Late Progress Payments on Local Public Works Projects Are Not a Statutory Breach of Contract
May 10, 2022 —
Ted Senet & Christopher Trembley - Gibbs GidenCalifornia local public agencies and their contractors should take note of a recent appellate decision pertaining to late progress payments on public works projects. In Clark Bros., Inc. v. North Edwards Water Dist., 2022 Cal. App. LEXIS 331, filed on April 22, 2022, the Court of Appeal for the Fourth Appellate District held that a local agency’s late progress payments to a general contractor did not constitute breach of contract under the prompt payment penalty statute, Public Contract Code § 20104.50. Notwithstanding this holding, the contractor recovered damages, interest, fees, and costs in excess of its contract amount.
In 2013, the North Edwards Water District awarded a $6.2 million contract to Clark Bros., Inc. to construct a water treatment facility. The District’s water contained excessive levels of arsenic, and the project was sponsored by the State of California with funds earmarked to provide safe drinking water. The State agreed to disburse funds to the District during construction upon the State’s review and approval of the contractor’s progress payment applications. The contract required completion of the work within one year following the District’s issuance of a notice to proceed to the contractor.
As a result of factors arguably outside the control of the contractor, including unforeseen site conditions and the failure of the District’s equipment supplier to meet delivery deadlines, the project was significantly delayed beyond the deadline for completion. The District nonetheless terminated the contractor, which in turn filed suit against the District and the State. The contractor asserted claims for breach of contract, including breach of contract for the District’s failure to pay the contractor’s progress payment applications within the time specified under Public Contract Code § 20104.50. Subsection (b) of the statute provides:
Any local agency which fails to make any progress payment within 30 days after receipt of an undisputed and properly submitted payment request from a contractor on a construction contract shall pay interest to the contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure.
Reprinted courtesy of
Ted Senet, Gibbs Giden and
Christopher Trembley, Gibbs Giden
Mr. Senet may be contacted at tsenet@gibbsgiden.com
Mr. Trembley may be contacted at Ctrembley@gibbsgiden.com
Read the court decisionRead the full story...Reprinted courtesy of
How the California and Maui Wildfires Will Affect Future Construction Projects
October 30, 2023 —
Susan Doering - Construction ExecutiveJust like any kind of fire, wildfires are caused by the presence of fuel and a spark. In the case of the
2017 fires in the wine country of California, along with the state's 2018
Camp Fire, the fuel was dry leaf litter, branches and downed trees. And the spark, in some cases, resulted from electric utility lines and, in other cases, due to contractor’s work.
More recently, this summer's Maui fires have taken hundreds of lives—deceased and missing—and burned more than 2,500 acres. Lahaina’s historic sites cannot be replaced, and estimates of the rebuild costs are near $5 billion. In Hawaii, the fuel was the same as in California: dried forest debris. It is alleged that the spark was from a powerline downed by extreme winds from Hurricane Dora. While sparks were present, it is the increased volume of fuel that has been the true source of the disastrous recent wildfires.
The increased presence of fuel is the result of recent changes in forestry-management practices, coupled with accelerated climatic shifts in recent years toward hotter, drier weather from 2011 to 2020 in California and 2022 to 2023 in Maui, increasing both frequency and severity.
Reprinted courtesy of
Susan Doering, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Will Superusers Future-Proof the AEC Industry?
May 13, 2019 —
Aarni Heiskanen - AEC BusinessDesign professionals who leverage tools and technology and, at the same time, have people skills, are essential to the future of the industry. They are Superusers, the protagonists of the latest book by Randy Deutsch.
Randy Deutsch is an architect, educator, workshop leader, writer, and international keynote speaker. I had a chance to interview him about his book, Superusers: Design Technology Specialists and the Future of Practice.
First, I was curious to know why he chose this topic for his fourth book. He explains: “Right now, it made a lot of sense to focus on the individual, not focus on collaboration and building teams, and really define what each individual team member should be.”
Who Are Superusers?
IT, technology, and tool specialists are typically experts in a relatively narrow field. Designers, especially architects, must have a wider perspective. Superusers are design technologists; liaisons between business needs and technology solutions. They demonstrate certain skillsets and mindsets.
Read the court decisionRead the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
aec-business@aepartners.fi
Can’t Get a Written Change Order? Document, Document, Document
August 29, 2018 —
Todd M. Heffner - Smith CurrieMost construction contracts require that any changes to the work be made formally, in writing, via a change order, work directive, or similar written document. Frequently, however, changes to the work or extra work are communicated orally by the architect, engineer, or owner’s representative, instead of in writing. What is the contractor to do in such a situation? The best option is follow the provisions of the contract and demand a written change order before performing changed work. Unfortunately, the realities of construction sometimes make it impossible to get the changes in the proper format in a timely manner. Savvy contractors will maintain schedule and produce written documentation of the change in lieu of a formal change order or directive. But many contractors will simply proceed with the changed work, relying on the owner, architect, or engineer to do the right thing and stand by their oral instructions.
Read the court decisionRead the full story...Reprinted courtesy of
Todd M. Heffner, Smith CurrieMr. Heffner may be contacted at
tmheffner@smithcurrie.com
Orion Group Holdings Honored with Leadership in Safety Award
October 09, 2023 —
Orion Group Holdings, Inc.HOUSTON, Oct. 06, 2023 (GLOBE NEWSWIRE) -- Orion Group Holdings, Inc. (NYSE: ORN) ("Orion" and "Company"), a leading specialty construction and engineering company today announced it received the Company Award for Leadership in Safety from the Council of Dredging and Marine Construction Safety (CDMCS). The award, presented at the 2023 CDMCS Annual Awards Dinner in Washington, D.C. on September 28, recognizes outstanding safety leadership in the dredging and marine construction industry.
Orion Group Holdings was recognized for advancing a safety-first culture through safety-conscious policies and procedures in the workplace, mentoring others in safety, training on identifying and properly controlling hazards, and placing high personal value on collaborative and proactive work toward improving safety. Travis Boone, President and Chief Executive Officer of Orion Group Holdings, accepted the award at the ceremony.
"I am honored to accept this award on behalf of our Orion team, who work collaboratively every day to meet exacting standards while safely delivering world-class marine construction and dredging services to our customers," said Orion Group Holdings CEO Travis Boone. "Our safety-through-leadership success is born out of a strong advocacy for accident prevention, innovative training and a commitment to exceeding regulatory compliance. Being responsible and accountable is a priority for every team member, with special emphasis on performing every task safely, every time."
About Orion Group Holdings
Orion Group Holdings, Inc., a leading specialty construction company serving the infrastructure, industrial and building sectors, provides services both on and off the water in the continental United States, Alaska, Hawaii, Canada and the Caribbean Basin through its marine segment and its concrete segment. The Company's marine segment provides construction and dredging services relating to marine transportation facility construction, marine pipeline construction, marine environmental structures, dredging of waterways, channels and ports, environmental dredging, design, and specialty services. Its concrete segment provides turnkey concrete construction services including place and finish, site prep, layout, forming, and rebar placement for large commercial, structural and other associated business areas. The Company is headquartered in Houston, Texas with regional offices throughout its operating areas. https://www.oriongroupholdingsinc.com.
Read the court decisionRead the full story...Reprinted courtesy of
Want to Use Drones in Your Construction Project? FAA Has Just Made It Easier.
March 01, 2017 —
Masaki J. Yamada – Ahlers & Cressman PLLCThe new Part 107 FAA Rules took effect on Monday, August 29, 2016. Unlike the previous requirements for flying a drone commercially, the new rules are much more simplistic and permissive of a broad amount of commercial drone usage.
The following is the basic knowledge you need to legally use a drone on your future projects. To fly a drone commercially, there are now four major requirements:
- You must be at least sixteen years old;
- You must register your drone online;
- You must pass an aviation knowledge test administered at an FAA-approved testing center; and
- You must pass review by the Transportation Security Administration.
Read the court decisionRead the full story...Reprinted courtesy of
Masaki J. Yamada, Ahlers & Cressman PLLCMr. Yamada may be contacted at
myamada@ac-lawyers.com
Tick Tock: Don’t Let the Statute of Repose or Limitations Time Periods Run on Your Construction Claims
February 28, 2022 —
Gus Sara - The Subrogation StrategistIn Wascher v. ABC Ins. Co., No. 2020AP1961, 2022 Wisc. App. LEXIS 110 (Feb. 9, 2022), the Court of Appeals of Wisconsin considered whether the plaintiffs were barred — by Wisconsin’s 10-year statute of repose for improvements to real property claims and the six-year statute of limitations for breach of contract claims — from bringing a lawsuit against the original builders of their home. The plaintiffs alleged negligence and breach of contract against the masonry subcontractors, asserting that they improperly installed the exterior stone cladding. The court found that the plaintiffs’ claims against the original builders were time-barred.
In 2005, the plaintiffs, Thomas and Pamela Wascher (the Waschers) retained Mathwig Builders (Mathwig) as the general contractor for the construction of their home in Greenville, Wisconsin. Mathwig subcontracted defendants Natural Surfaces, LLC (Natural Surfaces) and Carved Stone Creations (CSC) to install the stone cladding on the exterior walls and patio for the home. On November 3, 2008, the Township of Greenville inspected the home and granted the Waschers permission to occupy the residence. The Waschers moved into the home within the next few weeks. In early 2009, the Waschers discovered efflorescence on the stone cladding for the patio. In 2010, the Waschers hired CSC to repair the stone cladding. CSC removed some stone, which revealed that flashing had not been installed behind the stone, which caused water to infiltrate the stone and patio.
Read the court decisionRead the full story...Reprinted courtesy of
Gus Sara, White and WilliamsMr. Sara may be contacted at
sarag@whiteandwilliams.com
Meet D1's Neutrals Series: BILL FRANCZEK
August 14, 2023 —
Jessica Knox - The Dispute ResolverCompany: Woods Rogers Vandeventer Black PLC
Office Location: Norfolk, VA
Email: Bill.Franczek@wrvblaw.com
Website: https://wrvblaw.com/attorney_/william-e-franczek/
Law School: Syracuse University Law – JD, 1982, Magna Cum Laude, Order of the Coif
Types of ADR services offered: Arbitration, Dispute Resolution Boards and Panels, Mediation and Neutral Evaluations
Affiliated ADR organizations: American Arbitration Association (AAA); International Institute for Conflict Prevention and Resolution (CPR); London Court of International Arbitration (LCIA); International Court of Arbitration (ICC)
Geographic area served: Nationwide
Q: Describe the path you took to becoming an ADR neutral.
A: I have an undergraduate degree in Civil Engineering and a Professional Engineering License in NY and VA. So, when I became a lawyer, I applied for membership in the AAA, and was accepted as a construction neutral in 1987. I now practice construction law and serve as an ADR Neutral in matters across the country and internationally.
Read the court decisionRead the full story...Reprinted courtesy of
Jessica Knox, Stinson LLPMs. Knox may be contacted at
jessica.knox@stinson.com
