Fairfield Connecticut Building Expert Directory

Subcontract Should Flow Down Delay Caused by Subcontractors

December 21, 2020 — David Adelstein - Florida Construction Legal Updates
A general contractor’s subcontract with its subcontractor should include a provision that entitles it to flow down liquidated damages assessed by the owner stemming from delays caused by the subcontractor. Such a provision does not mean the general contractor does not have to prove delays caused by the subcontractor or can arbitrarily allocate the amount or days it claims the subcontractor is liable. The general contractor still will need to reasonably establish the delays the subcontractor caused the critical path of the schedule, i.e., delayed the job. In addition to the right to flow down liquidated damages, the subcontract should also entitle the general contractor to recover its actual extended general conditions caused by the subcontractor’s delays (regardless of whether the owner assesses liquidated damages). The objective is that if the subcontractor delays the job, the subcontractor is liable for liquidated damages the general contractor is liable to the owner for in addition to the general contractor’s own delay damages. This is an important subcontractual provision so that the risk of delay caused by subcontractors is clearly flowed down to them in the subcontract. In a 1987 case, Hall Construction Co., Inc. v. Beynon, 507 So.2d 1225 (Fla. 5th DCA 1987), the subcontract at-issue contained language that stated, “The parties hereto agree that a supplier who delays performance beyond the time agreed upon in this Purchase Order shall have caused [general contractor] liquidated damages in the amount required of [general contractor] by their contract per day for each day such delay continues which sum the supplier hereby agrees to pay.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Taking the Stairs to Human Wellness and Greener Buildings

June 22, 2016 — Rob Finch – Construction Informer Blog
If taking the stairs catches on, buildings with elevators could automatically get greener. The people working in them also stand a good chance of getting healthier. However, designers and builders working for owners who want to reap these advantages, will need to learn a few new tricks when it comes to how stairs get placed and promoted. They also get a chance to unleash creativity in how they are finished. Read the court decision
Read the full story...
Reprinted courtesy of Rob Finch, Construction Informer Blog

Impasse Over Corruption Charges Costs SNC $3.7 Billion, CEO Says

January 08, 2019 — Frederic Tomesco - Bloomberg
Canada’s failure to reach a negotiated settlement with SNC-Lavalin Group Inc. over past corruption charges has probably cost the company more than C$5 billion ($3.7 billion) in lost revenue and continues to damage its reputation internationally, Chief Executive Officer Neil Bruce said. Read the court decision
Read the full story...
Reprinted courtesy of Frederic Tomesco, Bloomberg

Construction Jobs Expected to Rise in Post-Hurricane Rebuilding

November 07, 2012 — CDJ STAFF
Businessweek reports that construction jobs and materials will see increased demand as property owners in New York and New Jersey rebuild after hurricane Sandy. Tom Jeffery, of Irvine, California-based CoreLogic, a real estate information service, noted that “a high percent of damaged properties are going to be repaired.” Experts estimate property damage to total anywhere from $7 billion to $40 billion. It is also estimated that about 739,000 properties in the area are underwater in the way that has nothing to do with flooding, with negative equity of 25 percent or more. Many of these homeowners are likely to walk away from their mortgages. Ken Simonson, chief economist of the Associated General Contractors of America, expects “localized spikes in construction employment throughout November and the winter.” Martin Connor, the chief financial officer of Toll Brothers, expects to see more a rise in labor costs than in materials. Read the court decision
Read the full story...
Reprinted courtesy of

West Coast Casualty Promises Exciting Line Up at the Nineteenth Annual Conference

March 28, 2012 — CDJ STAFF

West Coast Casualty has announced the lineup for the annual WCC Construction Defect Seminar. This year’s seminar will be the nineteenth anniversary, and it will be held on May 17th and 18th, 2012 in Anaheim, California. They are the largest construction defect event in the world and this year’s seminar will again bring the top people in the field to address many of the current issues and where the construction defect community will be going in the future.

The event, anticipated to be even larger than prior years, will have numerous panels and presentations on the current state of construction defect litigation. Among the topics that will be presented are “Arbitrate? Let’s See You Make Me!” “Defending Construction Defect Failure Mechanisms?An Expert’s Perspective,” and “Current Trends in Effectively Handling SB800 Cases.”

Speakers at the event will include judges, lawyers, and representatives of the insurance industry. One event, “Meet Your Judges, A Candid Discussion on Construction Defect Claims and Litigation from the Bench?” will include judges from five states, including the Honorable Nancy M. Saitta, Chief Justice of the Nevada Supreme Court, the Honorable Clifton Newman of the South Carolina Circuit Court, and the Honorable Rex Heeseman of the Los Angeles County Superior Court.

Daniel A. Berman, Esq. and Stephen Henning, Esq. will be talking on the topic of “Social Networking Sites: Strategies, Ethical Pitfalls, and Practice Pointers for Litigating and Winning Your Construction Defect Case.” Mr. Berman is a Founding and Managing Partner of Wood, Smith, Henning & Berman LLP. He has been named a Southern California Super Lawyer for eight consecutive years. Mr. Henning is a Founding Partner of Wood, Smith, Henning & Berman, LLP and Fellow of the Litigation Counsel of America. Mr. Henning will also be one of the presenters on the panel “Important Court Decisions Impacting Construction Defect Claims.”

The panel “Why Do We Need to Know Certain Things and How Decisions Are Made” will be presented by important figures in the construction claims industry, including Phyllis Modlin, Todd Schweitzer, Teresa D. Wolcott, and Lee Wright. Ms. Modlin is a Construction Defect Claims Supervisor responsible for nationwide claims for Markel Corporation. Mr. Schweitzer is an Assistant Vice President of Major Case for Construction Defect and Professional Liability Claims Services at Zurich North America. Ms. Wolcott is the National Product Manager for Construction Defect Claims within the Construction Claims Organization at Travelers Insurance. Mr. Wright is an Assistant Vice President and Senior Claims Consultant for XL Specialty Insurance.

The event will also include a Science and Technology Fair in which exhibitors will be presenting technological problem solving and decision making as they relate to resolving ongoing construction and post construction-defect related issues while reducing costs for all those involved in claims and litigation. The fair is dedicated to these novel applications of science and technology that benefit the construction defect community but are not yet commonly available. This will be the third time the Construction Defect Seminar will include a Science and Technology Fair.

Sessions at the event are approved for MCLE credit in Arizona, California, Colorado, Illinois, Maine, Minnesota, New York, Ohio, and Pennsylvania. MCLE credits vary by state; attendees can obtain up to 10.25 hours of credit in Arizona, California, Maine, and New York. Applications for several other states are still pending. Additionally, the event is also worth continuing education credits with the Florida Department of Insurance and for Registered Professional Adjusters. West Coast Casualty has applications pending for adjuster continuing education in an additional thirty-six states.

West Coast Casualty recommends this event for anyone involved in construction or construction defect claims, whether they are a claims adjuster, a member of a homeowner board, a judge, a property manager, a construction claims attorney, a general contractor, or anyone else with an interest in this area. The event typically has more than 1,600 attendees. Those interested can register online.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

The Sensible Resurgence of the Multigenerational Home

August 13, 2014 — Chris Farrell – Bloomberg
One of the biggest fears spawned by the recession and subsequent up-and-down recovery is getting stuck at home. The commonly expressed concern is that millennials are too burdened with student debts and poor job prospects to make it on their own. According to the narrative of generational dependency, the resurgence in multigenerational living is a trend hardly worth celebrating. Or is it? Yes, many young college graduates have faced tough economic circumstances in recent years. But the trend toward embracing the multigenerational home began well before the Great Recession, suggesting something else is at work. A record 57 million Americans, or 18.1 percent of the population, lived in a multigenerational household in 2012, according to a Pew Research report, “In Post-Recession Era, Young Adults Drive Continuing Rise in Multi-Generational Living,” released on June 17, 2014. (You can include the First Family among the multigenerational households.) That’s up from 28 million, or 12.1 percent of the population, in 1980. Equally impressive, the return of the multigenerational household marks a striking reversal of the post-World War II decline. In 1940, 24.7 percent of the population resided in a multigenerational home, a living arrangement that bottomed in the early 1980s. Read the court decision
Read the full story...
Reprinted courtesy of Chris Farrell, Bloomberg

Congratulations to BWB&O’s 2024 Southern California Super Lawyers!

February 05, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
BWB&O is excited to announce that Partners Nicole Whyte, Keith Bremer, John Toohey, and Tyler Offenhauser have been selected in the 2024 Southern California Super Lawyers list as Super Lawyers for their work in Business Litigation, Family Litigation, Personal Injury Litigation, and Construction Litigation. To read Super Lawyers’ digital publication, please click here. Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The objective of Super Lawyers’ patented multiphase selection process is to create a credible, comprehensive, and diverse listing of outstanding attorneys that can be used as a resource for attorneys and consumers searching for legal counsel. Please join us in congratulating Nicole, Keith, John, and Tyler on achieving this level of recognition! Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Texas EIFS Case May Have Future Implications for Construction Defects

October 02, 2013 — CDJ STAFF
Lennar Homes addressed a problem with EIFS in homes built in Texas in the 1990s by replacing every roof they had built. Some of those homes had problems with leaks, rotting, or termites, but other roofs hadn’t suffered any problems. Lennar’s insurers initially refused coverage. Lennar managed to settle with all but one, Markel American Insurance. Their dispute formed the case Lennar Corp. v. Markel American Insurance Co. This was first tried before a jury and eventually appealed to the Texas Supreme Court. Brian S. Martin of Thompson Coe Cousins & Irons LLP discusses this case at Insurance Journal. Markel’s claim was that under the policy language, Lennar could not make voluntary payments without getting Markel’s consent, which they did not. But the Texas Supreme Court disagreed, determining that Lennar took, as Mr. Martin notes, “a reasonable approach to a serious problem.” Markel also made the claim that the whole amount of the damages was not covered by the policy, as they did not view the policy as covering the cost of determining the extent of the damage. The Court disagreed, noting that “under no reasonable construction of the phrase can the cost of finding EIFS property damage in order to repair it not to be considered ‘because of the damage.’” Mr. Martin concludes by calling the Texas Supreme Court decision “a frontal assault on several critical provisions of liability policies that will assuredly lead to further litigation.” He also notes that the decision “may indicate a shift in the Court’s approach in insurance cases to a more result-oriented jurisprudence.” Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES