Fairfield Connecticut Building Expert Directory

Home Buyers will Pay More for Solar

February 05, 2015 — Beverley BevenFlorez-CDJ STAFF
The National Association of Home Builders’ (NAHB) Eye on Housing reported that a study’s results “found that homebuyers are willing to pay more for homes that have installed solar photovoltaic (PV) energy systems.” The team of researchers led by the U.S. Department of Energy’s Berkeley Laboratory “estimates a price premium of approximately $4 per watt of PV installed. For a typical PV system, the research team found that this translates into a price premium of $15,000.” Furthermore, according to the NAHB, the study “suggests that the presence of energy-efficient home features is among the most important concerns for prospective home buyers.” Read the court decision
Read the full story...
Reprinted courtesy of

California to Require Disclosure of Construction Defect Claims

October 30, 2013 — CDJ STAFF
California Governor Jerry Brown has signed Senate Bill 625. Starting in July 2014, anyone who sells a home will have to disclose all claims made of construction defects and the status of these claims. Read the court decision
Read the full story...
Reprinted courtesy of

Delays and Suspension of the Work Under Fixed Price Government Contract

July 22, 2024 — David Adelstein - Florida Construction Legal Updates
Here is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors. In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Fifth Circuit: Primary Insurer Relieved of Duty to Defend Without Release of Liability of Insured

March 02, 2020 — Bethany L. Barrese & Ashley McWilliams - Saxe Doernberger & Vita, P.C.
In Aggreko, LLC v. Chartis Specialty Ins. Co.,1 the Fifth Circuit affirmed a decision by the Texas District Court and held that a Covenant Not to Execute constituted a “settlement” sufficient to exhaust policy limits and terminate a primary insurer’s duty to defend. This case arose out of a wrongful death suit filed by the parents of James Brenek II (“Brenek”). In 2014, Brenek was fatally electrocuted by an electrically energized generator housing cabinet while performing work on a rig in Texas for Guichard Operating Company, LLC (“Guichard”), a Louisiana-based drilling subcontractor. Guichard had leased the generator from Aggreko, LLC (“Aggreko”). A rental agreement between Guichard and Aggreko required Guichard to maintain commercial general liability insurance during the lease period and list Aggreko and the rig owner, Rutherford Oil Corporation (“Rutherford”), as additional insureds under the policy. Guichard’s primary insurance carrier, The Gray Insurance Company (“Gray”), agreed to defend and indemnify Aggreko and Rutherford in the wrongful death suit. The Gray policy had a limit of $1,000,000, subject to a $50,000 self-insured retention. Reprinted courtesy of Bethany L. Barrese, Saxe Doernberger & Vita, P.C. and Ashley McWilliams, Saxe Doernberger & Vita, P.C. Ms. Barrese may be contacted at blb@sdvlaw.com Ms. McWilliams may be contacted at amw@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Policy Renewals: Has Your Insurer Been Naughty or Nice?

December 26, 2022 — Latosha M. Ellis & Jae Lynn Huckaba - Hunton insurance Recovery Blog
A review of insurance policies at renewal should be on every business’s annual task list—and it should be checked twice! Just as your business grows and evolves every year, so should your insurance program. Together with staying proactive and preparing for renewal months before the policy expiration, there are a number of best practices to put your business in the best position to maximize insurance recovery, including shopping around, evaluating changes to your business, engaging the appropriate stakeholders, and performing a policy audit with a coverage attorney. Shop Around An early start to the renewal process allows for thorough decision-making and more time to engage in negotiations with the insurer. Even if the preference is to stay with the existing insurer, shopping around creates some buying power within the negotiation process. Evaluate Operational or Business Practice Changes Risk control and mitigation have a direct impact on your premiums and availability of coverage. Assess any changes in the business’s exposure to risk and make any necessary insurance coverage adjustments. Reprinted courtesy of Latosha M. Ellis, Hunton Andrews Kurth and Jae Lynn Huckaba, Hunton Andrews Kurth Ms. Ellis may be contacted at lellis@HuntonAK.com Ms. Huckaba may be contacted at jhuckaba@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

An Era of Legends

May 03, 2018 — Beverley BevenFlorez-CDJ STAFF
In 2010, West Coast Casualty’s Construction Defect Seminar added a new award: The Legend of an Era. West Coast Casualty recognizes “those in the construction defect community who inspire, contribute, advocate and influence others for the benefit and betterment of this community, making it a better place.” They define Legend as “One that inspires or achieves legendary fame based upon ones own achievement(s) which promises to be enduring” and Era, as “A fixed point of time from which a series of years is reckoned and an order of things prevail.” This annual award is presented at the West Coast Casualty Construction Defect Seminar. Read the court decision
Read the full story...
Reprinted courtesy of

Submitting Claims on Government Projects Can Be Tricky

March 19, 2015 — Craig Martin – Construction Contractor Advisor
The Federal Circuit Court of Appeals opinion in K-Con Building Systems, Inc. v. United States illustrates the difficulties a contractor may face when pursuing a claim before a Contracting Officer. After nearly 10 years of litigation, the court found that the contractor’s claim to the Contracting Officer did not contain enough detail to allow the claim to proceed. That’s a lot of time and resources wasted on a claim that was dead from the start. K-Con was awarded a $582,000 job to design and build a Coast Guard support building in Michigan. K-Con was unable to complete the project by the finish date and the Coast Guard assessed liquidated damages of $109,554. K-Con contested the assessment of liquidated damages by submitting a one paragraph letter asserting that it was not the sole cause of the alleged delays; that the government was at fault for the delay; and the liquidated damages were an impermissible penalty. The Contracting Officer ultimately denied K-Con’s claim and K-Con appealed to the Court of Claims. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Not Pandemic-Proof: The Ongoing Impact of COVID-19 on the Commercial Construction Industry

December 06, 2021 — George B. Green Jr. - Construction Executive
The impact of COVID-19 has been felt in nearly every industry and arena across the country, with the exception of construction—or so that is the general perception. Perceptions are often wrong though, and this one is no different. The truth is that the construction industry has been hit just as hard, if not harder, than every other industry. As the COVID-19 pandemic struck in the spring of 2020, construction projects plowed forward full steam ahead. Roadwork seemed to increase and developers continued to systematically acquire property and initiate large-scale projects. Perhaps it was these observations that led many to the conclusion that construction was pandemic-proof as the rest of society attempted to cobble together something that vaguely resembled a normal business year. But the construction industry has endured many challenges over the last 18 months, and unfortunately, the challenges do not appear to be evaporating anytime soon. The industry has been primarily affected in the areas of scheduling, manpower and permitting, which has ultimately affected pricing. The entire way jobs are scheduled has been turned upside down. The supply chain issues that many have experienced for everyday household items have hit the construction industry as well. Reprinted courtesy of George B. Green Jr., Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Green may be contacted at ggreen@wwhgd.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES