Fairfield Connecticut Building Expert Directory

Blockbuster Breakwater: Alternative Construction Method Put to the Test in Tampa Bay

August 14, 2023 — Scott Judy - Engineering News-Record
On June 7, 2023, Tampa Bay news reporters trekked to the Sunshine Skyway bridge for a Florida Dept. of Transportation press conference that would explain the mystery behind the hundreds of curiously shaped concrete structures lining nearly the entire length of the span’s mile-plus-long south fishing pier access road. Reprinted courtesy of Scott Judy, Engineering News-Record Mr. Judy may be contacted at judys@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

North Carolina Appeals Court Threatens Long-Term Express Warranties

April 09, 2014 — Beverley BevenFlorez-CDJ STAFF
Jonathan Massell of the firm Nexsen Pruet explained how a “recent holding by the North Carolina Court of Appeals is threatening to render many long-term express warranties ineffective,” in the online publication Lexology. In Christie v. Hartley Construction, Inc., “the court held that the six-year North Carolina statute of repose for improvements to real property trumps the bargained-for duration terms of an express warranty.” In the Christie case, this meant that even though the homeowners had a twenty year warranty, because of the statute of repose, the warranty effectively expired after six years. Massell stated to “be mindful of jurisdiction.” If the express warranty is in a state other than North Carolina, it’s possible that the claim could be filed in that state instead of North Carolina. For instance, according to Massell, South Carolina’s “statue of repose does not expire until eight years after the date of substantial completion for an improvement to real property.” Furthermore, “long-term warranties are not trumped by the South Carolina statute of repose.” Read the court decision
Read the full story...
Reprinted courtesy of

Construction Litigation Roundup: “Ursinus is Cleared!”

March 11, 2024 — Daniel Lund III - Lexology
Ursinus University in Pennsylvania – a “private, nonprofit liberal arts college” – funded a construction project for a new building utilizing monies loaned by the Montgomery County Health and Higher Education Authority, a public economic development authority “formed by the Board of County Commissioners… authorized to issue bonds relative to projects for eligible educational institution such as Ursinus.” Loans up to the amount of $23,000,000 became available to the University, and construction proceeded using the loans as construction funds. At issue: whether a project was to be considered publicly funded project such that prevailing wage rates were required to be paid. IBEW filed a related grievance with the Pennsylvania Department of Labor and Industry’s Bureau of Labor Law Compliance, which was refused by the Bureau, on the basis that because work was “financed completely by loans from the Authority, which Ursinus was required to repay in their entirety, the Project was ultimately funded through private sources and exempt from coverage under the [Pennsylvania Prevailing Wage Act].” A grievance to the Prevailing Wage Appeals Board ensued, and the Board took a different position. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Arizona Supreme Court Confirms a Prevailing Homeowner Can Recover Fees on Implied Warranty Claims

August 30, 2017 — Rick Erickson - Snell & Wilmer Real Estate Litigation Blog
On August 9th, in Sirrah Enterprises, L.L.C. v. Wunderlich, the Arizona Supreme Court settled the question about recovery of attorneys’ fees after prevailing on implied warranty claims against a residential contractor. The simple answer is, yes, a homeowner who prevails on the merits can recover the fees they spent to prove that shoddy construction breached the implied warranty of workmanship and habitability. Why? Because, as Justice Timmer articulated, “[t]he implied warranty is a contract term.” Although implied, the warranty is legally part of the written agreement in which “a residential builder warrants that its work is performed in a workmanlike manner and that the structure is habitable.” In other words, a claim based on the implied warranty not only arises out of the contract, the claim is actually based on a contract term. Since, in A.R.S. § 12-341.01, Arizona law provides for prevailing parties to recover their fees on claims “arising out of contract” and because the implied warranty is now viewed by the courts as a contract term, homeowners can recover their fees after successfully proving breach of the implied warranty. Read the court decision
Read the full story...
Reprinted courtesy of Rick Erickson, Snell & Wilmer
Mr Erickson may be contacted at rerickson@swlaw.com

Court Addresses HOA Attempt to Restrict Short Term Rentals

December 11, 2018 — Kevin J. Parker - Snell & Wilmer Real Estate Litigation Blog
In a recent case, the Texas Supreme Court addressed an attempt by a homeowners’ association (“HOA”) to restrict short-term rentals based upon recorded Covenants, Conditions, and Restrictions (“CC&Rs”) applicable to a residential subdivision. The property was a single-family home. The homeowner rented the home through websites such as VRBO. The HOA issued notices of violation; the homeowner kept renting; the HOA assessed fines against the property. The property owner then sought a declaration from the court that the CC&Rs did not impose a minimum duration on occupancy or leasing. The trial court agreed with the HOA. The Texas Court of Appeals also agreed with the HOA. The Texas Supreme Court reversed, holding that the CC&Rs, as properly interpreted, did not prohibit short-term rentals. In arriving at its holding, the Texas Supreme Court analyzed the CC&Rs in detail and came to an interpretation different than the trial court and the Court of Appeals. Read the court decision
Read the full story...
Reprinted courtesy of Kevin J. Parker, Snell & Wilmer
Mr. Parker may be contacted at kparker@swlaw.com

Insurer Entitled to Reimbursement of Defense Costs Under Unjust Enrichment Theory

May 04, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court for the district of Hawaii determined that the insurer could recover defense costs from an additional insured consistent with its Reservation of Rights letter under an unjust enrichment theory. Giga, Inc. v. Kiewit Infrastructure W. Co., 2020 U.S. Dist. LEXIS 10151 (D. Haw. Jan. 22, 2020). This case was related fall-out from the Arthur case. Arthur v. Dept. of Hawaiian Homelands, 185 Haw. 149 (Haw. Ct. App. 2015). A prior post on the case is here. In Arthur, a resident, Mona Arthur, of the Kalawahine Streamside Housing Development, was killed when she apparently slipped and fell from a hillside adjacent to the project. She was on the hillside tending to her garden there. At the bottom of the hill was a two foot fence in front of a drainage ditch, where Mona allegedly hit her head. Mona's husband, William Arthur, sued a variety of defendants including the land owner, designer, developer, civil engineer and others. William alleged the defendants were negligent in the design, construction and supervision of the construction of the hillside area. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Newport Beach Attorneys John Toohey and Nick Rodriguez Receive Full Defense Verdict

July 31, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara is pleased to report that Partner John Toohey and Senior Associate Nicholas Rodriguez received a complete defense verdict after a 5-week jury trial in Orange County Superior Court. The case involved a multimillion-dollar home in Orange County. Plaintiff had originally suffered a water loss throughout areas of the home. Our client, an Orange County restoration and construction company, was hired to provide on-going estimates and perform demolition. Plaintiff claimed that, in the course of the demolition process, asbestos containing material was disturbed and spread resulting in contamination throughout home. Plaintiff claimed contractor negligence and breach of contract against our client. Plaintiff sought millions against our client in general and special damages for whole home restoration and other related general damages. The jury found in complete favor of our client on all allegations and awarded zero dollars to the opposing party. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES