Seattle Washington Building Expert Directory

Thanks to All for the 2024 Super Lawyers Nod!

May 13, 2024 — Christopher G. Hill - Construction Law Musings
It is with humility and a sense of accomplishment that I announce that I have been selected for the seventh straight year to the Virginia Super Lawyers in the Construction Litigation category for 2024. Add this to my recent election to the Virginia Legal Elite in Construction and I’ve had a pretty good year. As always, I am thrilled to be included on these peer-elected lists. So without further ado, thank you to my peers and those on the panel at Virginia Super Lawyers for the great honor. I feel quite proud to be part of the 5% of Virginia attorneys that made this list for 2024. The full list of Virginia Super Lawyers will appear in the May edition of Richmond Magazine. Please check it out. If you want to see the lists before then, a digital version of the Virginia Super Lawyers Magazine is available here (click on the Virginia magazine). Thanks again to all of you who participated in my nomination and election. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

No Coverage for Collapse of Building

January 04, 2021 — Tred R. Eyerly - Insurance Law Hawaii
Damage to a building caused by the break of a water pipe was not a collapse under the policy. Naabani Twin Stars v. Travelers Cos., 2020 U.S. Dist. LEXIS 196443 (D. N. M. Oct. 22, 2020). An underground water line ruptured on plaintiffs property This caused a collapse under the adjacent parking lot, which in turn caused land beneath the building go change positions and damage the building. A geotechnical consultant concluded that a material change in the site conditions occurred as a direct result of the rupture of the water pipe in the parking lot, and that those changes directly affected the settlement of the building. Travelers denied coverage for the damage. Travelers concluded that the building settlement was the result of subsurface movement, which invoked the earth movement exclusion. Travelers inspection concluded that the building was not in a state of collapse. The policy defined collapse as "an abrupt falling down or caving in of a building or structure, or any part of a building or structure, with the result that the building, or part of the building, cannot be occupied for its intended purpose." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Excessive Corrosion Cause of Ohio State Fair Ride Accident

August 10, 2017 — David Suggs – Bert L. Howe & Associates, Inc.
The manufacturer of the Fire Ball ride at the Ohio State Fair claims that excessive corrosion “led to the accident that killed a teenager and injured seven others…in July.” According to a statement by KMG International, reported by ABC News, “Corrosion on the interior of the support beam reduced the beam's thickness, which led to the accident at the fair.” Furthermore, “The company said it conducted an investigation into the incident, which included a visit to the scene and a review of video footage of the incident. The company also conducted a metallurgical inspection of the ride.” A U.S. Consumer Product Safety Commission (CPSC) spokesperson said “it is aware of 22 deaths associated with amusement attractions since 2010, including Wednesday's incident, but excluding water park and work-related fatalities.” Read the court decision
Read the full story...
Reprinted courtesy of

Want to Stay Up on Your Mechanic’s Lien Deadlines? Write a Letter or Two

March 22, 2017 — Christopher G. Hill – Construction Law Musings
90 days. 150 days. 6 months. 30 days. Do these numbers sound familiar? If you read Construction Law Musings regularly, they should be. These are various deadlines relating to the recording and enforcement of mechanic’s liens in Virginia. 90 days from your last work performed (or from the last date of the last month of work in the correct circumstances) sets the outside limit on when a construction company can record a lien on a construction project. 150 days is the “look back” period for what work’s value can be included in that lien. 6 months is the statute of limitations for the filing of an enforcement suit. Finally, 30 days amount of time after your start of work within which you, as a construction professional, must notify a mechanic’s lien agent of your presence on a residential project. Of course, there are always nuances to these rules that need to be taken into account, preferably with the help of your friendly neighborhood construction attorney, before deciding how to proceed in this very picky and “form over function” area of construction law. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Does the Implied Warranty of Habitability Extend to Subsequent Purchasers? Depends on the State

October 08, 2014 — Beverley BevenFlorez-CDJ STAFF
Attorneys for Traub Liberman Straus & Shrewsberry LLP (in JD Supra Business Advisor), discussed how state courts have come to different conclusions as to “whether a subsequent purchaser of a previously inhabited residence can recover contract damages from a builder or general contractor for breach of the implied warranty of habitability.” Recently, a Pennsylvania “sided with the builder, holding that the implied warranty of habitability was grounded in contract law. Thus, the Court reasoned that an action for breach of the implied warranty of habitability required a showing of contractual privity between the parties. Because there was no contractual privity between the Conways and the builder, the Conways could not pursue an action against the builder based on a breach of the implied warranty of habitability.” However, other state courts have made other conclusions. “Iowa permits an action for breach of the implied warranty of workmanlike construction by subsequent purchasers and does not require a showing of contractual privity. Rhode Island also does not require contractual privity, but limits liability to latent defects discovered within 10 years of construction.” Vermont and Connecticut, however, require contract privity. Read the court decision
Read the full story...
Reprinted courtesy of

Avoiding Disaster Due to Improper Licensing

February 18, 2019 — Candace Matson - Construction & Infrastructure Law Blog
IT’S NOT ENOUGH FOR A CONTRACTOR TO BE LICENSED . . . it must be properly licensed. We are reminded of this by the recent case of JMS Air Conditioning and Appliance Service, Inc. v. Santa Monica Community College District, Bernards Bros., Inc., 30 Cal. App. 5th 945 (2018). In that case, JMS entered into an $8.2M subcontract with Bernards to install an HVAC system in a new facility being built for the District. JMS held a C-20 warm-air heating, ventilating and air-conditioning license. A year into the project, Bernards sought permission from the District to substitute another subcontractor for JMS (as required under Public Contract Code Section 4107 for listed subcontractors on public works of improvement). Among other things, Bernards contended that JMS was not properly licensed to perform that portion of the work which consisted of hydronic plumbing and hydronic boiler work. JMS countered that this work was an integral part of installing an HVAC system, and relied on Business & Profession Code Section 7059, which permits work that is “incidental and supplemental to the performance of the work for which the specialty contractor is licensed,” and a California State Licensing Board regulation which defines “incidental and supplemental” as meaning “essential to accomplish the work in which the contractor is classified.” (Cal. Code Regs., tit. 16, §831.) Read the court decision
Read the full story...
Reprinted courtesy of Candace Matson, Sheppard Mullin
Ms. Matson may be contacted at cmatson@sheppardmullin.com

Title II under ADA Applicable to Public Rights-of-Way, Parks and Other Recreation Areas

June 29, 2017 — Richard E. Morton - Haight Brown & Bonesteel LLP
Plaintiff Ivana Kirola, who suffers from cerebral palsy, sued the City and County of San Francisco, in a class action contending certain public areas, including rights-of-way, pools, parks and other recreation areas, did not meet the mandate of Title II of the American With Disabilities Act (Kirola v. City and County of San Francisco, 9th Circuit Court of Appeals, No. 14-17521, 2017 DJDAR 5982). Title II provides that no qualified individual with a disability “shall, by reason of such disability, be excluded from participation in or be denied the benefits of the services, programs, or activities of a public entity, or be subjected to discrimination by any such entity.” Title II’s implementing regulations mandate that each facility constructed after January 26, 1992 be “readily accessible to and usable by individuals with disabilities.” And, for each facility “altered after January 26, 1992,” the altered portion must, “to the maximum extent feasible,” be likewise accessible. The Federal Architectural and Transportation Barriers Compliance Board creates nonbinding Americans With Disabilities Act Accessibility Guidelines (ADAAG) to ensure compliance with Title II, and that the Department of Justice (DOJ) adopt its own binding regulations, consistent with the ADAAG standards. Here, the District Court interpreted ADAAG standards as not applying to public rights-of-way, parks, and playground facilities. The District Court concluded that none of Kirola’s experts were reliable in their interpretation of the standards and how the standards applied to the public rights-of-way, etc. Conversely, the District Court concluded that all of the city’s experts were reliable. It thus disregarded and discarded every ADAAG violation identified by Kirola’s experts, accepting only the small number of violations identified by the city’s experts. Read the court decision
Read the full story...
Reprinted courtesy of Richard E. Morton, Haight Brown & Bonesteel LLP
Mr. Morton may be contacted at rmorton@hbblaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES