Fairfield Connecticut Building Expert Directory

Leftover Equipment and Materials When a Contractor Is Abruptly Terminated

November 06, 2023 — Brian Perlberg - ConsensusDocs
Termination for cause is costly and adversarial and has been covered in this article. But can a terminating party use equipment and tools left behind on the worksite (i.e., a crane)? The answer depends on what is in your contract. Under ConsensusDocs, a constructor must give its permission to use any equipment or supplies left at the worksite, such as a crane.[i] Moreover, the owner must indemnify the constructor for using their equipment. This makes sense because even if a constructor were appropriately terminated for cause, using their equipment and materials they no longer possess or control unfairly creates additional liability exposure. At a minimum, the owner should take on the risk of using the equipment and materials since they benefit from such use. Read the court decision
Read the full story...
Reprinted courtesy of Brian Perlberg, ConsensusDocs Coalition
Mr. Perlberg may be contacted at bperlberg@ConsensusDocs.org

Lien Claimant’s Right to Execute against Bond Upheld in Court of Appeals

February 10, 2012 — Douglas Reiser, Builders Council Blog

Stonewood v. Infinity Homes is a simple construction dispute over a matter of about $9,000.00. But sometimes these tiny little disputes turn into expensive legal battles over mere procedural quivering. In Stonewood, a small subcontractor won a big victory yesterday when the Divison 1 Court of Appeals upheld its judgment against a lien release bond posted by an owner.

Infinity Homes contracted with Stonewood Design to lay tile in one of its customer’s homes. Stonewood did the work, but Infinity withheld roughly $9,000.00 of the contract sums for what it alleged were trade damages left on the tile. The two parties were unable to come to an agreement over payment and Stonewood proceeded with a lien under RCW 60.04. It then filed an action to enforce the lien against the homeowner, Infinity and its bonding company.

Read the full story…

Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com

Read the court decision
Read the full story...
Reprinted courtesy of

New Recommendations for Healthy and Safe Housing Conditions

May 19, 2014 — Beverley BevenFlorez-CDJ STAFF
The National Center for Healthy Housing (NCHH) and the American Public Health Association (APHA) jointly “released the National Healthy Housing Standard, which provides recommendations for the maintenance and condition of occupied dwellings,” reported Big Builder. According to Big Builder, “The standard's provisions aim to fill gaps where there are no property maintenance policies and to complement the International Property Maintenance Code and other federal, state, and local policies in place regarding the upkeep of existing homes.” Some of the recommendations included room access to daylight, no or low-VOC building materials, and water management. Read the court decision
Read the full story...
Reprinted courtesy of

Insurer Must Pay for Matching Siding of Insured's Buildings

December 02, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The Seventh Circuit found that the insurer was obligated to pay for siding of a building that was not damaged by hail so that it matched the replaced damaged portions of the siding. Windridge of Naperville Condominium Association v. Philadelphia Indem. Ins. Co., 2019 U.S. App. 23607 (7th Cir. Aug. 7, 2019). A hail and wind storm damaged buildings owned by Windridge. The storm physically damaged the aluminum siding on the buildings' sought and west sides. Philadelphia Indemnity, Windridge's insurer, contended that it was only required to replace the siding on those sides. Windridge argued that replacement siding that matched the undamaged north and east elevations was no longer available, so Philadelphia had to replace the siding on all four sides of the buildings to that all of the siding matched. Windridge sued and moved for summary judgment. The district court ruled that matching was required. The only sensible result was to treat the damage as having occurred to the building's siding as a whole. The policy was a replacement-cost policy. Philadelphia promised to "pay for direct physical 'loss' to 'Covered Property' caused by or resulting from" the storm, with the amount of loss being "the cost to replace the lost or damaged property with other property . . . of comparable material and quality . . . and . . . used for the same purpose." The loss payment provision offered four different measures for loss, leaving Philadelphia free to choose the least expensive: (1) pay the value of the lost or damaged property; (2) pay the cost of repairing or replacing the lost or damaged property; (3) take all or any part of the property at an agreed or appraised value; or (4) repair, rebuild or replace the property with other property of like kind and quality. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Sales of New U.S. Homes Surged in August to Six-Year High

September 24, 2014 — Jeanna Smialek – Bloomberg
New-home sales in the U.S. surged in August to the highest level in more than six years, a sign that the housing recovery is making progress. Purchases of new houses jumped 18 percent to a 504,000 annualized pace, the strongest since May 2008 and surpassing the highest forecast in a Bloomberg survey of economists, Commerce Department figures showed today in Washington. The one-month increase was the biggest since January 1992. The housing market is improving in fits and starts this year amid slow wage growth and tight credit conditions. Sustained improvement in the job market will be needed to push up pay and sustain a stronger recovery. Read the court decision
Read the full story...
Reprinted courtesy of Jeanna Smialek, Bloomberg
Ms. Smialek may be contacted at jsmialek1@bloomberg.net

Couple Claims ADA Renovation Lead to Construction Defects

December 30, 2013 — CDJ STAFF
A couple in Mercer County, West Virginia have claimed that the renovations done to their home not only failed to meet the requested ADA standards, but lead to construction defects, as reported by The West Virginia Record. Ray and Sherry Price are suing Lamberts Construction Company of Bluefield, West Virginia, claiming breach of contract and infliction of emotional distress. The couple hired to company to construct a bathroom addition, a bedroom addition, and a new driveway. In addition to other damages, they are also seeking the cost to repair the renovations. Read the court decision
Read the full story...
Reprinted courtesy of

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Construction Problem Halts Wind Power Park

November 13, 2013 — CDJ STAFF
Engineers have yet to determine why a blade on a wind turbine broke at a wind power plant in Michigan, but as part of their investigation they are halting work on the final 10 turbines. The already completed 60 turbines have been taken out of operation. As a result, the Echo Wind Park is no longer generating power. Scott Simons, a spokesperson for the project, said “we’re not going to put anyone or anything at risk until we get to the bottom of this.” However, Dennis Buda, the project manager, attributed the broken blade to a manufacturing defect. Construction was planned to end in November. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES