Fairfield Connecticut Building Expert Directory

The Sky is Falling! – Or is it? Impacting Lives through Addressing the Fear of Environmental Liabilities

March 30, 2016 — John Van Vlear and Karl Foster – Newmeyer & Dillion, LLP
Six months ago, a couple anxiously relayed to N&D lawyers how the sky was falling – with environmental liabilities at the center of their seemingly real Chicken Little fears. The couple owned two properties in a central California town, one being a former gas station which an oil company had abandoned alleging the lease was void given partial eminent domain actions. Before interviewing us, the couple had spent in excess of $100,000 in legal fees with another law firm trying to force the oil company to take responsibility for potential environmental impacts under the disputed lease. Reprinted courtesy of John Van Vlear, Newmeyer & Dillion, LLP and Karl Foster, Newmeyer & Dillion, LLP Mr. Van Vlear may be contacted at john.vanvlear@ndlf.com. Mr. Foster may be contacted at karl.foster@ndlf.com Read the court decision
Read the full story...
Reprinted courtesy of

Pa. Contractor Pleads No Contest to Prevailing-Wage Charges, Pays Workers $20.7M

September 20, 2021 — Tom Ichniowski - Engineering News-Record
Pennsylvania construction contractor Glenn O. Hawbaker Inc. has pleaded no contest to counts of theft of worker pay—in alleged violation of state prevailing-wage laws—and will pay 1,267 workers restitution of $20.7 million in unpaid wages, Pennsylvania Attorney General Josh Shapiro said. The company entered its plea to four felony counts of “theft by failure to make required disposition of funds received” on Aug. 3 before President Judge Pamela A. Ruest of the Centre County Court of Common Pleas in Bellefonte, Pa. Reprinted courtesy of Tom Ichniowski, Engineering News-Record Mr. Ichniowski may be contacted at ichniowskit@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Construction Litigation Roundup: “Tender Is the Fight”

August 21, 2023 — Daniel Lund III - Lexology
A performance bond surety for a defaulted general contractor principal found itself with a recalcitrant owner which refused to accept the tender of a replacement general contractor to complete a $3,000,000 construction project in Monmouth County, New Jersey. Even before the original GC was off the job, the surety – having been notified of the contractor’s difficulties in performing the work – stepped in promptly, providing assistance in the form of an additional contractor. At the surety’s behest, that additional contractor remained on the project (focused principally at the time on roof repairs) after the initial GC was placed in default and terminated. Eventually, the surety, by draft tender agreement issued to the owner, offered that the additional contractor serve as the completion contractor for the entire project (not simply the roof repairs), a proposal rejected by the owner – which had never cared for the additional contractor. Instead, the owner proposed its own completion contractor and, in connection with that offer, demanded a sum of money ($1.6 million) from the surety – a proposal the surety rejected: “[Owner] cannot choose whatever contractor it wants to complete the work and then charge the costs to [the surety]." Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Short on Labor, Israeli Builders Seek to Vaccinate Palestinians

February 01, 2021 — Ivan Levingston & Fadwa Hodali - Bloomberg
Israeli builders want the government to vaccinate Palestinian construction workers to help rally a battered housing industry. While Israel is racing to inoculate its citizens, the West Bank-based Palestinian Authority has no vaccination program in place. Beyond being a critical health issue, the gap is also an economic problem because the Israeli construction sector relies heavily on Palestinian workers who’ve been cut off repeatedly from building sites due to lockdowns. Before the pandemic, about 65,000 Palestinians worked for Israeli contractors inside Israel, accounting for a third of their workforce. Closures and restrictions on both sides led to a 30% drop in housing starts despite rising demand. Reprinted courtesy of Ivan Levingston, Bloomberg and Fadwa Hodali, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Business Interruption Claim Granted in Part, Denied in Part

February 16, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The court granted portions of the business interruption claim, while denying other portions. Phoenix Ins. Co. v. Infogroup, Inc., 2015 U.S. Dist. LEXIS 162810 (S. D. Iowa Nov. 30, 2015). Phoenix insured Infogroup's business buildings and personal business property, including data and data processing equipment. In late May 2011, warnings were issued of possible flooding from the Missouri River. On June 1, 2011, Infogroup moved and relocated its business operations and data centers away from the river and did not intend to return to the facilities. On July 19, 2011, Phoenix advanced $500,000 to Infogroup for anticipated claims under the policy. On August 22, 2011, heavy rain left surface water in the parking lot at Infogroup's facilities. Infogroup claimed that it suffered minor property damage during July and August, 2011, including damage to an uninterruptable power source and damage to a server. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Steel Component Plant Linked to West Virginia Governor Signs $1M Pollution Pact

January 04, 2023 — Mary B. Powers - Engineering News-Record
Bluestone Coke, a 100-year old Birmingham. Ala. factory that produces a key component in steelmaking and is partially owned by West Virginia Gov. Jim Justice, must pay nearly $1 million under a Dec. 9 state consent decree for violating federal clean air rules by releasing toxic emissions from coke ovens. Reprinted courtesy of Mary B. Powers, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Construction Defect Leads to Death, Jury Awards $39 Million

November 27, 2013 — CDJ STAFF
A failure in the installation of a 13-ton concrete panel in Milwaukee County lead to the death of a 15-year-old boy in 201; two others were also injured. A lawsuit over this has concluded with the contractor, Advance Cast Stone, found culpable due to their concealing that the panel was not installed as prescribed. The incident happened at a parking garage operated by the county. Advanced Cast Stone made the claim that the method they used to secure the panel had been approved by other in the project. The jury awarded $6.3 million to the estate of Jared Kellner, $1.5 million each to the young man who was injured, Eric Wosniki, and his parents. The county was also awarded $6 million for lost revenue in the parking garage and for repairs. Read the court decision
Read the full story...
Reprinted courtesy of

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES