Fairfield Connecticut Building Expert Directory

Difficult Task for Court to Analyze Delay and Disorder on Construction Project

August 23, 2021 — David Adelstein - Florida Construction Legal Updates
One of my favorites quotes from a case, and I am sure others in the construction industry feel the same way or can relate, is from the District of Columbia Court of Appeals in Blake Construction Co., Inc. v. C.J. Coakley Co., Inc., 431 A.2d 569, 575 (D.C. 1981):

We note parenthetically and at the outset that, except in the middle of a battlefield, nowhere must men coordinate the movement of other men and all materials in the midst of such chaos and with such limited certainty of present facts and future occurrences as in a huge construction project such as the building of this 100 million dollar hospital. Even the most painstaking planning frequently turns out to be mere conjecture and accommodation to changes must necessarily be of the rough, quick and ad hoc sort, analogous to ever-changing commands on the battlefield. Further, it is a difficult task for a court to be able to examine testimony and evidence in the quiet of a courtroom several years later concerning such confusion and then extract from them a determination of precisely when the disorder and constant readjustment, which is to be expected by any subcontractor on a job site, become so extreme, so debilitating and so unreasonable as to constitute a breach of contract between a contractor and a subcontractor.

Do you agree with this sentiment? The reality is that retrospectively analyzing delay on a complicated construction project with numerous moving parts on a day-by-day, hour-by-hour, basis is no easy feat. It is not easy for the parties and certainly not easy for courts to unravel. With every party claiming delay based on a retrospective analysis there will be another party with either a different delay analysis or providing credible cross examination as to flaws with the delay analysis. The same bodes true with loss of productivity / inefficiency claims and the particular case-specific facts are important, preferably with evidence such as photos, videos, notifications, daily reports, manpower reports, etc., supporting the facts. But the facts are complicated, and the delay analysis is complicated, and it is a difficult task for a trier of fact to unravel these facts. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Burden Supporting Termination for Default

January 11, 2021 — David Adelstein - Florida Construction Legal Updates
Terminating a contractor for default is a “‘drastic sanction’ and ‘should be imposed (or sustained) only for good grounds and on solid evidence.’” Cherokee General Corp. v. U.S., 150 Fed.Cl. 270, 278 (Fed.Cl. 2020) (citation omitted). This is true with any termination for default because terminating a contract for default is the harshest recourse that can be taken under a contract. It is a caused-based termination. For this reason, the party terminating a contract for default needs to be in a position to carry its burden supporting the evidentiary basis in exercising the default-based (or caused-based) termination. Stated differently, the party terminating a contract for default needs to justify the reasonableness in terminating the contract for default. A party looking to terminate a contract for default should smartly work with counsel to best position its justification in exercising the termination for default. Likewise, a contractor terminated for default should immediately work with counsel to best position the unreasonableness or the lack of justification for the default-based termination. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Almost Half of Homes in New York and D.C. Are Now Losing Value

September 03, 2015 — Prashant Gopal – Bloomberg
Almost half of single-family houses in the New York and Washington metropolitan areas are losing value, a sign that buyers' tolerance for high prices in many large U.S. cities may be reaching a limit. The values of 45 percent of houses in both the Washington and New York areas slumped by at least 2 percent in June from a year earlier, according to a new index created by Allan Weiss, co-founder of the Case-Shiller home price indexes. In June 2014, only 15 percent of Washington residences dropped in value, while 20 percent fell in New York. Because the index is of only single-family homes, it doesn't include Manhattan. More properties also were in decline in Los Angeles, Chicago, Phoenix and Miami. Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg

Want to Build Affordable Housing in the Heart of Paris? Make It Chic.

November 01, 2022 — Marie Patino & Kriston Capps - Bloomberg
The project at 12 Rue Jean-Bart is a modest one, just eight units of affordable housing on a narrow lot in Paris near the Luxembourg Gardens. The social housing project nevertheless caused a stir with neighbors in the 6th arrondissement, one of the city’s more affluent areas. When local politicians backing the project came to visit the building during its construction, neighbors shouted from windows across the street that it was a shame to build social housing here, according to Jean-Christophe Quinton, the Paris-based architect who designed the small in-fill development. Local resistance was a persistent feature of the project throughout its three-year-long construction, Quinton says; the building regularly faced harsh scrutiny in local newspaper Le Parisien. Reprinted courtesy of Marie Patino, Bloomberg and Kriston Capps, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Real Estate & Construction News Roundup (5/8/24) – Hotel Labor Disputes, a Congressional Real Estate Caucus and Freddie Mac’s New Policies

June 04, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, nonresidential construction increases, Redfin settles lawsuits, overseas real estate becomes more lucrative than domestic real estate, and more!

High inflation and a disappointing report on economic growth — followed by a sudden drop in stocks late last month — show similar signs to the 1970s when the housing market stagnated, and the decade itself became synonymous with stagflation. (Gabriella Cruz-Martinez, Yahoo)
American investors have figured out that buying property overseas can be both affordable and lucrative, with some countries offering “golden visas” to foreign investors who make large real estate investments in their country. (Jordan Rosenfeld, Yahoo)
Nonresidential construction spending ticked up 0.2% in March to a seasonally adjusted annual rate of $1.19 trillion. (Sebastian Obando, Construction Dive)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Lucky No. 7: Seventh Circuit Court of Appeals Issues Pro-Policyholder Decision Regarding Additional Insured Coverage for Upstream Parties

November 02, 2020 — Daniela Aguila - Saxe Doernberger & Vita
In Scottsdale Ins. Co. v. Columbia Ins. Group, Inc,1 the Seventh Circuit Court of Appeals recently held that a subcontractor’s insurer was obligated to defend and indemnify the project owner’s insurer for damages associated with the subcontractor's employee's personal injury lawsuit where the underlying complaint alleged negligence by the additional insureds. The case cements the notion that under Illinois law, one can significantly benefit from the facts presented in third party complaints as a basis for additional insured coverage. Rockwell Properties (“Rockwell”) was the project owner, along with Prairie Management & Development (“Prairie”), the general contractor, on a construction project in Chicago. Prairie subcontracted HVAC services to TDH Mechanical (“TDH”). When an employee of TDH Mechanical sustained serious injuries performing work at a construction site, a suit was lodged against Rockwell and Prairie in state court. The lawsuit did not bring any claims against TDH but instead alleged that both Rockwell and Prairie had negligently failed to supervise the subcontractors’ work on-site, thus contributing to the worker’s injuries. Read the court decision
Read the full story...
Reprinted courtesy of Daniela Aguila, Saxe Doernberger & Vita
Ms. Aguila may be contacted at dag@sdvlaw.com

Motion to Dismiss COVID Claim Granted in Part, Denied in Part

February 06, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The insurer's motion to dismiss the insured's claim for business losses due to COVID-19 was granted in part, denied in part. SRL v Zurich Am. Ins Co., 2022 U.S. Dist. LEXIS 210058 (N.D. Ill. Nov. 21, 2022). Excelsior owned and managed the Westin Excelsior Rome, a luxury hotel in Rome. The hotel suffered business income losses with the onset of the pandemic.While the hotel was not forced to close, its bookings decreased to virtually nothing. The Excelsior's complaint alleged that the COVID-19 virus was present in and around the hotel as multiple guests and at least six employees tested positive for COVID-19. It further alleged that the virus attached to interior property and was in the air. Excelsior was insured under a commercial property policy issued by Zurich. The court agreed there was no direct physical loss because no structure suffered damage. Among the coverages under the policy, however, was a "Cancellation of Bookings" provision. Zurich agreed there was coverage under this provision, but argued that Excelsior had already reached its annual limit for Cancellation of Bookings claims. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

The ABCs of PFAS: What You Need to Know About Liabilities for the “Forever Chemical”

February 22, 2021 — Robert F. Walsh, Gregory S. Capps & R. Victoria Fuller - Complex Insurance Coverage Reporter
This article is based on a presentation the authors made at White and Williams LLP’s Virtual Coverage College® on October 22, 2020. Every year, hundreds of insurance professionals come to Philadelphia—this year via our online platform—to participate in a full day of lectures and interactive presentations by White and Williams lawyers and guest panelists about the latest issues and challenges involved in claim handling and insurance litigation. Visit coveragecollege.com for more information and stay tuned for Coverage College® 2021. Perfluoroalkyl and polyfluoroalkyl substances, commonly referred to as PFAS or PFOS, have been a key ingredient in numerous industrial and consumer products for decades. These man-made chemicals are prevalent and are also known for their longevity in the environment. More recently, PFAS have been the focus of thousands of lawsuits alleging personal injury and property damage. Some insurers have already questioned whether PFAS could rival asbestos in scope and bottom-line impacts. It is a legacy that confronts manufacturers and other defendants and insurers today. This article provides a primer on PFAS, including the current regulatory framework and litigation landscape. We also identify some key emerging coverage issues insurers should be aware of when dealing with PFAS claims under liability and first-party property policies. Reprinted courtesy of Robert F. Walsh, White and Williams LLP and Gregory S. Capps, White and Williams LLP Mr. Walsh may be contacted at walshr@whiteandwilliams.com Mr. Capps may be contacted at cappsg@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES