FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Think Before you Execute that Release – the Language in the Release Matters!

June 17, 2024 — David Adelstein - Florida Construction Legal Updates
If you execute a release in exchange for payment or other consideration, remember the language in the release means something. THE RELEASE LANGUAGE MATTERS! And the meaning in the release may be way more than you intended so please make sure you truly digest and consider release language before executing. This sentiment could not be truer than in the 2009 decision Bell BCI Company v. United States, 570 F.3d 1337 (Fed. Cir. 2009). In this case, a contractor entered into a modification (change order) with the government. The modification included the following language: increase the contract amount by $2,296,963 … as full and equitable adjustment for the remaining direct and indirect costs of the Floor 4 Fit-out (EWO 240–R1) and full and equitable adjustment for all delays resulting from any and all Government changes transmitted to the Contractor on or before August 31, 2000. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

South Carolina Couple Must Arbitrate Construction Defect Claim

June 28, 2013 — CDJ STAFF
The South Carolina Court of Appeals has rejected a claim by Sun City property owners that they were not bound by the arbitration clause in their purchase agreement. Roger and Mary Jo Carlson brought the claim against Del Webb Communities and Pulte Homes. About 140 homeowners are alleging problems in the community. According to the court, the Carlsons will have to go through arbitration with the companies over the alleged stucco defects to their home. Read the court decision
Read the full story...
Reprinted courtesy of

---

Business and Professions Code Section 7031, Demurrers, and Just How Much You Can Dance

February 14, 2022 — Garret Murai - California Construction Law Blog
Fights between owners and contractors under Business and Professions Code section 7031 can get nasty and detailed. An owner’s remedy under Section 7031, as courts have stated, can be “harsh[ ],” “draconian” and even “unjust” and damages can be significant. Panterra GP, Inc. v. Superior Court, 2022 WL 289216 (2022), a case decided this past month, is no different. It even involved a disagreement between the very justices deciding the case. The Panterra GP Case Panterra GP, Inc. was a licensed general contractor. Rosedale Bakersfield Retail VI, LLC and Movie Grill Concepts XX, LLC intended to hire Panterra GP to perform renovation work at the Studio Movie Grill in Bakersfield, California, but drafted a construction contract mistakenly listing Panterra Development Ltd., LLP as the contractor on the project. Panterra GP was the general partner of Panterra Development. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

A Property Tax Exemption, Misapplied, in Texas

June 18, 2019 — Anthony B. Cavender - Gravel2Gavel
In an important ruling for Texas businesses, the Texas Supreme Court has unanimously ruled that the TCEQ misapplied the Texas property tax’s exemption for specified pollution control equipment. Since 1993, the Texas Constitution has included a provision which authorizes the Texas Legislature to exempt from ad valorem taxation “all or part of real and personal property used … wholly or partly … for the control or reduction of air, water or land pollution.” This provision is implemented by Section 11.31 of the Texas Tax Code, which is administered by the Texas Commission on Environmental Quality. (See the rules at Title 30, Chapter 17 of the Texas Administrative Code.) If the Executive Director of the TCEQ determines that the equipment is used wholly or partly for pollution control, he issues a “positive use determination”; in the event it does not, the Executive Director issues a “negative use determination and rejects the application for the exemption. In 2007, Section 11.31 was amended at 11.31 (k) to list several items of equipment that are presumed to be pollution-control equipment, including “heat recovery steam generators” or HRSGs. This equipment is used by powerplants to reduce nitrogen oxide emissions that are the product of generation of electricity. Several applications were submitted to the TCEQ by the Brazos Electric Power Cooperative, seeking a tax exemption for its HRSG units. In July 2012, the TCEQ denied these applications, with the flat declaration that HRSGs are not pollution-control equipment—“they are used solely for production.” The Brazos Cooperative sued the Commission, and on May 3, 2019, in the case of Brazos Electric Power Cooperative, Inc. v. TCEQ, the Texas Supreme Court issued a unanimous opinion reversing the Commission, and the lower court (the Eight Court of Appeals, sitting in El Paso) that affirmed the Commission’s action. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---

DC District Court Follows Ninth Circuit’s Lead Dismissing NABA’s Border Wall Case

April 10, 2019 — Anthony B. Cavender - Gravel2Gavel
On February 14, the U.S. District Court for the District of Columbia dismissed the complaint of the National American Butterfly Association (NABA) alleging that the U.S. Government’s border wall preparation and law enforcement activities at NABA’s National Butterfly Center, located in South Texas along the Rio Grande River, violated federal environmental laws (National Environmental Policy Act (NEPA)) and the Endangered Species Act (ESA)) as well as NABA’s constitutional rights. The case is National American Butterfly Association v. Nielsen, et al. On January 25, 2017, the President issued an Executive Order to the Secretary of the Department of Homeland Security (Secretary) to “take all appropriate steps to immediately plan, design, and construct a physical wall along the southern border” with Mexico. A few weeks later, the Secretary issued a memorandum to the U.S. Customs and Border Enforcement to implement the Executive Order. The land occupied by the NABA has been affected by these actions, as well as other actions taken by the Secretary pursuant to her authority under the Illegal Immigration Reform and Immigrant Responsibility Act (IIRIRA), located at 8 U.S.C. § 1103. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---

New Jersey Imposes New Apprenticeship Training Requirements

February 11, 2019 — Joanna Masterson - Construction Executive
The New Jersey Senate and Assembly approved a bill (A-3666) that requires construction businesses to certify participation in a U.S. Department of Labor-approved apprenticeship program in order to obtain or renew a public works contractor registration certificate. The DOL-approved program requirements apply to every classification of worker employed on a public works jobsite. New Jersey businesses that don’t want to set up an in-house program can satisfy these mandates by participating in a trade association’s DOL-registered apprenticeship program. Reprinted courtesy of Joanna Masterson, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

NY Court Holds Excess Liability Coverage Could Never be Triggered Where Employers’ Liability Policy Provided Unlimited Insurance Coverage

February 28, 2018 — Theresa A. Guertin and Samantha M. Martino - SDV Blog
In a potentially significant development in New York insurance law, a recent appellate level decision held that an excess liability policy was not obligated to provide coverage where the underlying employer’s liability policy provided unlimited coverage pursuant to New York regulations. The Arthur Vincent & Sons Construction, Inc. v. Century Surety Insurance Co.1 case arose out of an underlying wrongful death claim. Fordham University hired Arthur Vincent and Sons Construction, Inc. (“AVSC”) to install a new roof on its Lewis Calder Center. As is typical of most construction contracts, AVSC agreed to indemnify the University against any claims arising out of its negligence, and to name the University as an additional insured on its commercial general liability policy. AVSC was insured by three policies: (1) a worker’s compensation and employer’s liability policy issued by Commerce and Industry Insur¬ance Company (“CIIC”); (2) a primary CGL policy issued by Century Surety Insurance Company (“Century”); and (3) an excess liability policy issued by Admiral Insurance Company (“Admiral”). Reprinted courtesy of Theresa A. Guertin, Saxe Doernberger & Vita, P.C. and Samantha M. Martino, Saxe Doernberger & Vita, P.C. Ms. Guertin may be contacted at tag@sdvlaw.com Ms. Martino may be contacted at smm@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---