Fairfield Connecticut Building Expert Directory

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

Delaware “occurrence” and exclusions j(5) and j(6)

June 10, 2011 — CDCoverage.com

In Goodville Mut. Cas. Co. v. Baldo, No. 09-338 (D. Del. June 2, 2011), claimants condominium association and unit owners sued project developer Rehoboth and general contractor Capano seeking damages because of moisture penetration property damage to common elements and individual units resulting from construction defects. Rehoboth and Capano filed a third party complaint against insured property manager Baldo alleging that, if Rehoboth and Capano were liable to claimants, Baldo was also liable because of Baldo’s failure to properly manage, maintain, and repair the property

Read the full story…

Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

Update Relating to SB891 and Bond Claim Waivers

June 10, 2015 — Christopher G. Hill – Construction Law Musings
Several bills were passed and will go into effect on July 1, 2015 that affect the construction industry here in Virginia. The most interesting of these was an amendment to the mechanic’s lien statutes relating to waivers of lien rights. As I posted in March, SB891 amended the mechanic’s lien statute, Va. Code Section 43-3, to remove proactive waivers of lien and bond rights. This bill has been signed into law with a minor modification. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Watch Your Step – Playing Golf on an Outdoor Course Necessarily Encompasses Risk of Encountering Irregularities in the Ground Surface

May 08, 2023 — Kaitlyn A. Jensen & Lawrence S. Zucker II - Haight Brown & Bonesteel LLP
On April 27, 2023, the First District Court of Appeal issued an opinion in Walter Wellsfry, et al. v. Ocean Colony Partners, LLC (A165175, April 27, 2023) affirming summary judgment for a golf course owner on the grounds that the injured golfer’s lawsuit was barred by the primary assumption of risk doctrine. In doing so, the Court of Appeal found that outdoor golfers assume the risks associated with the topographical features of the course, including the risk of stepping on an inconspicuous tree root. Recreational golfer Walter Wellsfry was walking from a tee box back to his golf cart when he allegedly stepped on a small tree root concealed by grass, causing him to fall into his golf cart in immediate pain. The ground consisted of mixed terrain, including a combination of grass, dirt, and sand. The tree root was estimated to be approximately 1.5 inches high by 1.5 inches wide. Believing he may have only sprained an ankle, Wellsfry continued the course and reported the incident to management. He later sued the golf course owner Ocean Colony Partners for negligence, claiming that the tree root was a “hidden obstruction” creating an unreasonable risk of harm to anyone who traversed the area. Reprinted courtesy of Kaitlyn A. Jensen, Haight Brown & Bonesteel LLP and Lawrence S. Zucker II, Haight Brown & Bonesteel LLP Mr. Jensen may be contacted at kjensen@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Florida Condo Collapse Victims Reach $1 Billion Settlement

May 23, 2022 — Erik Larson - Bloomberg
Victims of the South Florida condominium collapse that killed 98 people last year reached settlements totaling almost $1 billion with defendants including the developer of an adjacent luxury tower, engineers and a law firm for the condo association. The massive deal was cobbled together through multiple agreements before a state court hearing Wednesday in Miami, according to Harley S. Tropin, one of the lead plaintiffs’ lawyers who had sued on behalf of survivors and victims’ families. He said he disclosed the settlements in court. “We are pleased to have resolved this case with the defendants to get what we think is a very fair recovery to help end the litigation and allow the victims to attain some means of attempting to move forward from this horrific tragedy,” Tropin said in an emailed statement. The 12-story Champlain Towers South condominium building in Surfside, Florida, collapsed June 24, triggering multiple lawsuits and prompting state and federal probes. A focus was the development of the Renzo Piano-designed Eighty Seven Park high-rise next door to the Champlain Towers. Read the court decision
Read the full story...
Reprinted courtesy of Erik Larson, Bloomberg

Billion-Dollar Power Lines Finally Inching Ahead to Help US Grids

April 03, 2023 — Brian Eckhouse, Naureen S Malik & Dave Merrill - Bloomberg
The biggest impediment to the US achieving a cleaner power grid isn't climate deniers or fossil-fuel lobbies; it’s a lack of transmission lines. The country badly needs more conduits to cart wind and solar energy and hydropower to cities. For more than a decade, multibillion-dollar power-line projects have struggled to advance, slowed or halted by bureaucracy, NIMBYism or general industry stasis. Now suddenly, several are progressing — and with them the prospect of newly unleashed clean energy as well as more resilient grids in the face of ever-dangerous storms and extreme heatwaves. There’s SunZia in the Southwest, TransWest Express in the Mountain West, Grain Belt Express to the Midwest, and Champlain Hudson Power Express into New York City — projects that together will cost at least $13 billion. Some are now ordering expensive equipment, a signal of their advancement. SunZia and TransWest expect to begin construction this year. Reprinted courtesy of Brian Eckhouse, Bloomberg, Naureen S Malik, Bloomberg and Dave Merrill, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

It’s Too Late, Lloyd’s: New York Federal Court Finds Insurer Waived Late Notice Defense

June 05, 2023 — Latosha M. Ellis & Janine A. Hanrahan - Hunton Insurance Recovery Blog
A New York federal judge recently ruled that an insurer waived its late notice defense because a generic reservation of rights was insufficient to preserve it. As a result, the policyholder’s claim was preserved despite being submitted more than three months after the loss—a delay which would ordinarily be fatal under New York law. The decision underscores the importance both of timely submission of claims and careful attention to reservation of rights letters. Background Mave Hotel Investors LLC (“Mave”) owns a small hotel in Manhattan that was insured by Certain Underwriters at Lloyd’s, London (“Lloyd’s”). From October 2017 to October 2020, Mave contracted with a housing network to temporarily house homeless families and their children in the hotel. When the contract with the housing network terminated in October 2020, Mave alleged that the rooms were severely damaged and that it had to pay $1.4 million to repair them. Reprinted courtesy of Latosha M. Ellis, Hunton Andrews Kurth and Janine A. Hanrahan, Hunton Andrews Kurth Ms. Ellis may be contacted at lellis@HuntonAK.com Ms. Hanrahan may be contacted at jhanrahan@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Florida Court of Appeals Rejects Insurer’s Attempt to Intervene in Underlying Lawsuit to Submit Special Interrogatories

October 09, 2018 — Jeremy Macklin - TLSS Insurance Law Blog
On August 10, 2018, the Florida Court of Appeals for the Second District upheld a trial court’s dismissal of an insurance company’s intervention in a tort lawsuit brought against its insured for the purposes of submitting special interrogatories and verdict forms. In Houston Specialty Ins. Co. v. Vaughn, 2018 Fla. App. LEXIS 11197, 2018 WL 3795785 (Fla. 2d DCA Aug. 10, 2018), the insured, All Florida Weatherproofing and Construction, Inc. (“All Florida”) provided pressure washing, roof coating, and other roof-related services. Houston Specialty issued a general liability policy to All Florida. In 2012, a worker fell off a roof while applying protective coating on behalf of All Florida. The worker and his family sued All Florida in connection with the worker’s injuries. Read the court decision
Read the full story...
Reprinted courtesy of Jeremy Macklin, Traub Lieberman Straus & Shrewsberry LLP
Mr. Macklin may be contacted at jmacklin@tlsslaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES