Fairfield Connecticut Building Expert Directory

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

Fewer NYC Construction Deaths as Safety Law Awaits Governor's Signature

July 25, 2022 — Richard Korman - Engineering News-Record
The hoped-for progress in New York City construction safety is coming too late for laborer Jose Fortina Armenta Hernandez. At 8:37 a.m. on May 27, 2021, while jackhammering a roof section on a Brooklyn building, the section on which Armenta stood gave way and he fell 60 ft. When last year his family sent his body from New York City to Mexico to be buried, they used a GoFundMe page to raise money for the laborer's funeral. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Bribe Charges Take Toll on NY Contractor

February 22, 2018 — Mary B. Powers - ENR
The federal bid-rigging trial of former executives of one-time Buffalo, N.Y., regional contracting giant LPCiminelli won’t start until late spring, more than 18 months after they were indicted, along with others, on bribery, corruption and fraud charges in a New York state contract “pay for play.” Read the court decision
Read the full story...
Reprinted courtesy of Mary B. Powers, Engineering News-Record

Is the Event You Are Claiming as Unforeseeable Delay Really Unforeseeable?

September 26, 2022 — David Adelstein - Florida Construction Legal Updates
Is the item or event you are claiming as an unforeseeable, excusable delay really unforeseeable? This is not a trick question. Just because your construction contract identifies items or events that constitute unforeseeable, excusable delay does not mean those items can be used as a blanket excuse or crutch for the contractor. That would be unfair. For instance, it is not uncommon for a construction contract to list as unforeseeable, excusable delay the following events or items: “(i) acts of God or of the public enemy, (ii) act of the Government in either its sovereign or contractual capacity, (iii) acts of another Contractor in the performance of a contract with the Government, (iv) fires, (v) floods, (vi) epidemics, (vii) quarantine restrictions, (viii) strikes, (ix) freight embargoes, (x) unusually severe weather, or (xi) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers.” See, e.g., F.A.R. 52.249-10(b)(1). While the itemization of excusable delay may be worded differently, the point is there may be a listing as to what items or events constitute excusable delay. An excusable delay would justify additional time and, potentially, compensation to the contractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

With VA Mechanic’s Liens Sometimes “Substantial Compliance” is Enough (but don’t count on it) [UPDATE]

October 14, 2019 — Christopher G. Hill - Construction Law Musings
Virginia mechanic’s liens are a powerful and tricky beast that in most cases require absolute precision in their preparation. However, an interesting opinion recently came out of the Virginia Supreme Court that may provide a bit of a “safe harbor” from the total form over function nature of a mechanic’s lien. In Desai, Executrix v. A.R. Design Group Inc., the Court considered a lien memorandum that had what could be described as technical flaws in the preparation of the mechanic’s lien by A. R. Design Group. The basic facts are that A. R. Design Group used the form of lien found in Va. Code Sec. 43-5 (also found as Form CC-1512 at the Virginia Judiciary website) when it recorded two lien memoranda for two pieces of property owned by a trust. Relating to one of the two properties, the memorandum failed to identify the “Owner” as the trustee of the trust. On the memoranda relating to both properties the affidavit verifying the amounts claimed did not identify the signatory as agent for A. R. Design Group, instead listing the agent as the claimant and further failed to state a date from which interest is claimed or a date on which the debt was due. Needless to say, the owner argued that each of these technical defects invalidated the memoranda and therefore they should have been released. Somewhat surprisingly the Fairfax, Virginia Circuit Court disagreed and held the liens to be valid. On appeal, the Virginia Supreme Court affirmed the lower court. The held that the failure to add the word “Trustee” after Ulka Desai’s name did not invalidate the lien because the trustee had all of the rights of ownership and furthermore that naming Desai in the memorandum served the purpose of putting third parties on notice of the lien. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Rhode Island District Court Dismisses Plaintiff’s Case for Spoliation Due to Potential Unfair Prejudice to Defendant

September 04, 2018 — Lian Skaf - The Subrogation Strategist
In Amica Mutual Ins. Co. v. BrassCraft Mfg., Co., 2018 U.S. Dist. LEXIS 88986 (D.R.I. May 29, 2018), the United States District Court for the District of Rhode Island addressed the question of whether the defendant was so unfairly prejudiced by the subrogating insurer’s spoliation of evidence that dismissal of the plaintiff’s case was the appropriate Rule 37(b)(2)(a)(i)-(vi) sanction. The court, focusing on the potential for undue prejudice to the defendant, granted the defendant’s motion to dismiss. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams, LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

Prompt Payment More Likely on Residential Construction Jobs Than Commercial or Public Jobs

May 02, 2022 — Levelset
NEW ORLEANS, May 02, 2022 (GLOBE NEWSWIRE) -- In construction, no line of work guarantees prompt and in-full payments, but contractors working on residential jobs say their rate of prompt payment is significantly better than commercial or public jobs, according to the 2022 Levelset Cash Flow and Payment Report. However, the report revealed that residential construction jobs require increased communication to improve the chance of prompt payment when compared to commercial or public jobs. Contractors working on residential projects are more than twice as likely as those working on public projects to report getting paid within 30 days, with residential construction contractors saying they are paid in 30 days or less 48% of the time and public construction contractors saying that only happens 21% of the time. Significantly slow payments of 60 days or more are three times more likely on public construction projects than on residential construction projects, according to the survey participants. Residential contractors say it happens rarely, just 6% of the time, while public project contractors say it happens nearly one out of five times (18%). For more information about the report and a detailed summary of findings, please visit: www.levelset.com/survey About Levelset Levelset's mission is to empower contractors to always get what they earn. Levelset's products help millions in the construction industry each year to make payment paperwork and compliance easier, get cash faster, monitor the risk on jobs and contractors, and better understand payment processes and rules. The results are faster payments, access to capital, and fewer surprises. Founded in 2012, Levelset is based in New Orleans, Louisiana, with offices in Austin, Texas, and Cairo, Egypt, and is owned and operated by Procore Technologies, Inc. For more information, visit www.levelset.com. Read the court decision
Read the full story...
Reprinted courtesy of

White and Williams Obtains Reversal on Appeal of $2.5 Million Verdict Against Electric Utility Company

September 03, 2014 — Edward Koch, Mark Paladino, Luke Repici, & Andrew Susko – White and Williams LLP
PPL Electric Utilities successfully argued on appeal that the $2.5 million plaintiff’s molded verdict awarded to an injured painting subcontractor should be vacated because the alleged evidence was legally insufficient and therefore the utility was not liable. In Nertavich v. PPL Electric Utilities, the plaintiff argued that although the utility was a landowner out of possession of the worksite, the utility was liable because it controlled the work of the subcontractor both by contract and by conduct. PPL argued on appeal before the Superior Court of Pennsylvania that the alleged evidence of the utility company’s control was insufficient as a matter of law to constitute control over the means and methods of the subcontractor’s work, and thus, PPL was not liable as a landowner out of possession. Reprinted courtesy of White and Williams LLP attorneys Edward Koch, Mark Paladino, Luke Repici and Andrew Susko Mr. Koch may be contacted at koche@whiteandwilliams.com; Mr. Paladino may be contacted at paladinom@whiteandwilliams.com; Mr. Repici may be contacted at repicil@whiteandwilliams.com; and Mr. Susko may be contacted at suskoa@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES