Changing Course Midstream Did Not Work in River Dredging Project
December 10, 2015 —
Craig Martin – Construction Contractor AdvisorA contractor learned a $12M lesson when it tried to change course on a Corps of Engineer river dredging project. The case also illustrates the importance of documenting problems on a project and providing notice of those problems to the owner.
In Weston/Bean Joint Venture v U.S., Weston/Bean was awarded a Corps of Engineers project to provide maintenance dredging on the Miami River to a depth of 15 feet. The contract noted that the contractor may experience sediment, debris and rock, including soft to moderately hard limestone.
The contractor encountered rocks early on in the project, but consistently submitted reports to the Corps of Engineers that nothing was experienced on the project that would lead to a change order or claim. And, for the first year of operations, the contractor made no claim for differing site conditions. Instead, the contractor terminated the subcontractor for not being able to process the rock uncovered during the dredging process.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
Manhattan Gets First Crowdfunded Condos
September 03, 2015 —
David M. Levitt & Oshrat Carmiel – BloombergNew York’s first real estate project financed significantly though crowdfunding is set to open, a step forward for a nascent investing model that has yet to prove itself in commercial property.
AKA United Nations, an extended-stay hotel-condominium on East 46th Street near Second Avenue, will start taking guests Sept. 10. Sales of the suites have already begun. Of the $95 million it cost to buy and fix up the existing hotel, $12 million was raised from online pledges.
It’s “the first ever crowdfunded building in New York coming to completion, from A to Z,” said Rodrigo Nino, chief executive officer of Prodigy Network, which is gut-renovating the building with partners. Until now, “everything has been about promises.”
Reprinted courtesy of
David M. Levitt, Bloomberg and
Oshrat Carmiel, Bloomberg Read the court decisionRead the full story...Reprinted courtesy of
Can General Contractors Make Subcontractors Pay for OSHA Violations?
March 05, 2015 —
Craig Martin – Construction Contractor AdvisorOSHA has long held the opinion that general contractors may be held liable for subcontractor’s OSHA violations and the Eighth Circuit Court of Appeals, overseeing the Midwest, has agreed since 2009. To combat this risk, general contractors would be well served to incorporate targeted indemnity provisions into their subcontracts that require subcontractors to pay for all claims and costs associated with subcontractor caused OSHA violations.
OSHA’s Multi-Employer Policy
OSHA’s Multi-Employer Policy, a/k/a OSHA Instruction CPL 02-00-124, allows OSHA to cite multiple employers at a single worksite for creating a hazard, or for failing to prevent or correct a hazard, even if their own workers are not exposed to the hazard. A ‘‘controlling’’ or ‘‘correcting’’ employer is liable for hazards that it did not take ‘‘reasonable care’’ to detect and prevent.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
Intellectual Property And Employment Law Best Practices: Are You Covering Your Bases In Protecting Construction-Related Trade Secrets?
November 15, 2021 —
Colin Holley - ConsensusDocsThere are four main types of intellectual property (IP) – patents, copyrights, trademarks and trade secrets. Many companies have IP rights of all four types. Very different steps are required to protect different types of IP. Your company should work with an experienced IP attorney to develop and continuously update a comprehensive IP protection plan. And for the reasons discussed below, it is important for your company’s IP protection plan to be closely coordinated with employment and contracting practices.
Patents are rights that may be granted to protect uniquely-original and usable inventions for a prescribed period of years, the length of which depends on the patent type. To register a patent, an application must be filed with the United States Patent and Trademark Office (USPTO), which will decide whether the invention is patentable. A registration gives the owner the ability to prevent others from using or selling the invention without permission. Registered patents may be challenged in court on several grounds, but mounting a successful challenge is a very expensive proposition. A patent registration is thus a highly valued asset and is key to preventing others from using or copying your invention, unless you have a foolproof way to keep your invention secret and out of the hands of competitors. On the other hand, if it is possible to keep the invention secret for enough time to gain a commercial advantage over competitors and the enforceability of the patent is questionable, registering a patent may be a mistake because the invention must be publicly disclosed in excruciating detail, for all competitors to see.
Read the court decisionRead the full story...Reprinted courtesy of
Colin Holley, Watt, Tieder, Hoffar, & Fitzgerald, LLPMr. Holley may be contacted at
cholley@watttieder.com
Pennsylvania Civil Engineers Give the State's Infrastructure a "C-" Grade
November 28, 2022 —
American Society of Civil EngineersPENNSYLVANIA. — The Pennsylvania Council of the American Society of Civil Engineers (ASCE) released the 2022 Report Card for Pennsylvania's Infrastructure today at three congruent news conferences across the state including Harrisburg, Lehigh Valley, and Pittsburgh, with 15 categories of infrastructure receiving an overall grade of a "C-". This is the same grade issued by the council in its 2018 report. A "C-" means Pennsylvania's infrastructure is in mediocre condition and requires attention. Pennsylvania's aviation and rail networks are helping to drive economic growth in the region and an improved roadway network is helping increase efficiency for the regional and national economies, but an aging infrastructure network and struggling water systems threaten the health, safety and welfare of the region. Civil engineers graded aviation (B-), bridges (D+), dams (C), drinking water (D), energy (C), hazardous waste (B-), levees (C), parks (C+), ports (C+), rail (C), roads (C-), solid waste (C+), stormwater (D), transit (D), and wastewater (D-).
"Considering Pennsylvania's aging infrastructure and its critical role in our state's economy, policy makers must continue to prioritize dedicated funding to update and improve all infrastructure assets," said Rep. Mike Carroll, D-118. "Failure to do so will seriously harm the quality of life for every citizen."
"This report shows that Pennsylvania's infrastructure has seen some noteworthy improvements and that our lawmakers are prioritizing the built environment, but out-of-sight, out-of-mind systems such as water and wastewater pipelines are lacking the necessary attention," said David DiGioia, chair, 2022 Report Card for Pennsylvania's Infrastructure. "With help from the Bipartisan Infrastructure Law, we could improve our communities for generations if we double down on investment and close our funding gaps across all sectors included in this report."
The Report Card was created as a public service to citizens and policymakers to inform them of the infrastructure needs in their state. Civil engineers used their expertise and school report card-style letter grades to condense complicated data into an easy-to-understand analysis of Pennsylvania's infrastructure network. ASCE State and Regional Infrastructure Report Cards are modeled after the national Infrastructure Report Card, which gave America's infrastructure an overall grade of 'C-' in 2021.
To view the report card and all five categories, visit https://infrastructurereportcard.org/state-item/Pennsylvania/.
ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS
Founded in 1852, the American Society of Civil Engineers represents more than 150,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel.
Read the court decisionRead the full story...Reprinted courtesy of
Subcontractor Entitled to Defense for Defective Work Causing Property Damage Beyond Its Scope of Work
May 27, 2019 —
Tred R. Eyerly - Insurance Law HawaiiThe Illinois Court of Appeals found the subcontractor was owed a defense for alleged property damage caused by its faulty workmanship, but outside its scope of work. Acuity Ins. Co. v. 950 W. Huron Condo. Ass'n, 2019 Ill. App. LEXIS 208 (Ill. Ct. App. March 29, 2019).
The condominium association sued its general contractor, Belgravia, for alleged defects allowing water to infiltrate and cause damage. Belgravia filed a third-party complaint against its subcontractors, including the carpentry subcontractor Denk & Roche. Denk & Roche held a CGL policy with two insurers during the relevant period, one with Cincinnati Insurance Company for the period January 1, 2000 through June 1, 2007, and another with Acuity Insurance Company, effective June 1, 2007, through December 31, 2013.
Denk & Roche tendered its defense to both insurers. Cincinnati agreed to defend and contributed to a settlement of the AOAO's claims. Acuity denied a defense, contending that the underlying claims did not trigger a duty to defend. Acuity's declaratory judgment suit sought a determination that it had no duty to defend. Cincinnati intervened and argued it was entitled to equitable contribution from Acuity.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
BHA Attending the Construction Law Conference in San Antonio, TX
February 18, 2015 —
Beverley BevenFlorez-CDJ STAFFBert L. Howe & Associates, Inc. (BHA) is proud to be joining with the State Bar of Texas, Construction Law Section as a sponsor and exhibitor at the event, and is excited to announce that they will also be sponsoring a raffle for a $100 Nordstrom gift card to given away at the Conference. Just stop by the BHA booth, and drop your card in the bowl for a chance to win.
With offices in San Antonio and Houston, BHA offers the experience of over 20 years of service to carriers, defense counsel, and insurance professionals as designated experts in nearly 5,500 cases. BHA’s staff encompasses a broad range of licensed and credentialed experts in the areas of general contracting and specialty trades, as well as architects, civil and structural engineers, and has provided services on behalf of developers, general contractors and subcontractors across the state of Texas.
BHA’s experience covers the full range of construction defect litigation, including single and multi-family residential (including high-rise), institutional (schools, hospitals and government buildings), commercial, and industrial claims. BHA also specializes in coverage, exposure, and delay claim analysis.
Download the seminar brochure and register...
Read the court decisionRead the full story...Reprinted courtesy of
Wake County Justice Center- a LEED Silver Project done right!
October 01, 2014 —
Melissa Dewey Brumback – Construction Law in North CarolinaYesterday evening, I had the privilege of attending the Triangle USGBC’s “Talk & Walk” at the Wake County Justice Center. The 576,996 square foot Justice Center was completed 6 months early and over 30 million under budget. (The final cost, including soft costs, came in at ~$141,000,000). Now that’s what I call a LEED project done right!
Interestingly, the County did not endeavor for a LEED Silver rating– the plan was to aim for a Certification. However, as the process unfolded, the Team kept meeting the goals and points for a Silver certification without any appreciable additional costs.
The end result? An “iconic but energy efficient building,” according to Tim Ashby, current Wake County Facilities Project Manager. Tim was initially involved in the Project while working at O’Brien Atkins, which served as the architecture firm for the Project under the direction of Architect Andrew Zwiacher.
Read the court decisionRead the full story...Reprinted courtesy of
Melissa Dewey Brumback, Construction Law in North CarolinaMs. Brumback may be contacted at
mbrumback@rl-law.com
