Fairfield Connecticut Building Expert Directory

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Yet ANOTHER Reminder to Always Respond

July 11, 2021 — Christopher G. Hill - Construction Law Musings
You would think I wouldn’t have to discuss the absolute need to respond to any served pleadings, particularly after some of the prior examples of what can happen if you fail to respond. Of course, I wouldn’t be starting a post like this if those that were sued contacted an experienced attorney in a timely fashion and followed this advice. Yet another example of the disastrous results that can occur simply from failing to file responsive pleadings occurred last year in the Eastern District of Virginia federal court in Alexandria, VA. In Pro-Telligent, LLC v. Amex Int’l, Inc. the Court considered a claim for breach of contract (among other causes of action) by Pro-Telligent against Amex. The operative facts are that Pro-Telligent was a subcontractor to Amex that claimed it was unpaid in the amount of $279,660.27, its Complaint was served on January 7, 2021, and Amex did not respond within the required 21-day window. The Court then held a hearing on February 28, 2020, regarding the validity of the Clerk of Court’s entry of default per the rules of court. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

The Three L’s of Real Estate Have New, Urgent Meaning

April 15, 2024 — Mark Gongloff - Bloomberg
What will it take to make Americans stop rushing headlong into climate peril? Cheaper housing in safer places, for one thing. But maybe big red flags on property listings will help, too. Redfin Corp., the digital real estate company, last week added air-quality data to its listings as part of its “climate risks” feature, which aims to warn homebuyers of the chances their dream home could succumb to a global-warming nightmare. Using data from the climate research firm First Street Foundation, Redfin estimates a property’s current and predicted risk levels for flooding, wildfires, extreme heat, high winds — and now days when the Environmental Protection Agency’s Air Quality Index tops 100, a category known as “unhealthy for sensitive groups.” Read the court decision
Read the full story...
Reprinted courtesy of Mark Gongloff, Bloomberg

Turning Back the Clock: DOL Proposes Previous Davis-Bacon Prevailing Wage Definition

April 19, 2022 — David Chidlaw & Carina Novell - Sheppard Mullin Construction & Infrastructure Law Blog
On March 11, 2022, the Department of Labor (“DOL”) proposed reverting the definition of “prevailing wage” under the Davis-Bacon Act to a definition used over 40 years ago. According to the DOL, the proposal is meant to modernize the law and “reflect better the needs of workers in the construction industry and planned federal construction investments.”[1] Brief History Lesson The Davis-Bacon Act was enacted in 1931 and requires the payment of locally prevailing wages and fringe benefits on federal construction contracts. The law applies to workers on contracts in excess of $2,000 entered into by federal agencies and the District of Columbia for the construction, alteration, or repair of public buildings or public works.[2] From the 1930s to the early 1980s, the DOL used the following three-step process to define prevailing wage:

Any wage rate paid to a majority of workers.
If there was no wage rate paid to a majority of workers, then the wage rate paid to the greatest number of workers, provided it was paid to at least 30 percent of workers (i.e., the “30 percent rule”).
If the 30 percent rule was not met, the weighted average rate.

Reprinted courtesy of David Chidlaw, Sheppard Mullin and Carina Novell, Sheppard Mullin Mr. Chidlaw may be contacted at dchidlaw@sheppardmullin.com Ms. Novell may be contacted at cnovell@sheppardmullin.com Read the court decision
Read the full story...
Reprinted courtesy of

Construction Litigation Roundup: “You May Want an Intervention …”

June 10, 2024 — Daniel Lund III - Lexology
You may want an intervention … but you are not getting one! So said a federal court in New Orleans to a masonry supplier seeking to intervene in in an upstream subcontractor’s lawsuit against a payment bond surety for allegedly unpaid subcontract sums. It all seems so obvious: the masonry supplier indicates it is unpaid, and the subcontractor to which it supplied materials is saying the same thing and pursuing monies from the general contractor’s surety. Eventually, if the subcontractor prevails against the surety, monies ought to flow to the supplier – a set of facts lending itself to an intervention. The federal district court disagreed, however. Referring to Federal Rule of Civil Procedure 24(a)(2) and prior United States Fifth Circuit Court of Appeals case law the topic, the court opined that the masonry supplier lacked an interest in the subcontractor’s potential recovery that was “related to the property or transaction that forms the basis of the controversy…an interest that is ‘direct, substantial, [and] legally protectable.’" Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Workers Hurt in Casino Floor Collapse

February 10, 2012 — CDJ STAFF

More than a dozen construction workers fell about thirty feet when a floor collapsed in a Cincinnati casino. The workers were pouring cement on the second-floor level when the accident happened. The area in question will be the gaming area in the completed casino. Scott Allen, OSHA’s regional spokesperson, said their investigation of the accident would probably take about a month to complete.

The cause of the collapse is still undetermined. Although the weather has been wet in the area, experts thought it unlikely to be the cause. A construction forensics professor at Ohio State University said that “concrete pouring is very common” and that “you cannot go wrong unless something happens with the connection.” Engineering experts said it was more likely an issue with the metal decking.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

New Spending Measure Has Big Potential Infrastructure Boost

February 14, 2018 — Tom Ichniowski – ENR
Construction and engineering companies find lots of good news in a newly enacted budget and appropriations package that keeps federal agencies open until late March, provides $89 billion for post-disaster relief and rebuilding and also holds out the prospect of an additional $20 billion in infrastructure funding over the next two years. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, Engineering News-Record
Mr. Ichniowski may be contacted at ichniowskit@enr.com

New Case Law Alert: Licensed General Contractors Cannot Sue Owners to Recover Funds for Work Performed by An Unlicensed Subcontractor

May 30, 2022 — Michele A. Ellison & Samantha R. Riggen - Gibbs Giden
The opinion in Kim v. TWA Construction, Inc. (2022 Cal. App. LEXIS 412) issued by the Court of Appeal of California Sixth Appellate District, on May 13, 2022, makes it clear that a properly licensed general contractor cannot bring an action for compensation from an owner for work performed by an unlicensed subcontractor. California licensing law has long made explicit that an unlicensed contractor cannot bring or maintain any action to collect or recover compensation for work that contractor performed unless they were duly licensed at all times during the performance of that work. This new ruling extends the scope of this restriction to licensed contractors who hired unlicensed subcontractors. The Underlying Dispute The case involved a dispute between property owners and their former general contractor and its principal (collectively “TWA”). The property owners hired TWA to construct a home, and during the early stages of the project, TWA hired an unlicensed subcontractor to perform tree trimming services and to remove a large eucalyptus tree. The subcontractor partially removed the eucalyptus tree, but was stopped by a neighbor, and it was discovered that the tree was partly located on the neighbor’s property. The neighbor brought suit against the property owners, and eventually TWA, for the damage. The property owners subsequently filed a cross-complaint against TWA, and TWA in turn filed a cross-complaint against the property owners. Reprinted courtesy of Michele A. Ellison, Gibbs Giden and Samantha R. Riggen, Gibbs Giden Ms. Ellison may be contacted at mellison@gibbsgiden.com Ms. Riggen may be contacted at sriggen@gibbsgiden.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES