Fairfield Connecticut Building Expert Directory

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Construction Legislation Likely to Take Effect July 1, 2020

April 27, 2020 — Christopher G. Hill - Construction Law Musings
Coronavirus is dominating the news and planning for the effects of COVID-19 is a big deal for construction companies in the Commonwealth. However, these issues, though immediate, are not the only ones that have popped up here at the beginning of 2020. Several bills that I have been monitoring (here and here) have recently passed both the House of Delegates and the Virginia Senate and are on their way to the Governor for signature (a signature that is most likely going to happen in each case). Among those bills that did not pass are a bill that would have eliminated right to work in Virginia and allowed so called “closed shops” as well as fair share fees legislation that would have required those that were not part of a union to pay certain portions of union expenses. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

State Farm to Build Multi-Use Complex in Dallas Area

December 30, 2013 — CDJ STAFF
State Farm in Insurance is building a new office complex which will have space for thousands of State Farm employees in the Dallas area, according to The Dallas Morning News. That’s not all the $1.5 billion development, CityLine, will include. The first phase of the complex will include three office towers, a shopping center, a hotel, and apartments. Opening is expected in early 2015. Read the court decision
Read the full story...
Reprinted courtesy of

Associated Builders and Contractors Northern California Chapter Announces New President/CEO

January 24, 2022 — Associated Builders and Contractors, Northern California Chapter
(January 19, 2022 – Livermore, CA) Associated Builders and Contractors, Northern California Chapter (ABC NorCal) Board of Directors launched an exhaustive, nationwide CEO search, and recently selected Deborah Maus as the next President/CEO. Deborah is a Certified Association Executive (CAE) with 25+ years of strategic and operational leadership. Prior to accepting the position, Deborah served as the chief executive officer of Plumbing Heating Cooling Contractors of California. Mark Kirkes, President of MK Electric & Design Inc—and 2022 ABC NorCal Chair— said, "We believe Deborah will focus on strengthening organizational structure to meet new and expanding program needs, guide policy development and strategic innovations, bring increased value to members and continue to be the leading voice of the merit shop in Northern California. Her demonstrated knowledge of the industry and her support of all who desire to succeed in the construction industry made her an ideal choice to advance ABC's mission in Northern California." Former ABC NorCal President/CEO Michele Daugherty is transitioning to the ABC Central Florida Chapter as President/CEO, continuing her 16+ years of service in ABC. ABC 2021 Chair, Josh Ward noted, "Michele has been working for ABC since 2006 and we are happy to see that she is staying in the ABC family—continuing to fight for the Merit Shop. The Executive Committee expresses its sincere appreciation for Michele and her remarkable services to the organization. Her enthusiasm and leadership will be deeply missed and difficult to replicate. However, we believe we have found the right person in Deborah Maus." About ABC Northern California Chapter ABC Northern California Chapter (ABC NorCal) is a trade association founded on the merit shop philosophy and dedicated to serving construction professionals from Fresno to the Oregon border. Our mission: To promote free enterprise by advancing the merit shop philosophy in the construction industry through education, advocacy and business services. To learn more visit www.abcnorcal.org Read the court decision
Read the full story...
Reprinted courtesy of

Rainwater Collecting on Rooftop is not Subject to Policy's Flood Sublimits

October 15, 2024 — Tred R. Eyerly - Insurance Law Hawaii
Responding to a certified question from the First Circuit, the Supreme Judicial Court of Massachusetts determined that rainwater collecting on the insureds' rooftop and causing interior damage was not "flood" as defined in the policy and subject to sublimits. Zurich Am. Ins. Co. v. Medical Properties Trust, Inc., 2024 Mass. LEXIS ___ (Mass. July 23, 2024). A severe thunderstorm caused heavy rain and strong winds which damaged a hospital. The hospital was owned by Medical Properties Trust, Inc. (MPT) and leased to Steward Health Care System LLC (Steward). Ground water accumulated and flooded the basement. Rainwater also accumulated on the hospital's parapet roofs and on the second-story courtyard, and eventually seeped through the parapet roofs and courtyard to the hospital's upper floors, causing damage to the building and property within. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

The Biggest Thing Keeping Young Homebuyers out of the Market Isn't Student Debt

September 17, 2015 — Patrick Clark – Bloomberg
Conventional wisdom has it that the staggering student debt incurred by the current generation of young professionals has made it harder to save for a home—and deprived the U.S. housing market of the first-time buyer lifeblood it depends on. But not so fast. A blog post published by Zillow today shows that student-loan debt has little impact on the homebuying prospects of young families. This is not the first report to poke holes in the student-debt-holding-back-home-ownership theory, but Zillow's research makes its point by limiting the data to married couples in their early-30s with at least one child. The idea was to cut out the student debtors who don't own homes because they haven't yet started a family and attempt to isolate the effect of student debt on home ownership. Read the court decision
Read the full story...
Reprinted courtesy of Patrick Clark, Bloomberg

Do You Have an Innovation Strategy?

November 08, 2017 — Aarni Heiskanen - AEC Business
Construction and engineering are among the top five industries ripe for disruption according to research by PwC. Will innovation come from tech companies and startups, or could established firms be proactive? For Granlund, founded in 1960, innovation is a strategic essential and a core competency. Granlund is a Finnish design, consultancy, and software services firm specializing in energy efficiency. It employs more than 800 people in 20 locations in Finland and in its offices in Shanghai and Dubai. The company is known internationally for being in the vanguard of building information modeling and for real estate management software development. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

Payment Bond Claim Notice Requires More than Mailing

June 18, 2019 — Christopher G. Hill - Construction Law Musings
It’s been a while since I posted something new relating to Virginia’s “Little Miller Act” and its various notice requirements for a subcontractor to make a payment bond claim. I have posted on the basics of a Virginia payment bond claim previously here at Musings. One of these basics is the 90 day notice requirement for suppliers or second tier subcontractors with no direct contractual relationship to the general contractor. A recent case from the Norfolk, Virginia Circuit Court examined when notice is “given” under the Little Miller Act. In R T Atkinson Building Corp v Archer Western Construction, LLC the Court looked at the question of whether mailing of the notice of claim is enough to constitute notice being “given” in a manner that would satisfy the statutory requirements. In that case, the supplier mailed the notice within the 90 day window, but the defendant argued on summary judgment that it did not receive the notice until 2 days after the 90 day window had closed. In support of this contention, the defendant provided tracking information showing delivery by the USPS on the non-compliant date. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES