Seattle Washington Building Expert Directory

Late Progress Payments on Local Public Works Projects Are Not a Statutory Breach of Contract

May 10, 2022 — Ted Senet & Christopher Trembley - Gibbs Giden
California local public agencies and their contractors should take note of a recent appellate decision pertaining to late progress payments on public works projects. In Clark Bros., Inc. v. North Edwards Water Dist., 2022 Cal. App. LEXIS 331, filed on April 22, 2022, the Court of Appeal for the Fourth Appellate District held that a local agency’s late progress payments to a general contractor did not constitute breach of contract under the prompt payment penalty statute, Public Contract Code § 20104.50. Notwithstanding this holding, the contractor recovered damages, interest, fees, and costs in excess of its contract amount. In 2013, the North Edwards Water District awarded a $6.2 million contract to Clark Bros., Inc. to construct a water treatment facility. The District’s water contained excessive levels of arsenic, and the project was sponsored by the State of California with funds earmarked to provide safe drinking water. The State agreed to disburse funds to the District during construction upon the State’s review and approval of the contractor’s progress payment applications. The contract required completion of the work within one year following the District’s issuance of a notice to proceed to the contractor. As a result of factors arguably outside the control of the contractor, including unforeseen site conditions and the failure of the District’s equipment supplier to meet delivery deadlines, the project was significantly delayed beyond the deadline for completion. The District nonetheless terminated the contractor, which in turn filed suit against the District and the State. The contractor asserted claims for breach of contract, including breach of contract for the District’s failure to pay the contractor’s progress payment applications within the time specified under Public Contract Code § 20104.50. Subsection (b) of the statute provides:

Any local agency which fails to make any progress payment within 30 days after receipt of an undisputed and properly submitted payment request from a contractor on a construction contract shall pay interest to the contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure.

Reprinted courtesy of Ted Senet, Gibbs Giden and Christopher Trembley, Gibbs Giden Mr. Senet may be contacted at tsenet@gibbsgiden.com Mr. Trembley may be contacted at Ctrembley@gibbsgiden.com Read the court decision
Read the full story...
Reprinted courtesy of

Columbus, Ohio’s Tallest Building to be Inspected for Construction Defects

July 16, 2014 — Beverley BevenFlorez-CDJ STAFF
Fox 28 news reported that “[t]he state of Ohio is going to spend more than $166,000 to inspect…the 40-year-old Rhodes Tower” in Columbus. "They're going to look at the exterior of the building - [at] sealants between the joints, the condition of the panels, the window systems, how they're draining, how they're operating, and how they're sealed," Ned Thiell, of Ohio Facilities Construction Commission, told ABC 6/FOX 28 news. A study completed last year declared there were “’deficiencies’ on the building’s stone covering” and there were “panels with severe fracture defects” that “will need to be replaced with new stone panels.” Read the court decision
Read the full story...
Reprinted courtesy of

Spencer Mayer Receives Miami-Dade Bar Association's '40 Under 40' Award

March 04, 2024 — Lewis Brisbois Newsroom
Miami, Fla. (February 23, 2024) – Miami Associate Spencer Mayer received the 2024 Miami-Dade Bar Association Young Lawyers Section’s '40 under 40' Award at the association's annual "Miami Nights" event on February 22. Mr. Mayer serves on the Board of Directors of the Miami Dade Bar Association’s Young Lawyers Section. Lewis Brisbois was a proud sponsor of this event, which raised funds for the organization's community service initiatives and pro bono programming. Mr. Mayer is a member of the General Liability Practice. His practice focuses on all aspects of civil litigation, including complex commercial litigation, products liability, premises liability, wrongful death, catastrophic injury, and insurance coverage. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

California Limits Indemnification Obligations of Design Professionals

August 24, 2017 — William L. Doerler - White and Williams LLP
The California legislature recently enacted legislation – SB 496 – limiting a design professional’s indemnification obligations in private contracts related to design services. The term “design professional” refers to licensed architects, landscape architects and professional land surveyors, and registered professional engineers. As revised, Cal. Civ. Code § 2782.8 states that, for all contracts entered into on or after January 1, 2018 for design professional services, all provisions that purport to have the design professional indemnify the indemnitee for claims against the indemnitee – or require the design professional to provide a defense to the indemnitee – are unenforceable except to the extent that the claims against the indemnitee arise out of, or relate to, the negligence, recklessness or willful misconduct of the design professional. In addition, as revised, § 2782.8 limits a design professional’s liability for the cost of defense to the design professional’s percentage of fault. Read the court decision
Read the full story...
Reprinted courtesy of William L. Doerler, White and Williams LLP
Mr. Doerler may be contacted at doerlerw@whiteandwilliams.com

Chinese Demand Rush for Australia Homes to Stay, Ausin Says

August 06, 2014 — Nichola Saminather – Bloomberg
Ausin Group (Finance) Pty, which offers property and mortgage broking in Australia to Chinese buyers, expects to sell two-thirds more homes and to double the amount of loans it arranges as demand from the mainland surges. The company forecasts A$1.5 billion ($1.4 billion) in sales of new residential properties in the year ending June 30, compared with A$900 million over the previous 12 months, Sydney-based Managing Director Joseph Zaja said in an interview yesterday. The value of mortgages the closely held company arranges through Australian banks is expected to climb to A$500 million in the 2015 calendar year, he said. Ausin is benefiting from surging demand from China, where the housing market is faltering. Chinese purchasers overtook Americans to become the biggest buyers of real estate in Australia in the 12 months through June 2013, plowing A$5.9 billion into commercial and residential property, a 42 percent increase from the previous 12 months. Read the court decision
Read the full story...
Reprinted courtesy of Nichola Saminather, Bloomberg
Ms. Saminather may be contacted at nsaminather1@bloomberg.net

Winning Attorney Fees in Litigation as a California Construction Contractor or Subcontractor

December 27, 2021 — William L. Porter - Porter Law Group
The General Rule in California: The Winner Does NOT Receive Attorney Fees and Costs: There is a common misconception that court decisions require the loser in a lawsuit to reimburse the winner for the fees and costs incurred during the lawsuit. Reliance on this misconception in developing a legal strategy for dealing with disputes is a serious strategic error. Where the legal issue is, for example, “breach of contract,” the general rule in California is that there are only two methods by which the winning litigant will be awarded the attorney fees and costs incurred in bringing or defending the lawsuit. The first of these is if the contract in question contains an effective attorney fee clause specifically providing that the prevailing party will recover their attorney fees and costs. The second is if there is a statute on point which provides that the prevailing party will be awarded those fees and costs. The general rule in California is that each party pays their own attorney fees and costs, unless there is an independent legal basis that provides otherwise. This is known as the “American Rule,” used throughout most of the country. The Issue is Important Because Spending More Money Than You Can Be Awarded is a Losing Strategy: The importance of whether the prevailing party in a lawsuit will be awarded their fees and costs cannot be underestimated. The party contemplating whether to bring a lawsuit must seriously consider whether it is even worth the trouble. In many cases, unless the one bringing the lawsuit (the “plaintiff”) is entitled to be reimbursed for the considerable attorney fees and costs incurred in bringing the case, it is just not worth doing so. There is no point spending $50,000 on attorneys on a $40,000 claim unless the plaintiff can be awarded both the $40,000 and the $50,000 if the plaintiff wins. Unless fees and costs are awarded, the plaintiff will still be out $10,000 in the very best of cases. For a party sued (the “defendant”) a similar situation arises in that the defendant faces the reality that it may be less expensive to just pay on a frivolous or false claim than to fight it. Either scenario is unsatisfactory. On the whole, it is beneficial to have an attorney fee clause in a contract when either a plaintiff or a defendant must vindicate its rights. Both deserve to be fully compensated to achieve justice. It is also beneficial to have an attorney fee clause in a contract to encourage the one who is at fault to resolve the case rather than risk paying the fees and costs of the other party who is likely to win the case. In either case, the presence of an attorney fee clause facilitates the party in the right and encourages resolution outside of litigation. These are admirable societal goals. Read the court decision
Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

Chicago Developer and Trade Group Sue City Over Affordable Housing Requirements

September 03, 2015 — Beverley BevenFlorez-CDJ STAFF
The Chicago Tribune reported that Hoyne Development and Home Builders Association of Greater Chicago are suing the city of Chicago, claiming that the “Affordable Requirements Ordinance is unconstitutional because it involves the taking of private party without ‘just compensation,’ violating the Fifth Amendment.” Shannon Breymaier, spokeswoman for Chicago Mayor Rahm Emanuel, however, disputes the claims, and told the Chicago Tribune in an email that the city planned to “defend the ordinance vigorously.” Read the court decision
Read the full story...
Reprinted courtesy of

ASCE Statement on Devastating Tornado Damages Throughout U.S.

December 20, 2021 — Tom Smith, Executive Director - American Society of Civil Engineers (ASCE)
WASHINGTON, DC. – We are deeply saddened by the tragic tornado storms that ravaged six states across the Midwest and Southeastern portions of the U.S. last Friday evening, resulting in loss of life in five of those six states. Even though warnings were issued throughout the region, storms of this magnitude can be difficult to prepare for. Nevertheless, as civil engineers, our mission is to continually advance the design and construction of safe, reliable, and resilient building structures and infrastructure systems to mitigate the damage caused by storms. ASCE 7 — a nationally-adopted, consensus-based engineering standard that is the primary reference of structural design requirements in all U.S. building codes — was recently updated to include a new chapter for tornado loads in the 2022 edition. The new tornado provisions in ASCE 7-22 were a result of a decade-long effort in partnership with the National Institute of Standards and Technology following the 2011 Joplin, MO Tornado. ASCE 7-22 provides updated design requirements for a variety of structures, including many of the types impacted by Friday's storms. In an effort to assist, the Structural Engineering Institute of ASCE is currently offering free access to a report issued after the Joplin, MO tornado in 2011 that killed more than 150 people. Joplin, Missouri, Tornado of May 22, 2011: Structural Damage Survey and Case for Tornado-Resilient Building Codes presents the observations, findings, and recommendations of an engineering reconnaissance team that surveyed residential structures and schools in the tornado path shortly after the event. The EF 5 tornado cut a seven-mile swath through Joplin, Missouri; it destroyed more than 5,000 buildings and killed more than 150 people. We will continue to keep those who have been affected in our hearts and thoughts, and we share our heartfelt sympathies. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel. Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES