Seattle Washington Building Expert Directory

Balancing Cybersecurity Threats in Smart Cities: Is the Potential Convenience of “Smart” Intersections Worth the Risk?

September 02, 2024 — James P. Bobotek & Brian E. Finch - Gravel2Gavel Construction & Real Estate Law Blog
The term “smart cities” has become popular parlance for municipalities’ attempts to enhance delivery of urban services and infrastructure through information and communications technology. While they may conjure images of neon-lit high rises or streetscapes populated by sleek, hovering vehicles, a bit like the 1960s-era The Jetsons cartoon envisioned our high-tech future, the reality of smart cities has begun to emerge in more subtle, less glamourous forms. Cities tend to focus on wastewater monitoring, traffic control and energy distribution technologies in their efforts to become incrementally “smarter.” Smart cities lean heavily on automation, internet connectivity and the Internet of Things (IoT)—including smartphones, connected cars and a host of web-based appliances and utilities—to boost the delivery and quality of essential urban services and infrastructure like transit, sanitation, water, energy, emergency response and more. Successful smart cities need infrastructure that supports such connectivity, and they pull data from hundreds, or even thousands, of sensors that can be used to analyze and shepherd the direction of resources. Reprinted courtesy of James P. Bobotek, Pillsbury and Brian E. Finch, Pillsbury Mr. Bobotek may be contacted at james.bobotek@pillsburylaw.com Mr. Finch may be contacted at brian.finch@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Contractor Entitled to Defense for Alleged Faulty Workmanship of Subcontractor

February 10, 2020 — Tred R. Eyerly - Insurance Law Hawaii
Applying Nevada law, the Federal District Court in Florida found that the general contractor was entitled to a defense of claims based upon alleged faulty workmanship of a subcontractor. KB Home Jacksonville LLC v. Liberty Mutual Fire Ins. Co, 2019 U.S. Dist. LEXIS 151235 (M.D. Fla. Sept 5, 2019). KB Home completed six residential developments utilizing various subcontractors. One subcontractor was Florida State Plastering, LLC (FSP) for installing stucco. Eighty-eight complaints against KB Home implicated FSP's stucco work. Plaintiffs alleged that the stucco subcontractor's work suffered from construction defects, causing damages not only to the exterior stucco, but also the underling wire lath, paper backing, house wrap, wood sheathing, interior walls, interior floors and other property. Ironshore insured FSP under a CGL policy. KB Home was an additional insured for liability for property damage caused by "your work." KB Home was also insured under its own CGL policy with Liberty Mutual. Both insurers refused to defend. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Killer Subcontract Provisions

January 20, 2020 — Patrick McNamara - Porter Law Group
We are frequently requested by subcontractor clients to review the subcontract that has been prepared by the prime contractor, before our client signs it. While no two agreements are identical, there are a number of problematic contract provisions that appear in many agreements. Here is a list of ten such provisions (and their variations) that are potential “deal breakers”:

PAY IF/WHEN PAID (e.g. “Contractor shall have the right to exhaust all legal remedies, including appeals, prior to having an obligation to pay Subcontractor.”) “Pay-if-paid” provisions (“Receipt of payment from Owner shall be a condition precedent to Contractor’s duty to pay Subcontractor”) are illegal in California. However, the only legal limit on “Pay-When-Paid” provisions is that payment must be made “within a reasonable time.” The example above, as written, essentially affords the prime contractor a period of several years following completion of the project before that contractor has an independent duty to pay its subcontractors – not a “reasonable” amount of time, to those waiting to be paid. A compromise is to provide a time limit, such as 6 months or one year following substantial completion of the project.
CROSS-PROJECT SET-OFF (e.g. “In the event of disputes or default by Subcontractor, Contractor shall have the right to withhold sums due Subcontractor on this Project and on any other project on which Subcontractor is performing work for Contractor.”) Such provisions are problematic and likely unenforceable, as they potentially bar subcontractors’ lien rights. Such provisions should be deleted.
CONTRACTOR/SUBCONTRACTOR RESPONSIBILITY FOR DESIGN QUALITY (e.g. “Subcontractor warrants that the Work shall comply with all applicable laws, codes, statutes, standards, and ordinances.”) Unless a subcontractor’s scope of work expressly includes design work, this provision should either be deleted or modified, with the addition of the following phrase: “Subcontractor shall not be responsible for conformance of the design of its work to applicable laws, codes, statutes, standards, and ordinances.”

Read the court decision
Read the full story...
Reprinted courtesy of Patrick McNamara, Porter Law Group
Mr. McNamara may be contacted at pmcnamara@porterlaw.com

Drone Use On Construction Projects

June 05, 2023 — Brent N. Mackay - ConsensusDocs
The use of drones, or small unmanned aircraft systems (“UAS”), has become common throughout the construction industry in all phases of construction, including pre-construction, progress of the work, project closeout, and maintenance. This article examines the federal regulations related to drone use, as well as considerations for construction professionals related to state and local laws, project location, and weather issues. Federal Regulations Regardless of the state in which the project is located, companies and persons operating commercial drones must observe regulations promulgated by the Federal Aviation Administration (“FAA”), which has the exclusive authority to regulate aviation safety, airspace navigation, and air traffic control. Reprinted courtesy of Brent N. Mackay, Watt, Tieder, Hoffar, & Fitzgerald, LLP (ConsensusDocs) Mr. Mackay may be contacted at bmackay@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

Newmeyer & Dillion Gets Top-Tier Practice Area Rankings on U.S. News – Best Lawyers List

November 03, 2016 — Newmeyer & Dillion LLP
Prominent business and real estate law firm Newmeyer & Dillion LLP is pleased to announce that U.S. News–Best Lawyers® recognized six practice areas from its Orange County office for inclusion in its Best Law Firms rankings for 2017. Five of the six areas were ranked as tier 1, the highest ranking available, including commercial litigation, construction law, insurance law, litigation- construction and litigation- real estate. Real estate law as also recognized as tier 3. Jeff Dennis, Newmeyer & Dillion’s Managing Partner, believes these rankings reflect the quality of work Newmeyer & Dillion offers. “Our firm was built on the culture of excellent personalized service and achieving the best results possible. This is a great honor for our firm knowing that our clients and peers value the offerings we provide.” About Newmeyer & Dillion For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com. Read the court decision
Read the full story...
Reprinted courtesy of

Construction Law Alert: Builder’s Alternative Pre-litigation Procedures Upheld Over Strong Opposition

April 01, 2014 — Steven M. Cvitanovic and Whitney L. Stefko - Haight Brown & Bonesteel, LLP
Last week, the Court of Appeal, Fifth Appellate District, was tasked with evaluating the enforceability of provisions in home purchase contracts containing alternative pre-litigation procedures which differ from the standard Right to Repair Act procedures. The Court of Appeal, in McCaffrey v. Superior Court of Fresno, et al. ultimately upheld the contractual provisions, and in overturning the trial court's decision, preserved the rights of builders to contract around certain requirements set forth in the Right to Repair Act. The McCaffrey Group, Inc. constructed single-family homes in a Fresno development. Plaintiffs consisted of 24 homeowners within the development who brought suit against McCaffrey for construction defects in their homes. The homeowners were comprised of three categories: (1) the original purchasers who bought their homes from McCaffrey before January 1, 2003 and had a 2001 version of McCaffrey's contract; (2) the original purchasers who bought their homes from McCaffrey on or after January 1, 2003 and signed a 2003 version of McCaffrey's contract; and (3) the subsequent purchasers who did not buy their homes directly from McCaffrey, but purchased their homes subject to either the 2001 or 2003 version of McCaffrey's home purchase agreement. Reprinted courtesy of Steven M. Cvitanovic, Haight Brown & Bonesteel LLP and Whitney L. Stefko, Haight Brown & Bonesteel LLP Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com; Ms. Stefko may be contacted at wstefko@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

The Four Forces That Will Take on Concrete and Make Construction Smart

September 17, 2018 — Massimiliano Moruzzi - Construction Executive
When it comes to building a bridge, what prevents it from having the most enduring and sustainable life span? What is its worst enemy? The answer is, simply, the bridge itself—its own weight. Built with today’s construction processes, bridges and buildings are so overly massed with energy and material that they’re inherently unsustainable. While concrete is quite literally one of the foundations of modern construction, it’s not the best building material. It’s sensitive to pollution. It cracks, stainsand collapses in reaction to rain and carbon dioxide. It’s a dead weight: Take San Francisco’s sinking, leaning Millennium Tower as an example. Reprinted courtesy of Massimiliano Moruzzi, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES