SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Am I Still Covered Under the Title Insurance Policy?

May 01, 2019 — Ian Douglas - Snell & Wilmer Real Estate Litigation Blog
When transferring property for corporate restructuring or estate planning purposes, an important issue to consider is whether the successor owner will be covered by the grantee’s title insurance policy. Because title insurance policies insure only the title of the “Insured” identified in the policy, the successor in interest of the named insured may not be covered following the transfer. In older ALTA title insurance policies, the definition of “Insured” included the person or entity specifically identified in the policy as the insured, as well as any subsequent owners who took title to the subject property by operation of law. Because those policies did not clarify what the term “by operation of law” meant, it was unclear whether certain subsequent owners, such as a parent or subsidiary of the original insured, fell within the definition of “Insured”. In order to avoid any risk that a subsequent owner following a transfer between related parties was not covered by the grantor’s title policy, parties often obtained an “additional insured” endorsement which provided the subsequent owner coverage under the original policy. Read the court decision
Read the full story...
Reprinted courtesy of Ian Douglas, Snell & Wilmer
Mr. Douglas may be contacted at idouglas@swlaw.com

---

Structural Health Check-Ups Needed but Are Too Infrequent

August 16, 2021 — Jeff Rubenstone - Engineering News-Record
Knowing when a building is structurally deteriorating, and actually doing something about it can be very different things, as the collapse in Surfside, Fla., has shown this month. And while onsite visual inspections are still the common kind of structural assessment, other methods can assess the health of a building or piece of infrastructure and determine its soundness (see p. 69). Reprinted courtesy of Jeff Rubenstone, Engineering News-Record Mr. Rubenstone may be contacted at rubenstonej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

The Importance of Preliminary Notices on Private Works Projects

September 03, 2019 — William L. Porter - Porter Law Group
Time and time again I receive calls from subcontractors and suppliers who find themselves faced with a customer who is either unwilling or unable to pay for labor or materials supplied for a private works project. As an attorney, the first question I usually ask is “did you serve a Preliminary Notice?” The second question I usually ask is “did you serve the Notice within twenty (20) days after first furnishing labor, service, equipment or materials to the job site?” The answers to these questions will often determine the ability to collect on the claim. The excuses for failing to serve the Preliminary Notice range from “for the last ten years the customer has always paid on time” to “I didn’t want to imply the contractor was not going to pay me” to “it is too much trouble to do on every job” or, simply, “I forgot”. Contractors and suppliers are well advised that any subcontractor or supplier who fails to properly and timely serve a Preliminary Notice is depriving itself of the most powerful tool available for compelling payment of construction related debt on a private works project. For all but the smallest contracts failure to serve the Preliminary Notice is also a violation of contractors’ license law and constitutes grounds for discipline by the Contractor State License Board, up to and including suspension of the contractor’s license. Most of these rules are found in California Civil Code Section 8200-8216. The requirements of these sections are far too numerous to itemize here. Suffice it to say every contractor, subcontractor and construction material supplier to private construction projects should be familiar with these sections of the California Civil Code. They set forth most of the rules which relate to Preliminary Notices on private construction projects. Some of the most important features are as follows: Read the court decision
Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

---

Oracle Sues Procore, Claims Theft of Trade Secrets for ERP Integration

November 25, 2024 — Jeff Yoders - Engineering News-Record
Oracle, Inc., has sued Procore in federal court in Northern California, accusing the construction management platform provider of stealing confidential information related to developing enterprise resource planning products for contractors. Read the court decision
Read the full story...
Reprinted courtesy of Jeff Yoders, ENR
Mr. Yoders may be contacted at yodersj@enr.com

---

Comparing Contracts: A Review of the AIA 201 and ConsensusDocs - Part I

March 22, 2018 — Michael Sams and Amanda Cox – Construction Executive, A publication of Associated Builders and Contractors. All Rights Reserved.
Here’s a helpful comparison of and analysis of some important contract sections in the AIA 201 (2007 and 2017 versions) and ConsensusDocs (2014 and 2017 versions). While not intended to be all inclusive, this summary comparison of the contract documents will run as a three-part series. Part I covers Financial Assurances, Design Risk, Project Management and Contract Administration. Part II will cover Schedule/Time, Consequential Damages/LDs, Claims and Disputes/ADR. Part III will cover Insurance and Indemnification and Payment. FINANCIAL ASSURANCES

• What assurances are there that the owner can pay for the project?

• The Contractor should have the right to request and obtain proof that the Owner has funding sufficient to pay for the Work. The provision should also provide that the Contractor may terminate the Contract if the Owner refuses to allow a review of funding documents, or should the Contractor reasonably determine that the Owner does not have sufficient funds to pay for the Work.

Relevant Sections:

• A201 2007 Section 2.2.1; 2017 Section 2.2.1-2.2.2 A201

• 2014 & 2017 ConsensusDocs 200: Section 4.2

AIA:

• Section 2.2.1 A201 2007 & 2017: Both editions require the Owner, upon Contractor’s written request, to provide, “reasonable evidence that the Owner has made financial arrangements to fulfill the Owner’s obligations under the Contract.” Thereafter, the Contractor may only request such evidence if (1) the Owner fails to make payments; (2) a change in the Work materially changes the Contract Sum; or (3) the Contractor identifies in writing a reasonable concern regarding the Owner’s ability to make payment when due. If the Owner does not comply, the Contractor may stop work.

• Additionally, A201 2017 Section 2.2.2 awards costs to the Contractor for demobilization and remobilization.

Reprinted courtesy of Michael Sams , Kenney & Sams and Amanda Cox, Kenney & Sams Mr. Sams may be contacted at mpsams@KandSlegal.com Ms. Cox may be contacted at ajcox@KandSlegal.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Are Untimely Repairs an “Occurrence” Triggering CGL Coverage?

January 17, 2023 — Christopher G. Hill - Construction Law Musings
All Class A commercial contractors in Virginia are required to have a minimum level of Commercial General Liability (CGL) coverage. As a general rule, this insurance is there for damage to property or persons arising from an “occurrence” that is covered by the policy. Many cases that are litigated relating to coverage for certain events under a CGL policy turn on the definition of “occurrence” and whether the event leading to a request for coverage constitutes an “occurrence.” A recent case in Fairfax County, Virginia, Erie Insurance Exchange v. Spalding Enterprises, et al., is just such a case. In the Spalding Enterprises case, the Court considered the following scenario. A homeowner, Mr. Yen contracted with Spalding Enterprises to fix some fire damage at his home. Spalding promised the repairs would be complete in October of 2019. However, after Mr. Yen paid a $300,000.00 deposit, Spalding Enterprises stated that the work would not be completed until November of 2019. Yen then fired Spalding Enterprises and sued for breach of contract, constructive fraud, and violation of the Virginia Consumer Protection Act. Spalding Enterprises sought coverage from Erie Insurance for the claim and Erie denied coverage and sought a declaratory judgment that the events alleged in the Complaint by Mr. Yen did not fall under the definition of “occurrence” in the CGL policy held by Spalding Enterprises. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

US Attorney Alleges ADA Violations in Chicago Cubs Stadium Renovation

August 07, 2022 — Annemarie Mannion - Engineering News-Record
The friendly confines of Wrigley Field are not so friendly to wheelchair users, according to federal prosecutors who filed a civil lawsuit July 14 alleging that the Chicago Cubs’ multi-year renovation of the baseball stadium eliminated prime wheelchair seating and did not include other accessible features required under the Americans with Disabilities Act. Reprinted courtesy of Annemarie Mannion, Engineering News-Record Ms. Mannion may be contacted at manniona@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---