Fairfield Connecticut Building Expert Directory

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Colorado House Bill 20-1290 – Restriction on the Use of Failure to Cooperate Defense in First-Party Claims

May 18, 2020 — David M. McLain – Colorado Construction Litigation
On February 7th, Representative Garnett, with Senator Fenberg as the Senate sponsor, introduced HB 20-1290, concerning the ability of an insurer to use a failure-to-cooperate defense in an action in which the insured has made a claim for insurance coverage. If the bill were to pass, in order to plead or prove a failure-to-cooperate defense in any action concerning first-party insurance benefits, the following conditions must be met:

The carrier has submitted a written request for information the carrier seeks to the insured or the insured’s representative, by certified mail;
The written request provides the insured 60 days to respond;
The information sought would be discoverable in litigation;

Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell
Mr. McLain may be contacted at mclain@hhmrlaw.com

2017 California Employment Law Update

January 13, 2017 — Evelin Y. Bailey - California Construction Law Blog
Below are some of the new laws going into effect this year that affect the construction industry. Unless otherwise noted, the laws go into effect on January 1, 2017. Public Works and Prevailing Wages You can read more about the new laws—AB 326, AB 1926 and SB 954—relating to public works and prevailing wages in an earlier blog post. Employment Contracts Choice of Forum and Choice of Law. Under SB 1241, an employer cannot require an employee who primarily works and resides in California to agree to file a lawsuit or bring a claim in another state when the claim arises in California. This is usually referred to as the choice of forum clause. Read the court decision
Read the full story...
Reprinted courtesy of Evelin Y. Bailey, Wendel Rosen Black & Dean LLP
Ms. Bailey may be contacted at ebailey@wendel.com

Effective Zoning Reform Isn’t as Simple as It Seems

July 03, 2022 — Yonah Freemark & Lydia Lo - Bloomberg
The Biden Administration’s Housing Supply Action Plan, unveiled last week, aims to help close America’s shortfall of almost 4 million housing units and subdue the nation’s skyrocketing home prices. At the top of its list of action items is a promise to provide federal grants as a reward to communities that alter land-use policies to promote density, an approach the administration is already piloting. But identifying the land-use policies that most effectively add housing is harder than it seems. Mounting evidence indicates that one-off reforms such as eliminating single-family-only zoning aren’t adequate. To make meaningful progress in building homes, municipalities have to do more. The Biden plan doesn’t detail how it will determine which types of policies will make a community eligible for these federal grants. But to meet the administration’s housing goals, we recommend it require that local governments seeking grants both show that their zoning changes are actually producing additional housing units, and also that their reforms include the full array of land-use policies that affect housing affordability. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

Contractor Sentenced to 7 Years for “Hail Damage” Fraud

November 13, 2013 — CDJ STAFF
The hailstorm might have spared homes in New Jersey, but the contractor didn’t. Marcin Gradziel entered a guilty plea when he was accused of filing fraudulent insurance claims for homes in New Jersey. In order to fool the inspectors from the insurance agency, after homeowners agreed to their pitch, Mr. Gradziel would damage their homes. After admitting this in court, Mr. Gradziel has now been sentenced to seven years in prison. His former employers, Precision Building, has gone out of business after paying restitution to the defrauded insurers. Read the court decision
Read the full story...
Reprinted courtesy of

Honoring Veterans Under Our Roof & Across the World

November 15, 2017 — Newmeyer & Dillion, LLP
November 11, 2017 - In honor of Veterans Day, we would like to take time to acknowledge, honor and thank those who have served in the United States Armed Forces. We are also proud to recognize eleven of our own who have served our great country. Ben Ammerman – United States Navy Philip Kopp – United States Air Force Ryan Manning – United States Marine Corps Jason Morris – United States Marine Corps Tyson Nakagawa - United States Marine Corps Richard Protzmann - United States Marine Corps Francis Quinlan - United States Marine Corps Louis “Dutch” Schotemeyer - United States Marine Corps Christina Soto-Maynez – United States Army Michael Studenka - United States Marine Corps Paul Tetzloff - United States Marine Corps About Us For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com. Read the court decision
Read the full story...
Reprinted courtesy of

US Supreme Court Orders All Mountain Valley Gas Line Work to Proceed

August 14, 2023 — Debra K. Rubin - Engineering News-Record
In a ruling without explanation in response to an emergency appeal by the project developer, the U.S. Supreme Court on July 27 said work to complete the Mountain Valley gas pipeline can proceed. The decision follows an order earlier this month by the Richmond, Va., appeals court to halt restart of work on the much-litigated and delayed $6.6-billion, 303-mile natural gas pipeline in Virginia and West Virginia, after new lawsuits filed by opponent groups. Reprinted courtesy of Debra K. Rubin, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

$5 Million Construction Defect Lawsuit over Oregon Townhomes

January 06, 2012 — CDJ STAFF

A homeowners’ association in Lake Oswego, Oregon has filed a $5 million lawsuit against the developers of the luxury townhomes. The homeowners of Sunset Crossing are suing Centurion Homes and Aspen Townhomes over claims that construction defects have lead to water intrusion and structural damages. The townhomes were built in 2005.

Andy Burns, the lawyer for Phillip and Patricia Gentelmann, the owners of both Centurion Homes and Aspen Townhomes, said the Gentelmanns were “taking these allegations very seriously.” The suit says that the construction violated state and local building codes and that the firms did not repair damage caused by water intrusion.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES