16(a-1)(2). The statute creating this warranty is called the “Warranty Against Structural Defects,” contained in the DC Condo Act § 42-1903.16.
“Structural Defects” Defined
The warranty applies to “structural defects,” which are very broadly defined to include many types of construction defects. Structural defects are not just limited to defects in the supporting structure of the building. Rather, a structural defect can be any condition that:
“(A) Reduces the stability or safety of unit or common elements below standards commonly accepted in the real estate market,” or
(B) Restricts the normally intended use of all or part of the common elements of a unit and which requires repair, renovation, restoration, or replacement to serve the purpose for which it was intended.”
DC Condo Act § 42-1903.16(j)(6).
Read the court decisionRead the full story...Reprinted courtesy of
Nicholas D. Cowie, Cowie Law GroupMr. Cowie may be contacted at
ndc@cowielawgroup.com
Florida Adopts Less Stringent Summary Judgment Standard
January 25, 2021 —
John A. Rine & Sarah Hock - Lewis BrisboisOn New Year’s Eve, Florida’s Supreme Court issued an amendment to essentially apply the federal summary judgment standard to cases in Florida state courts starting on May 1, 2021. See In Re: Amendments to Florida Rule of Civil Procedure 1.510, No. SC20 1490 (Fla. Dec. 31, 2020) (per curiam). This change brings Florida in line with the majority of states (38).
Summary judgment is easier to obtain under the federal standard. A moving party need only show that the opposing party lacks the evidence to support its case at trial. Under the soon-to-be obsolete Florida standard, however, moving parties had to entirely “disprove the nonmovant’s theory of the case in order to eliminate any issue of fact." See id. at 3. The nonmoving party could defeat a summary judgment motion by showing that there was a slight doubt on any material fact. See id. at 4-5.
This change is good news for defendants and their insurers. With summary judgment easier to obtain, weak claims can be defended prior to trial. Claims may be resolved more quickly and economically. The threat of summary judgment also gives defendants powerful leverage in settlement discussions. The shift may also reduce the backlog of cases accumulated during the suspension of jury trials over the past summer.
Reprinted courtesy of
John A. Rine, Lewis Brisbois and
Sarah Hock, Lewis Brisbois
Mr. Rine may be contacted at John.Rine@lewisbrisbois.com
Ms. Hock may be contacted at Sarah.Hock@lewisbrisbois.com
Read the court decisionRead the full story...Reprinted courtesy of
No Coverage for Collapse of Building
January 04, 2021 —
Tred R. Eyerly - Insurance Law HawaiiDamage to a building caused by the break of a water pipe was not a collapse under the policy. Naabani Twin Stars v. Travelers Cos., 2020 U.S. Dist. LEXIS 196443 (D. N. M. Oct. 22, 2020).
An underground water line ruptured on plaintiffs property This caused a collapse under the adjacent parking lot, which in turn caused land beneath the building go change positions and damage the building. A geotechnical consultant concluded that a material change in the site conditions occurred as a direct result of the rupture of the water pipe in the parking lot, and that those changes directly affected the settlement of the building.
Travelers denied coverage for the damage. Travelers concluded that the building settlement was the result of subsurface movement, which invoked the earth movement exclusion. Travelers inspection concluded that the building was not in a state of collapse. The policy defined collapse as "an abrupt falling down or caving in of a building or structure, or any part of a building or structure, with the result that the building, or part of the building, cannot be occupied for its intended purpose."
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Partner Bradley T. Guldalian Secures Summary Judgment Win for National Hotel Chain
August 26, 2019 —
Bradley T. Guldalian - Traub LiebermanOn June 26, 2019, Traub Lieberman Straus & Shrewsberry LLP Partner Bradley T. Guldalian secured summary judgment on behalf of a national hotel chain in a slip and fall accident filed in Osceola County Circuit Court in Kissimmee, Florida. The underlying loss occurred when the Plaintiff slipped and fell in a puddle of water allegedly existing in the hotel’s laundry room and suffered a partial thickness rotator cuff tear involving the distal infraspinatus tendon for which he underwent surgery and incurred over $70,000 in medical bills. The Plaintiff filed a premises liability action against the hotel claiming the hotel had failed to maintain its premises in a reasonably safe condition proximately causing the Plaintiff’s fall and resulting injuries.
After discovery closed, Mr. Guldalian filed a motion for summary judgment on behalf of the hotel arguing that to prevail in a negligence claim involving a “transitory foreign substance”, such as water on a floor, an injured party must plead and prove pursuant to Florida Statute 768.0755 that the business establishment had actual or constructive knowledge of the dangerous condition and should have taken action to remedy it prior to the time of the alleged fall. Constructive knowledge may be proven by circumstantial evidence showing that (1) the dangerous condition existed for such a length of time that, in the exercise of ordinary care, the business establishment should have known of the condition or (2) that the condition occurred with such regularity that it was foreseeable that the condition would be present on the day the injury occurred.
Read the court decisionRead the full story...Reprinted courtesy of
Bradley T. Guldalian, Traub LiebermanMr. Guldalian may be contacted at
bguldalian@tlsslaw.com
Parking Garage Collapse May Be Due to Construction Defect
November 07, 2012 —
CDJ STAFFA parking garage under construction at the Doral campus of Miami Dade College collapsed on October 9. Experts state that the collapse may have been due to errors in the construction process, either in the fabrication of the pre-cast components or in their assembly. The Bradenton Herald quotes Mark Santos, a structural engineer, who “would look at erection procedures – that’s probably the one question to ask first.”
During the failure, floors separated from the south wall of the structure. The contractor responsible for the garage, Ajax Building Corp, said there was “no indication of any potential cause.”
Read the court decisionRead the full story...Reprinted courtesy of
A Survey of New Texas Environmental and Regulatory Laws Enacted in the 88th Session (Updated)
August 28, 2023 —
Anthony B. Cavender & Alexandra Trahan - Gravel2Gavel Construction & Real Estate Law BlogThis is a brief survey of many of the environmental and regulatory laws passed by the Texas Legislature and signed by the Governor in the 88th Regular Session of the Legislature, which ended in May 2023, although a special session has been called to address lingering matters. Altogether, more than 1,000 laws were enacted in this session, including a surprising number of water-related environmental bills.
Water
HB1565 relates to the functions of the Texas Water Development Board and continuation and functions of the State Water Implementation Fund for Texas Advisory Committee.
Effective 9.1.23.
HB1699 relates to the authority of the Evergreen Underground Water Conservation District to impose certain fees.
Effective 6.9.23.
HB1845 amends Section 37 of the Water Code to add Section 37.0045 relating to the licensing requirements for certain operators of wastewater systems and public water systems.
Effective 9.1.23.
Reprinted courtesy of
Anthony B. Cavender, Pillsbury and
Alexandra Trahan, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of
