SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Employee Screening and Testing in the Covid-19 Era: Getting Back to Work

August 10, 2020 — Aaron C. Schlesinger & Shannon D. Azzaro - Peckar & Abramson
Currently Available Workplace Protocols for Employers Employers seeking to minimize the risk of COVID-19 transmission in the workplace should consider from among the three currently available protocols: Written Questionnaires; Temperature Checks; and Viral or Diagnostic Testing. When implementing a screening or testing protocol, employers should explain the following in writing to employees: (1) the specific screening process or test utilized by the employer; (2) employee compliance expectations and any consequences for a refusal to participate; (3) how employee privacy will be protected; (4) if screening, the general benchmarks that indicate the employee has “passed” (e.g., temperature below 100.4ºF, per CDC guidelines); and (5) the outcome of an unsuccessful screen or test (e.g., being sent home from the workplace). Employers must also ensure that those administering the screening and/or testing are properly trained, and that appropriate written acknowledgements are obtained from employees consenting to the applicable protocol. Reprinted courtesy of Aaron C. Schlesinger, Peckar & Abramson and Shannon D. Azzaro, Peckar & Abramson Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com Ms. Azzaro may be contacted at sazzaro@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

What You Need to Know About Notices of Completion, Cessation and Non-Responsibility

June 30, 2016 — Garret Murai – California Construction Law Blog
We talk a lot about contractors on the California Construction Law Blog. Owners? Not so much. So this one’s for you. Why are Notices of Completion, Cessation and Non-Responsibility Important to Owners? California recognizes three types of statutory notices on construction projects available to owners:

• Notices of completion;
• Notices of cessation; and
• Notices of non-responsibility.
Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Scientists found a way to make Cement Greener

October 01, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Futurity, scientists say by “paying attention to concrete’s atomic structure…they could make it better and more environmentally friendly.” Cement currently is “the third-largest source of carbon dioxide released to the atmosphere.” Materials scientist Rouzbeh Shahsavari stated that “[t]he heart of concrete is C-S-H—that’s calcium, silicate, and hydrate (water). There are impurities, but C-S-H is the key binder that holds everything together, so that’s what we focused on.” The team spent a year in research and “looked at defects in about 150 mixtures of C-S-H to see how the molecules lined up and how their regimentation or randomness affected the product’s strength and ductility.” Read the court decision
Read the full story...
Reprinted courtesy of


---

Take Advantage of AI and Data Intelligence in Construction

May 06, 2019 — Nick Carter - Construction Executive
For consumers, AI and data intelligence are daily activities. Purchase recommendations from Amazon simplify holiday shopping. Music options from Spotify helps employees focus during the workday and relax at night. Car-sharing apps remove the stress from post-happy hour transport. It is time for this kind of data-driven ease to hit the construction industry. Building is booming, yet despite the good times, the industry still lags in terms of data intelligence and AI. With them, construction providers can transform document and jobsite information into intelligent insights, reduce errors, keep projects on schedule and predict and prevent costly inefficiencies. Artificial intelligence is the “connective tissue” that construction is missing--if it is used wisely. Why Construction is Ready for AI With its endless stream of owners, architects, engineers, contractors, subcontractors and suppliers, the construction industry manages more critical information on a day-to-day basis than nearly any other business. As a result, there are dozens of potential miscommunications just waiting to happen every day. Reprinted courtesy of Nick Carter, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of


---

General Contractors Have Expansive Common Law and Statutory Duties To Provide a Safe Workplace

February 18, 2020 — Paul R. Cressman Jr. - Ahlers Cressman & Sleight PLLC
On November 21, 2019, the Washington Supreme Court handed down its decision in Vargas v. Inland Washington, LLC.[1] At the time of the incident in May 2013, Mr. Vargas, the plaintiff, was helping pour the concrete walls for what would become a parking garage for an apartment building. He was employed by Hilltop Concrete Construction. Inland Washington was the general contractor, and subcontracted with Hilltop to pour concrete. Hilltop, in turn, entered into agreements with Ralph’s Concrete Pumping and Miles Sand & Gravel to provide a pump truck, certified pump operator, and supply concrete. A rubber hose carrying concrete whipped Mr. Vargas in the head. It knocked him unconscious and caused a traumatic brain injury. Vargas, through his guardian ad litem, along with his wife and children, sued Inland Washington, Ralph’s, and Miles. The trial court initially dismissed on summary judgment Vargas’ claims that Inland Washington was vicariously liable for the acts of Hilltop, Ralph’s, and Miles. Later, the trial court also granted Inland Washington’s motion for summary judgment that it was not directly liable as a matter of law. Read the court decision
Read the full story...
Reprinted courtesy of Paul R. Cressman Jr., Ahlers Cressman & Sleight PLLC
Mr. Cressman may be contacted at paul.cressman@acslawyers.com

---

Breach of Fiduciary Duty Claim Against Insurer Survives Motion to Dismiss

June 10, 2015 — Tred R. Eyerly – Insurance Law Hawaii
While some of their claims were dismissed, plaintiffs' breach of fiduciary duty survived the insurer's motion to dismiss. Senft v. Fireman's Fund Ins. Co., 2015 U.S. Dist. LEXIS 61870 (D. N.J. May 12, 2015). Plaintiffs' waterfront home was insured by Fireman's Fund. Plaintiffs alleged that the broker represented that the policy would provide (1) coverage in the event of a hurricane,(2) the "highest level of protection" offered by Fireman's Fund, and (3) "exceptional" services in the event of a catastrophe. The policy included a 2% hurricane deductible because of the home's proximity to the ocean. Hurricane Sandy badly damaged plaintiffs' home. Plaintiffs alleged that the winds from Sandy battered their home long before the storm surge reached the structure. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Court Bars Licensed Contractor From Seeking Compensation for Work Performed by Unlicensed Sub

June 06, 2022 — Garret Murai - California Construction Law Blog
It all started with a tree. A eucalyptus tree to be exact. What followed is one of the more important cases to be decided under Business and Professions Code section 7031 in recent years. Yes, that Section 7031. The statute variously described by the state’s courts as “harsh[ ],” draconian” and “unjust,” but, importantly, nevertheless valid. Under Section 7031, an unlicensed contractor is barred from seeking compensation for work requiring a contractor’s license. This has been called the “shield.” However, in addition to the “shield,” project owners can also employ Section 7031’s “sword,” and seek disgorgement of all monies paid to an unlicensed contractor. Section 7031’s “shield” and “sword” applies even if the project owner knew that the contractor was unlicensed. They also apply even if the unlicensed contractor’s work was flawless. And they also apply even if a contractor was unlicensed during a portion of its work. This is because, as courts have stated, Section 7031 is a consumer protection statute intended to protect the public from unlicensed contractors and applies irrespective of the equities. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---