COLUMBUS OHIO BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---

A Word to the Wise about Construction Defects

October 10, 2013 — CDJ STAFF
A post on The Buckner Blog suggests that “construction defects” are the scariest words for architects, engineers, and contractors. With the possible outcomes of a damaged reputation and astronomical costs, it’s not a surprise. Further, builders are using techniques that “have yet to be tested in real application over time.” As a result, “whoever has the deepest pockets or the most to lose becomes the primary target.” While a commercial general liability policy might pay for damage caused by a construction defect, the post notes that “it does not, however, cover the costs to remedy your work.” That cost could be “greater than the actual property damages incurred.” The post recommends a combination of transferring risk and risk control In transferring risk, the builder uses “indemnification and hold harmless agreements as well as inditional insured requirements in their construction contracts.” They advise to “request coverage as an additional insured on a primary basis.” And then there’s risk control. “Work only with architects, engineers and contactors who have good reputations and a track record of performance. Don’t cut corners.” By some careful planning, builders might “sleep better at night.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Contractor Sues License Board

June 30, 2011 — CDJ STAFF

Judge Kendall J. Newman of the US District Court handed down a decision on June 24 on the case of Kent v California Department of Consumer Affairs. Mr. Kent, appearing as his own counsel, had brought the suit against the California Department of Consumer Affairs and the Contractors State Licensing Board after he was arrested in a sting operation and, as the plaintiff put it, “was absurdly arrested and uncooperatively detained for a time longer than necessary or allowed by law under the false pretense of contracting with out a license.” Mr. Kent’s alleged that Rick Lopez, one of the defendants, formed him to read allow from the California Business and Professions Code. He said he was later handcuffed and placed in an uncomfortable chair, “enduring physical pain and emotional agony.”



Although Kent was given a Notice to Appear, he alleged that a further defendant, Stuart Rind, “closed the plaintiff’s case marked citation A7773 without giving written notice to anyone.” As a result, the Placer County District Attorney’s Office had no record of his Notice to Appear.



Kent alleged that subsequently his firm was essentially shut down for two years and that he was prevented from “legally contracting or selling services for any other contractor or qualifying for any other licensed capacity governed by the CSLB.” After this, the CSLB suspended the license for his firm, DSI Construction. He was assessed a $1,500 fine, after which he claims he sent a letter to the CSLB demanding money damages. The judge noted that the letter was not included in the plaintiff’s Ninth Amended Complaint.



Judge Kendall recommended that the plaintiff’s Complaints be dismissed, although he did allow that sixth, and perhaps the eighth and ninth, could be amended with a tenth amended complaint.



Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Real Estate & Construction News Roundup (1/16/24) – Algorithms Affect the Rental Market, Robots Aim to Lower Construction Costs, and Gen Z Struggle to Find Their Own Space

February 12, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, New York’s Prompt Payment Act comes into question, vacancy rates rise in commercial office space, the Biden administration applies project labor agreements on certain federal construction projects, and more!

• The Biden administration announced the implementing on an executive order that will require project labor agreements on federal construction projects costing $35 million or more, likely resulting in PLAs being required on a majority of large federal jobs. (Zachary Phillips, Construction Dive)
• Boeing plans to increase quality inspections of its 737 Max 9 aircraft, following a series of manufacturing flaws that have led some airlines to hold off aircraft purchases or go with its European rival, Airbus. (Ken Sweet, AP)
• 31% of Generation Z (generally defined as those born between 1996 and 2012) adults live at home with parents because they can’t afford to buy or rent their own space. (Jessica Dickler, CNBC)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Tall Mass Timber Buildings Now Possible Under 2021 IBC Code Changes

February 03, 2020 — Kenneth Bland - Construction Executive
The International Code Council (ICC) has approved 17 changes to the 2021 editions of the International Building Code (IBC) and International Fire Code, allowing for mass timber buildings up to 18 stories. With the addition of three new mass timber construction types (Type IV-A, IV-B, and IV-C), this is the first time in the history of the modern building code that significantly new construction types have been added to the code. Building Materials The primary building material that makes tall mass timber (TMT) buildings possible is cross-laminated timber (CLT). CLT is manufactured from dimension lumber (nominal 2x lumber) laid side-by-side or mass plywood panels of a specified width. Laminations of lumber are typically laid perpendicular to each other to form panels of various thicknesses that are bonded together using heat resistant adhesives that cure in large hydraulic presses. CLT commonly consists of an odd number of laminations. These solid wood panels can be anywhere from 6 inches to 20 inches nominal thickness and 60 feet long. Typical CLT panels will be 6 inches to 14 inches nominal thickness. The panels are fabricated off site, transported onto the construction site and assembled in a manner that is efficient and remarkably fast. CLT panels can be used as floor, wall, or roof building elements supported by glued-laminated beams and columns. Reprinted courtesy of Kenneth Bland, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

Toll Brothers Climbs After Builder Reports Higher Sales

February 26, 2015 — John Gittelsohn – Bloomberg
(Bloomberg) -- Toll Brothers Inc., the largest U.S. luxury-home builder, rose the most in a year after the company reported a higher-than-expected quarterly profit and said it sold more properties at higher prices. Net income for the three months through January was $81.3 million, or 44 cents a share, compared with $45.6 million, or 25 cents, a year earlier, the Horsham, Pennsylvania-based builder said in a statement Tuesday. The average of 14 estimates was for 28 cents a share, according to data compiled by Bloomberg. Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn, Bloomberg
Mr. Gittelsohn may be contacted at johngitt@bloomberg.net

---

In Review: SCOTUS Environmental and Administrative Decisions in the 2020 Term

August 10, 2021 — Anthony B. Cavender - Gravel2Gavel
Several decisions of interest were issued in the 2020 term, which stretched from October 2020 until early July 2021. This review will concentrate on environmental and administrative law cases. Texas v. New Mexico On December 14, 2020, the Court issued its ruling in an Original Action. Water is precious in the Pecos River Valley, and the distribution of water is governed by the Pecos River Compact. Here, Texas complained that New Mexico illegally was seeking delivery credits for evaporated water credits but the Court agreed that New Mexico was entitled to these credits under the provisions of the River Master’s Manual. Florida v. Georgia On April 1, 2021, in another waters right ruling on an Original Action filed in the Supreme Court, the Court rejected Florida’s claims that Georgia’s use of interstate waters harmed Florida’s businesses. Florida had to satisfy a heavy burden of proof, which it failed to do. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---

Engineers Propose 'River' Alternative to Border Wall

May 10, 2017 — Frank K. Johnson - Engineering News-Record
Of all the ideas that have been suggested for the border wall, there is one that may help to bring together Mexico and the U.S., instead of pitting the countries against each another over illegal immigration. I’m part of a group of civil engineers in Massachusetts that has conceived of a program that is based on a recently acquired patent for an advanced concrete construction technology for building large-scale, monolithic concrete structures capable of physically partitioning two countries while serving to promote economic development. This fast and thrifty construction method and our proposed program prove that, as far as creativity is concerned, civil engineering isn’t dead yet. Read the court decision
Read the full story...
Reprinted courtesy of Frank K. Johnson, ENR
ENR may be contacted at ENR.com@bnpmedia.com

---