A Few Things You Might Consider Doing Instead of Binging on Netflix
April 13, 2020 —
Garret Murai - California Construction Law BlogGovernments throughout the world have issued “shelter in place” orders requiring that residents stay at home except for “essential” purposes. As a result, in the United States, more than a third of Americans have been ordered to stay at home. This, in turn, has had a direct impact on construction projects which have slowed or have been temporarily shuttered altogether, and it will (not may) have an impact on the flow of project funds. So what can project owners and contractors do? We’ve got a few tips.
1. Read Your Contract, Paying Particular Attention to Force Majeure, No Damages for Delay and Notice Provisions
For the most part, with the exception of statutory rights and remedies which we will discuss below, your contract spells out your rights and remedies should the proverbial “S” hit the fan. It is, in other words, the rules you agreed to, and you should know what those rules provide. Three provisions you should look for, and if they’re in your contract, you should review carefully are: (1) Force majeure provisions; (2) No damages for delay provisions; and (3) notice provisions.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Wisconsin Court of Appeals Re-affirms American Girl To Find Coverage for Damage Caused by Subcontractors
September 20, 2021 —
Tred R. Eyerly - Insurance Law HawaiiThe trial court's finding of no occurrence and no property damage due to faulty workmanship was reversed by the appellate court. No. 5 Walworth v. Engerman Contracting, Inc., 2021 Wis. App. LEXIS 401 (Wis. Ct. App, July 30, 2021).
Engerman was the general contractor on a construction project at a residence. Engerman was hired to build a poll complex. Engerman subcontracted the project to Downes Swimming Pool Co., Inc. Downes purchased shotcrete (sprayed concrete) from Otto Jacobs Company LLC for the swimming poll walls and base.
After completion, the pool immediately began leaking. An investigation determined that the shotcrete material was not installed correctly, contributing to cracking in the pool walls and the steel reinforcing bars were not sufficient to prevent cracks in the pool walls. The owner demolished the pool and constructed a new one. Thereafter, the owner sued Engerman, its insurers (General Casualty Company of Wisconsin and West Bend Mutual Insurance Company) and Downes and its insurer. Downes filed a third-party complaint against Jacobs and its insurer (Acuity Mutual Insurance Company) alleging Jacobs negligently provided inferior shotcrete to Downes.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Glendale City Council Approves Tohono O’odham Nation Casino
August 13, 2014 —
Beverley BevenFlorez-CDJ STAFFWith a 4-3 vote, the Glendale, Arizona city council “approved an agreement with the Tohono O’odham Nation to build a casino adjacent to the city,” according to the Arizona Public Media. The tribe, under the agreement, “will commit more than $25 million over the next 20 years to the city.”
The agreement also stipulates that Glendale “will try to convince state and federal officials to end their opposition to the casino plans.” City Councilman Gary Sherwood stated that he “he doesn't believe the tribe has firm plans for construction yet, but he said he wouldn't be surprised if there was gaming on the site by next fall.”
Read the court decisionRead the full story...Reprinted courtesy of
How Does Your Construction Contract Treat Float
November 08, 2017 —
David Adelstein - Florida Construction Legal UpdatesAlthough there are different types of construction schedule float and more technical definitions, the definition that makes sense to me is that float is the amount of time a particular activity can be delayed without that activity delaying the project’s completion date (substantial completion date). In looking at a construction schedule, this determination is made from looking at the difference between the early start date for an activity and the late start date for that activity or the difference between the early finish date for that activity and the late finish date for that activity in your CPM schedule (which should be the same amount of time). This is often referred to as “total float” and is the float that I usually focus on since it may pertain to a delay to the substantial completion date of the project and can trigger either the assessment of liquidated damages and/or the contractor’s extended general conditions, whatever the case may be.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
Dadelstein@gmail.com
Hunton Andrews Kurth’s Insurance Recovery Practice, Andrea DeField and Cary D. Steklof, Recognized as Legal Elite
August 16, 2021 —
Casey L. Coffey - Hunton Andrews KurthWe are proud to share that Hunton Andrews Kurth insurance coverage Partner
Andrea (Andi) DeField and Counsel
Cary D. Steklof were recently recognized as 2021 Legal Elite Up & Comers in Florida Trend magazine. Florida Trend invited all in-state members of the Florida Bar to name attorneys whom they highly regard or would recommend to others. Only the top 111 attorneys were recognized for their leadership in the legal field and in the community. Andi and Cary are both well deserving of this honor and the award reflects their dedication to providing excellent legal services.Andi finds risk management, risk transfer, and insurance recovery solutions for public and private companies. She represents policyholders in a variety of insurance coverage disputes including those arising out of data breaches, ransomware attacks, construction defect and wrongful death suits, hurricanes, mergers and acquisitions, regulatory investigations, class actions, shareholder derivative suits, and COVID-19.
Cary represents individual, corporate and municipal policyholders in all types of first- and third-party insurance coverage and bad faith disputes. With experience in the areas of insurance litigation, insurer bad faith and unfair insurance practices, he concentrates his practice on advising policyholders in connection with director and officer, error and omission, cyber, commercial general liability, and commercial property insurance policies.
Read the court decisionRead the full story...Reprinted courtesy of
Casey L. Coffey, Hunton Andrews KurthMs. Coffey may be contacted at
ccoffey@HuntonAK.com
Trump Administration Issues Proposed 'Waters of the U.S.' Rule
December 19, 2018 —
Pam Radtke Russell - Engineering News-RecordConstruction contractors said a proposed revised definition of “Waters of the United States,” released by the Environmental Protection Agency and the Army Corps of Engineers on Dec. 11, would provide their firms with clarity about what types of permits they will need for their construction projects near various bodies of water.
Read the court decisionRead the full story...Reprinted courtesy of
Pam Radtke Russell, ENRMs. Russell may be contacted at
Russellp@bnpmedia.com
“Families First Coronavirus Response Act”: Emergency Paid Leave for Construction Employers with Fewer Than 500 Employees
March 30, 2020 —
Sidney Lewis & Alex Glaser, Jones Walker LLP - ConsensusDocsCOVID-19 has already taken a toll on construction projects across the nation. Construction industry participants, including general contractors, now face risks and challenges that are exceedingly difficult to anticipate and plan for. The spread of this virus has and will continue to create new labor force issues and amplify existing ones.
On March 18, 2020, the House of Representatives passed H.R. 6021, the “Families First Coronavirus Response Act,” which, contains provisions related to mandatory paid leave for employers with fewer than 500 employees. This legislation and the substantial obligations it imposes apply to the overwhelming number of general contractors in the nation—those with less than 500 full-time employees! The bill mandates up to 80 hours of “emergency paid leave” related to COVID-19, and not just for those who contract the illness. However, contractors with less than 50 employees may seek exemption.
Reprinted courtesy of
Sidney Lewis, Jones Walker LLP and
Alex Glaser, Jones Walker LLP
Mr. Lewis may be contacted at slewis@joneswalker.com
Mr. Glaser may be contacted at aglaser@joneswalker.com
Read the court decisionRead the full story...Reprinted courtesy of
California Case Is a Reminder That Not All Insurance Policies Are Alike Regarding COVID-19 Losses
April 05, 2021 —
Neal I. Sklar & Joshua A. Morehouse - Peckar & Abramson, P.C.A recent case from the Central District of California reminds us that not all insurance policies are alike. Depending on the particular policy, losses from the COVID-19 outbreak could qualify as property damage and therefore could be recoverable under an all-risk insurance policy.
COVID-19 has in many cases imposed significant costs on contractors, and in a host of ways. Contractors’ attempts to recover these costs from owners or insurers have at times been frustrated by contractual or policy language written after a lengthy time, during which the risk of a pandemic on the scale of COVID-19 was not as much of a concern as it is now. This has led contractors to explore new, often creative legal theories in their attempts to recover costs flowing from COVID-19.
A recent Complaint filed in the Central District of California focuses on all-risk property insurance policies and the potential for contractors who have purchased such policies to classify contamination from COVID-19 as an insurable property loss.
In AECOM v. Zurich Insurance Company, Case No. 2:21-cv-00237-JAK-MRW (C.D. Cal), a contractor purchased “all-risk” property insurance from Zurich. This policy covered “economic losses from all risks not expressly excluded.” According to the Complaint, the presence of COVID-19 on its properties “physically alter[ed] air, airspace, and surfaces preventing… (the contractor) from using its properties for their intended purpose and function.”
Reprinted courtesy of
Neal I. Sklar, Peckar & Abramson, P.C. and
Joshua A. Morehouse, Peckar & Abramson, P.C.
Mr. Sklar may be contacted at nsklar@pecklaw.com
Mr. Morehouse may be contacted at jmorehouse@pecklaw.com
Read the court decisionRead the full story...Reprinted courtesy of